洛江区马甲至河市应急供水工程招标公告
洛江区马甲至河市应急供水工程招标公告
1.1.2 合同当事人和人员
1.1.2.2 发包人：福建省水务发展集团洛江水务有限公司
1.1.2.3 承包人：(签约后填入承包人的名称)
1.1.2.5 分包人：(签约后填入分包人的名称)
1.1.2.6 监理人：(填入监理人名称)
1.1.4 日期
1.1.4.3 工期：日历天（其中各关键节点的工期：/）
1.1.4.5 缺陷责任期（工程质量保修期）：工程通过合同工程完工验收合格后1年。
进入合同文件的各项文件及其优先顺序是
（1）合同协议书及各种合同附件（含评标期间和合同谈判过程中的澄清文件和补充资料）；
（2）中标通知书；
（3）投标函及投标函附录；
（4）专用合同条款；
（5）通用合同条款；
（6）技术标准和要求；
（7）图纸；
（8）已标价工程量清单；
（9）承包人有关人员、设备投入的承诺及投标文件中的施工组织设计；
（10）其他合同文件。
1.7.2 来往函件均应按技术标准和要求（合同技术条款）约定的期限送达监理人，并办理签收手续。
2 发包人义务2.3.2 发包人提供的施工用地范围为：发包人负责办理招标图纸所示范围内用地征地和移民，向承包人提供能满足施工条件所需的用地，提供的用地期限在签订合同书时商定。超出招标图纸所示范围的用地，由承包人报监理人及发包人审批，若确需增加，由发包人负责征用，发生费用由承包人自行承担。
2.3.3 承包人自行勘察的施工场地范围为：删去本款全文，并代之以：“发包人负责办理工地范围内的征地和移民。施工用地由承包人自行勘察并对其结果自行负责，提供的用地范围和期限在签订协议书时商定。”。
(根据发包人的合同管理要求补充)
（1）……
（2）……
3 监理人3.1.1 监理人须根据发包人事先批准的权力范围行使权力，发包人批准的权力范围：
（1）按第4.3条约定，批准工程的某些非主体和非关键性工作分包；
（2）确定第4.11款下产生的费用增加额；
（3）按第11.3条约定，确定延长完工期限；
（4）根据第12.3款、第12.4款发布开工通知、暂停施工指示或复工通知；
（5）确定第15.4款下变更工作的单价；
（6）按第15.6条约定，批准暂列金额的使用；
（7）确定第15.8款项下的暂估价金额；
（8）确定第23.1款项下的索赔额。
（9）本项目设计变更、费用增减、工期顺延的指令、停工令、复工令的签发；施工总进度计划的审定；监理人有权拒绝承包人提供的不合格材料或工程设备，并要求承包人立即进行更换。监理人应在更换后再次进行检查和检验，由此增加的费用和（或）工期延误由承包人承担；总监理工程师签发任何付款凭证及主要管理人员更换、试验单位资质审核、主材进场审核等需经发包人同意。
如果发生紧急情况，监理人认为将造成人员伤亡，或危及本工程或邻近的财产需立即采取行动，监理人有权在未征得发包人的批准的情况下发布处理紧急情况所必须的指令，承包人应予执行，由此造成的费用增加由监理人按第3.5款商定或确定。
4 承包人4.1.4 对施工作业和施工方法的完备性负责
增加以下内容：
（1）合同签订15个日历天内承包人须向发包人及监理人提交完整的实施性施工组织设计、专项施工安全方案、安全度汛方案、抗台、雨季确保施工安全的方案和措施，施工场地内的排水组织方案以及工程施工总进度计划（包含以下重要节点完成时间）壹式肆份；
（2）每周星期一及每月25日前向发包人报送经监理人审核的《周例会报告》及包含“下一月度施工计划”、“实际进度与计划进度对比”的当月完成进度报告，一式肆份。
（3）合同签订后15个日历天内及每月25日前向发包人提供项目建设资金使用计划及每月用款计划，一式肆份。
（4）工程完工时提交完工报告书，遇其它异常情况应及时向发包人及监理人报告。
（5）发包人要求承包人提供的其他相关资料与表格。
以上报表、资料承包人均应按时提供，如果无故拖延或不提供的，每发生一次发包人有权要求承包人支付5000元的违约金，并从当期进度款中直接扣除。
（6）承包人应负责协调处理好与其承包的工程所在地的地方政府、农民及附近的有关单位的关系，尽可能的避免发生纠纷，还应该注意做好环境保护工作，以利工程顺利进行，发包人将尽力给予协助。在投标前现场勘查阶段，承包人应充分考虑上述因素，制定相应的措施及施工方案，并将由此产生的相关费用计入投标报价中。如因承包人处理不当导致工程暂停施工，或者向发包人索赔，则由承包人负责并承担全部责任。如承包人确无责任导致施工暂停施工，或者向发包人索赔，则由发包人、监理人及承包人与矛盾的对方协商解决，其中实际延迟的工期可按一半时间顺延，相关费用由承包人承担。
（7）承包人应采取适当的防洪排涝、安全度汛措施，并将有关费用列入工程报价，应防止洪水给施工工区造成损失。
4.1.10 其他义务
（1）临时占地由承包人向当地政府土地管理部门申请，并办理租用手续，承包人承担相关费用，费用包含在投标报价里不另计。
临时占地范围包括承包人驻地的办公室、食堂、宿舍、道路和机械设备停放场、材料（包括爆破所需材料）堆放场地、弃土场、预制场、拌合场、仓库、进场临时道路、临时便道、便桥等。承包人应在“临时占地计划表”范围内按实际需要与先后次序，提出具体计划报监理人同意，并报发包人。临时占地的面积和使用期应满足工程需要，费用包括临时占地数量、时间及因此而发生的协调、租用、复耕、地面附着物（电力、电信、房屋、坟墓除外）的拆迁补偿等相关费用。
临时占地退还前，承包人应自费恢复到临时占地使用前的状态。如因承包人撤离后未按要求对临时占地进行恢复或虽进行了恢复但未达到使用标准的，将由发包人委托第三方对其恢复，所发生的费用将从应付给承包人的任何款项内扣除。
（2）承包人应严格遵守国家有关解决拖欠工程款和民工工资的法律、法规，及时支付工程中的材料、设备货款及民工工资等费用。承包人不得以任何借口拖欠材料、设备货款及民工工资等费用，如果出现此种现象，发包人有权代为支付其拖欠的材料、设备货款及民工工资，并从应付给承包人的工程款中直接扣除相应款项。对恶意拖欠和拒不按计划支付的，作为不良记录纳入水利建设市场信用信息管理系统。
（3）承包人在实施和完成承建合同工程及修复缺陷过程中的一切作业应保证发包人免于承担因承包人借用、占用或进出其他标段工区或影响作业等所引起的索赔、诉讼费、损害赔偿及其他开支。承包人有义务提供与相邻标段工程施工的配合与协调，包括：
①工作面的安全和施工质量影响。
②施工进度的影响。
③及时提供或移交工作面。
④保持相邻界面附近的结构质量。
⑤为其他标段承包人提供交通道路、交叉工作面的作业场地。
（4）承包人应接受工程质量监督和工程安全鉴定单位的检查，并及时提交相关的自检报告。
（5）承包人应做到保证工程技术资料及竣工资料编制与施工同步进行，保证竣工资料的完整性和准确性。
（6）承包人应对设计图纸中的标高等进行复核、测量，发现设计与现状不符，应在施工前书面提出，报监理人及发包人并与设计部门进行协调、修改。若承包人对设计图纸不进行校核，擅自施工，造成返工的，一切损失由承包人负责。
（7）承包人应在施工组织设计建议书中就可预见的抗台风、雨季确保施工安全等制定方案和措施，并在工程实施过程中切实执行该方案和措施，由此所发生的一切费用应计入在相关项目的单价和合同总价之中。未按此方案或措施进行施工而造成的一切损失或后果发包人将不承担任何责任。
（8）承包人在施工过程中应采取一切措施防止对施工现场及其周边地区的污染，应根据环保部门的规定制定保护方案并予以实施。由于承包人措施不力或未采取相应的措施造成的一切责任、损失及相应罚款均由承包人承担。
（9）承包人的施工组织中应充分考虑施工期间的交通组织、土石方、材料运输过程中的运输距离、安全问题、施工干扰问题，制定社会交通组织方案等，按照制定的详细保证措施并在施工中予以实施，由此所发生的一切费用承包人均应计入在相关项目的单价和合同总价中，发包人不另行支付。
（10）包括安全、质量、外观在内的所有永久性工程的施工，承包人必须提前一周提供专门的施工组织计划和施工方案报监理人审批同意后方可实施。
（11）承包人必须对本项目履行合同的管理班子主要成员进行书面授权，并将书面授权书报监理人审批后送发包人备案。
（12）跟踪本项目范围内的征地拆迁工作进展情况，协调解决施工中与当地居民发生矛盾，及时反馈与征地拆迁相关信息。
（13）施工控制网由承包人负责测设，控制测量基准点、水准点由承包人负责从本项目测量基准点引用，相关费用由承包人承担，发包人予以协助。
（14）所有施工区和生活区的输配电线路需要指派持有电工进网作业证的电工人员负责修建和维护并承担相关费用，其相关费用应综合考虑在投标报价中，中标后不再另行计取。
（15）承包人应充分考虑施工区和生活区的供用电能力及可能发生的停电事故对工程的影响和损失，按其自身需要，为本合同工程的施工区和生活区用电，配备备用电源，因停电产生的损失和设置使用备用电源发生的费用由承包人自行承担，其相关费用应综合考虑在投标报价中，中标后不再另行计取。
（16）承包人应在施工现场或工地附近为监理人、设计代表提供各不少于15平方米建筑面积的房屋供监理人、设计代表等办公和生活使用，相关费用在临建措施费中计取，提供的房屋建筑时间至工程完（竣）验收后为止。
（17）承包人的合同价已包含劳保费用，承包人应向有关部门办理相关的劳保费缴交手续。
（18）施工作业区场内道路等由承包人负责修建，承包人负责全部施工道路在整个施工期内的管理和养护维修并承担相关费用。发包人予以协助。现有进场道路、桥、涵需维修加固产生费用，另订补充协议解决。
（19）承包人应做好各类安全施工防护措施、场内公路维修、维护、监管等安全生产工作，其相关费用应综合考虑在投标报价中，中标后不再另行计取。承包人应做好施工区各类电力线路、周边电站工厂、通信光缆、管道等设施的保护工作，其相关费用应综合考虑在投标报价中，中标后不再另行计取。如果承包人造成各类电力线路、周边电站工厂、通信光缆、管道等设施的破坏，其损失全部由承包人承担，发包人概不负责。
（20）承包人应严格遵守国家有关解决拖欠工程款和民工工资的法律、法规，按照《福建省人力资源和社会保障厅等六部门关于工程建设领域工资保证金实行差异化缴存的通知 》（闽人社文【2017】336号）等相关文件要求，及时支付工程中的材料、设备货款及民工工资等费用。承包人不得以任何借口拖欠材料、设备货款及民工工资等费用，如果出现此种现象，发包人有权代为支付其拖欠的材料、设备货款及民工工资，并从应付给承包人的工程款中扣除相应款项。
（21）承包人应科学安排施工，采取有效措施尽量减少施工噪音、粉尘等对周边单位及居民正常工作、生活造成的影响，同时负责协调处理好与周边单位及居民关系，自行妥善解决工地外部对工程施工的干扰影响，并按照相关规定，承包人和发包人各自承担相应费用。
（22）施工中产生的建筑垃圾应及时清理，防止环境污染，同时做好施工场地及周边环境的日常卫生保洁工作，并按照相关规定，承包人和发包人各自承担相应费用。
4.3.2 允许承包人分包的工程项目、工作内容与分包金额限额为：
（1）工程项目：/。
（2）工作内容：/。
（3）分包金额限额：/。
4.3.10 分包人项目管理机构的设立：/。
4.5.1承包人应按投标承诺指派项目经理（建造师）到职。合同期间承包人更换项目经理（建造师）应先提出书面申请，并应在更换14天前将更换人员报经发包人、监理人批准，且所更换人员的资格、业绩和信誉不得低于承包人投标时承诺标准，经发包人和监理人书面批准后方可更换，工作移接完毕后方可离开。本合同的项目经理未到职或擅自更换(除因病长期住院治疗及发包人认可的原因外)每人次承包人须向发包人交纳违约金人民币10万元。本合同的项目经理每月出勤不得少于22天，发包人有权制定考勤办法。本合同的项目经理需常驻现场，短期离开施工场地，应事先征得监理人及发包人同意，并委派代表代行其职责。如发现项目经理未签到或没有在现场履行职责，且未事先征得监理人及发包人同意，则发包人可按承包人项目经理擅自离岗，承包人需按每人次5000元标准向发包人支付违约金，上述约定的违约金发包人有权从尚未支付的工程款中直接扣除。
4.6.3承包人应按投标承诺指派技术负责人、施工员、安全员、质检员等主要管理人员到职。合同期间承包人更换技术负责人、施工员、安全员、质检员等主要施工管理人员应先提出书面申请，并应在更换14天前将更换人员报经发包人、监理人批准，且所更换人员的资格、业绩和信誉不得低于承包人投标时承诺标准，经发包人和监理人书面批准后方可更换，工作移接完毕后方可离开。
本合同的技术负责人未到职或擅自更换每人次承包人须向发包人交纳违约金人民币5万元；本合同的关键岗位人员（施工员、质检员、安全员、材料员）未到职或擅自更换每人次承包人须向发包人交纳违约金人民币1万元。本合同的技术负责人和关键岗位人员每月出勤不得少于22天，发包人有权制定考勤办法。本合同的技术负责人和关键岗位人员需常驻现场，短期离开施工场地，应事先征得监理人及发包人同意。技术负责人擅自离岗，经发现承包人需按每人次3000元标准向发包人支付违约金；关键岗位人员擅自离岗，经发现承包人需按每人次1000元标准向发包人支付违约金，上述约定的违约发包人有权从尚未支付的工程款中直接扣除。
4.7.1在施工过程中，发包人、监理人发现承包人的项目经理、技术负责人、以及专职质量、安全生产管理人员有重大失误或不能胜任工作，有权要求承包人予以更换，承包人必须无条件接受，且须按本合同专用合同条款第22条的约定承担违约赔偿责任。
4.9.1发包人按合同约定支付给承包人的各项价款应专用于合同工作。发包人或政府审计部门有权要求对承包人收取的工程款资金流向进行延伸审计，承包人应无条件接受延伸审计并主动配合。
4.11.1 不利物质条件的范围：按照通用合同条款有关约定执行。
5 材料和工程设备5.1.4承包范围内的所有材料、设备均由承包人自行采购供应，且应满足：
（1）承包人所提供主要材料设备应由发包人及监理人共同根据现有市场确定生产厂家（产地）、品牌、规格、质量等级等，但不免除承包人应承担的有关工程质量责任，并应按照工程师和发包人要求提前15天向发包人提供样品、有关资料和采购计划，报发包人及监理人审批后才能采购。
（2）承包人所提供主要材料设备属于福建省水务发展集团有限公司统招分采按集团出台的文件执行，不属于统招分采的在福建省水利投资开发集团有限公司出台的名录库中选用，承包人必须优先选用名录库中合资品牌的产品，都不属于以上两种情况的，品牌经招标人和监理人确定后才能采购。工程实施过程中福建省水利投资开发集团有限公司或福建省水务发展集团有限公司有新的文件出台，按新的文件执行。承包人所用的主材（设备）须事先得到发包人批准后方可使用，发包人有权拒绝使用不符合施工图纸规定标准的材料设备。
（3）承包人所提供材料和工程设备应符合设计及使用要求以及相关行业的标准和要求。
（4）承包人所提供材料和工程设备应具有相关的国家、省、市认可的产品合格证、质量保证书及产品说明等相关资料。
5.2.1 发包人提供的材料和工程设备见下表：
发包人提供的材料表（参考格式）
序号 | 材料名称 | 材料规格 | 数量 | 交货地点 | 交货方式 | 计划交货日期 | 备注 |
发包人提供的工程设备表（参考格式）
序号 | 工程设备名称 | 型号及规格 | 数量 | 交货地点 | 交货方式 | 计划交货日期 | 备注 |
5.3.3 如果由于承包人的责任造成任何设备缺陷或损坏，或不符合本项目的要求，或由于承包人技术人员在安装、调试、试运行和验收试验过程中出错而导致设备损坏，由承包人免费更换或修复。
6 施工设备和临时设施（1）发包人提供的的施工设备见下表：
发包人提供的施工设备表（参考格式）
序号 | 设备名称 | 型号及规格 | 设备状况 | 数量 | 移交地点 | 计划移交日期 | 备注 |
注：设备状况栏内填写该设备的新旧程度、购进时间、已使用小时数和最近一次的大修时间。
（2）发包人提供的临时设施：。
7 交通运输道路通行权和场外设施的约定：按通用合同条款执行，由承包人负责并承担有关费用。
增加7.2.3 承包人应负责全部施工道路在整个施工期内的养护维修工作并承担相关费用。如改建、扩建而需要相关征地时，由承包人负责并承担相关费用，发包人协助有关征地、赔青事宜。
8 测量放线8.1.1 施工控制网的约定：施工控制网由承包人负责测设，测量基准点、水准点由承包人负责从本项目测量控制基准点引用，相关费用由承包人承担，发包人予以协助。承包人28天内将施测的施工控制网资料提交监理人审批。监理人应在收到报批件后的14天内批复承包人。
9 施工安全、治安保卫和环境保护9.1.4 发包人提供/资料，其余资料由承包人负责收集。
9.2.1 承包人提交合同约定的安全工作内容，安全措施计划时间要求：工程开工前14天前报监理人批准。
9.2.12 下列工程应编制专项施工方案：
（1）基坑支护与降水工程；
（2）土方和石方开挖工程；
（3）模板工程；
（4）起重吊装工程；
（5）脚手架工程；
（6）拆除、爆破工程；
（7）围堰工程；
（8）其他危险性较大的工程。
其中对前款所列工程涉及高边坡、深基坑、地下暗挖工程、高大模板工程的专项施工方案，承包人应组织专家论证和审查。
9.3.1承包人应与当地公安部门协商，在现场建立治安管理机构或联防组织，统一管理施工场地的治安保卫事项，履行合同工程的治安保卫职责。发包人协助。
9.3.3除合同另有约定外，承包人应在工程开工后，编制施工场地治安管理计划，并制定应对突发治安事件的紧急预案。发包人协助。在工程施工过程中，发生暴乱、爆炸等恐怖事件，以及群殴、械斗等群体性突发治安事件的，发包人和承包人应立即向当地政府报告。发包人和承包人应积极协助当地有关部门采取措施平息事态，防止事态扩大，尽量减少财产损失和避免人员伤亡。
9.7.1 本合同文明工地的约定：本招标项目不要求创建文明工地，但承包人应文明施工。
11 开工和竣工（完工）11.4.3 本合同工程界定异常恶劣气候条件的范围为：
（1）日降雨量大于50mm的雨日超过3天。
（2）风速大于20m/s的8级以上台风灾害。
（3）日气温超过38℃的高温大于3天。
（4）日气温低于-20℃的严寒大于3天。
（5）造成工程损坏的冰雹和大雪灾害：日降雪量10mm及以上。
（6）其他异常恶劣气候灾害。
（1）因承包人原因造成工期延误，承包人应支付逾期竣工违约金人民币2000元/日历天。
（2）逾期竣工违约金按日历天计算，时间自预定的完工日期起到工程完工验收中写明的实际完工日期止（扣除已批准的延长工期）。
（3）全部逾期完工违约金的总限额为不超过合同总价的5%。
工期提前的奖金约定：不予奖励。
12 暂停施工（5）承包人承担暂停施工责任的其它情形：__无__。
（3）发包人承担暂停施工责任的其它情形：由于发包人原因引起的暂停施工使关键项目的施工进度计划拖后而造成工期延误时承包人有权要求发包人延长工期，但发包人对因此增加的相关费用不予补偿。
属于下列任何一种情况引起的暂停施工，均为发包人的责任：
(1)由于发包人违约引起的暂停施工；
(2)由于不可抗力的自然或社会因素引起的暂停施工；
(3)专用合同条款中约定的其它由于发包人原因引起的暂停施工。
13 工程质量13.7.4 重要隐蔽单元工程和关键部位单元工程质量评定的约定：按通用合同条款及现行的评定规程和规范执行。
13.7.7 工程合格标准为：应按国家和行业有关规范标准要求进行安全文明施工，且达到《水利水电工程施工质量检验与评定规程》（SL176-2007）及其它相关规范合格标准，该工程项目建成正常运行后，能顺利通过水利等相关部门验收；优良标准为：/。达到优良的奖金为：无。
13.8.4 工程竣工验收时，发包人向竣工验收委员会汇报并提交历次质量缺陷处理的备案资料。
14 试验和检验14.1.5 水工金属结构、启闭机及机电产品进场后的交货检查和验收中，承包人负责_验收合格后保管全部的设备并承担相应的费用。
14.1.6 本工程实行见证取样的试块、试件及有关材料：见证取样的范围和数量应按监理人的指示进行。本工程所有相关的检测费用均由承包人承担。
15 变更单价调整方式：单价不予调整。
修改为：
15.4.2 修改为“其单价应按投标报价时采用的定额、取费标准和中标下浮率计算，送监理人、发包人审核，最终的变更结算价格以财审部门审核结论为准。”
15.4.3修改为“其单价应按投标报价时采用的定额、取费标准和中标下浮率计算，送监理人、发包人审核，最终的变更结算价格以财审部门审核结论为准。”
15.5.2 承包人实现合理化建议的奖励金额为：无。
15.8.1（1）发包人和承包人组织招标的暂估价项目：无；发包人组织招标的暂估价项目：无。
（2）发包人和承包人以招标方式选择暂估价项目供应商或分包人时，双方的权利义务关系：无。
16 价格调整物价波动引起的价格调整方式：因考虑到施工期钢筋、水泥主要材料价格变动较大，钢筋、水泥价格风险承包幅度在±5%以内（含5%），该项材料价差由承包人承担或受益，即不予调差；上涨或下降幅度在±5%以外的，该项材料超出部分价差由发包人承担或受益。价差按月份调整，差价计算按招标控制价编制期采用的材料信息价与施工期材料信息价的差额为依据。其它材料价格不予调整。发生的价差仅计取差价和税金，不计取其他费用 。
16.1.2 采用造价信息调整价格差额
工程造价信息的来源：/。
价格调整的项目和系数：/。
17 计量与支付17.2.1 预付款
本工程无预付款。
17.3.2进度付款申请单
进度付款申请单的份数:一式陆份。
进度付款申请单的内容:按通用合同条款执行。
17.3.3进度付款证书和支付时间
(1) 进度付款额度和付款方式：工程按月支付进度款的比例为：①按当月确定的工程计算结果所含款项的80 %支付进度款；②工程完工并经有关部门进行验收合格后，发包人支付至合同价的90%；③工程完工并经有关部门进行验收合格后，工程结算价以审核单位最终审核结果为准，审核完成和相关资料归档后发包人支付至结算价的97%（处罚款除外），剩余3%作为工程质量保证金。
承包人必须要保证人工工资及设备材料款及时拨付，不得拖欠农民工工资、设备材料款等。
(2)发包人逾期支付进度款时违约金的计算及支付方法：发包人超过约定的支付时间不支付工程进度款，承包人应及时向发包人发出要求付款的通知，发包人收到承包人通知后仍不能按要求付款，可与承包人协商签订延期付款协议，经承包人同意后可延期支付，协议应明确延期支付的时间和从工程计量结果确认后第15天起计算应付款的利息(利率按同期银行贷款利率计)。
17.4.1 每个付款周期扣留的质量保证金为工程进度付款的3%，扣留的质量保证金总额为签约合同价的3%。
17.5.1竣工（完工）付款申请单
（1）承包人应提交完工付款申请单一式陆份。
17.6.1 最终结清申请单
（1）承包人应提交最终结清申请单一式陆份。
承包人应为竣工财务决算编制提供的资料：按国家有关规定。
18 竣工验收（验收）本工程为法人验收。
18.2.2 本工程由发包人主持的分部工程验收为/，其余由监理人主持。
18.3.4 提前投入使用的单位工程包括：/。
18.5.1 本合同工程阶段验收类别包括：（签订合同时商定）。
18.6.2 本合同工程专项验收类别包括：环境保护、水土保持及相关主管部门及规范要求的其它专项验收等。
18.7.3 本工程不需要竣工验收技术鉴定（蓄水安全鉴定）。
18.8.1 需要在施工期运行的单位工程或工程设备为：（签订合同时商定）。
18.9.1 试运行的组织：承包人组织；费用承担：费用由承包人承担，已含在投标报价里不另计。
增加18.12 完工资料
（1）本工程完工验收前，承包人必须按本合同及有关法规、规程的要求完成相应的验收签证、质量评定工作及编制完工资料，发包人将制定印发具体的管理办法，完工资料须经监理人审定，具体内容执行：国家档案局、国家发改委等政府颁布的法规的要求。
（2）完工资料壹式陆份，主要内容包括（但不限于）：
①原始资料部分（原件一式1份，复印件3份，A4纸，电子文件1套）：
a.主要原材料出厂合格证和质量检查、试验资料，材料代用的批准文件；
b.土建与金结制安工程质量检验原始记录；
c.隐蔽工程质量验收原始记录；
d.重大质量事故和工程缺陷处理资料；
e.按有关法规、规程和发包人合理要求的其它资料；
②重要文件部分
a.工程施工总结及大事记（一式陆份）；
b.生产性试验总结及成果分析报告；
c.工程实施进度及措施的记录包括文字记录和图象资料、彩色影像资料（包含施工前过程、施工过程、相关部门检查、调研、施工后期等全过程；一式叁份）；
d.工程完工图及工程量清单；
e.单元工程质量等级评定资料及其验收鉴定证书；
f.重大质量事故及处理记录；
g.重要财务和完工决算资料；
h.设备供应厂商的技术通知单；
i.工程施工报告及完工报告；
j.设备、备品、专用工具和专用器材清单；
k.设计通知单；
l.监理通知单；
m.发包人文件；
n.工程施工《会议纪要》；
o.发包人、承包人往来文件；
p.发包人和监理人认为其它重要的文件。
③完工图纸（一式陆份）
a.各工程完工图（含资料等）；
b.各项隐蔽工程详图（含资料等）；
c.制造厂提供的有关技术文件及图纸；
d.工程测量图。
④需提交验收委员会及汇编成册的完工资料陆套（电子文件1套）。
⑤承包人应根据发包人提供的表格式样制作各类验收单，费用由承包人承担。
⑥承包人应协助发包人完成工程竣工验收、质量安全鉴定等工作，提供相关验收、鉴定资料，相关费用由承包人承担。
19 缺陷责任与保修责任本工程缺陷责任期（工程质量保修期）计算如下：工程通过合同工程完（竣）工验收合格后1年。
20 保险建筑工程一切险和（或）安装工程一切险投保人：_由承包人代发包人购买的建筑工程一切险和安装工程一切险，保险费用由发包人承担；
投保内容：为本合同工程的永久工程、临时工程和设备及已运至施工工地用于永久工程的材料和设备所投的保险；
保险金额、保险费率和保险期限：保险金额不得低于政府有关部门规定的最低赔偿金额。保险费率按投保时国家相关部门规定。承包人应按本合同规定足额投保，其保险费率由发包人和承包人共同与保险机构商定，保险期限为从工程开工日起直至工程完（竣）工验收合格之日止，但第三者责任险期限为缺陷责任期满为止。上述保险费用建筑工程一切险和（或）安装工程一切险的保险费用由发包人承担，第三者责任险已含在投标报价中，由承包人承担。
20.4.2 第三者责任险保险费率：保险费率按投保时国家相关部门规定；
第三者责任险保险金额：承包人应按通用条款规定投保第三者责任险，费用已含在投标报价中，由承包人承担。
修改为：承包人应为其施工设备、进场的材料、工程设备和农民工等办理保险；
保险金额、保险费率和保险期限：保险期限为从工程开工日起直至工程完（竣）工验收合格之日止。保险金额、保险费率按保险有关规定执行，费用已含在投标报价中，由承包人承担。
20.6.1 保险凭证
承包人提交保险凭证的期限：_承包人向发包人提交各项保险生效的证据和保险单副本的期限：开工后15天内。但建筑工程一切险、安装工程一切险、第三者责任险等保险必须在工程开工之前办妥；保险条件：按保险有关规定执行。
20.6.4 保险金不足的补偿
保险金不足以补偿损失时,应承包人和(或)发包人负责补偿的范围与金额:因承包人的工程施工安装失误或责任事故引起的，由承包人或相关责任人承担补偿损失，因不可抗力因素引起的，由发包人、承包人自行承担。
22、违约补充：22.1.2发生承包人不按合同约定履行义务的其他违约情况处理：
A、因承包人原因发生质量事故、工程事故、安全事故或其他事故造成人身和财产损失的，承包方承担全部行政、民事、刑事责任，并承担损害赔偿责任。违反文明施工管理、卫生管理、安全生产管理、扬尘污染防治管理等国家、省、市相关规定，造成后果的由承包人承担一切责任。
B、承包人在收到监理工程师签发的开工令之前，必须保证投标书内承诺配备的主要施工机械设备、质检仪器在监理工程师指定的日期到场，以保证工程顺利开工。若投标书内的施工机械设备不能按时进场，每迟到一日发包人将按1000元/台从工程款中扣除违约金，直到设备进场为止。
C、在工程实施期间，未经监理工程师批准，承包人进场必用的施工机械和质检仪器不得撤离现场，否则发包人将按1000元/台·天从合同价中扣除违约金，直到设备重新进场为止。
D、承包人不得以材料价格、工程预算单价、变更单价、合同价款调整等经济问题未确定或未达到施工单位要求而发生威胁发包人或停工或闹事等不良影响，每发生一次，承包人向发包人支付违约金20000元/次。由此造成工期拖延的承包人应承担违约责任。
E、发包人和监理人有权要求撤换不能胜任本职工作、行为不端或玩忽职守的承包人项目经理、技术负责人和其他主要管理人员，承包人应在3天内撤换，否则承包人应承担责任并向发包人交纳每人每天壹万元人民币的违约金，违约金由发包人直接从工程款中抵扣或从承包人的履约保证金中扣取。
F、承包人不得存在工程挂靠行为(资质借用行为)，若发现工程挂靠的，承包人需按履约担保金承担违约责任，且发包人有权解除合同。
增加：22.1.7发生专用条款22.1.1承包人违约情形后，承包人拒绝整改的，发包人可在提前七日通知后，没收其履约保证金；承包人工期延误的按11.5款处理。
24 争议的解决合同当事人友好协商解决不成、不愿提请争议评审或不接受争议评审组意见的，约定的合同争议解决方式：向工程所在地的人民法院提起诉讼。
","template":"","PROJECT_PRICE_LIST_ATTACHMENTS":[{"id":"60bd6aa30a9e670768cf9543","md5":"9195C7201DA02095D032AD8144BE9E6B","name":"工程项目总价表.xlsx","new_id":"60bd6aa30a9e670768cf9543","size":20426,"url":"/file/getcontent/60bd6aa30a9e670768cf9543.xlsx"}],"TOTAL_PROJECT_PRICE_LIST_SELECT":"工程项目总价表","CONSTRUCTION_PROJECT_AMOUNT_PRICE_LIST_SELECT":"建筑工程工程量清单报价表","TEMPORARY_PROJECT_AMOUNT_PRICE_LIST_SELECT":"临时工程工程量清单报价表","OTHER_PROJECT_AMOUNT_PRICE_LIST_SELECT":"其他项目工程工程量清单报价表","ELECTRICAL_OR_METALLIC_STRUCTURES_PROJECT_AMOUNT_PRICE_LIST_SELECT":"机电或金属结构工程工程量清单报价表","EQUIPMENT_AND_INSTALLATION_PROJECT_AMOUNT_PRICE_LIST_SELECT":"设备及安装工程工程量清单报价表","OTHER_INDUSTRY_PROJECT_AMOUNT_LIST_ATTACHMENTS":[],"SUPPLEMENTARY_LIST_ATTACHMENTS":[],"TOTAL_PROJECT_PRICE_LIST":[{"index":"第一部分","name":"输水管线工程","cost":"","remark":""},{"index":"第二部分","name":"施工专项工程","cost":"","remark":""}],"PRIMARY_LIST":[{"PROJECT_NUMBER":"第一部分","PROJECT_LIST_NAME":"输水管线工程","UNIT":"元","QUANTITIES":"","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"管道工程","UNIT":"m","QUANTITIES":"3374.7","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(1)","PROJECT_LIST_NAME":"拆除C30砼路面（含外运，运距由投标单位自行考虑）","UNIT":"m3","QUANTITIES":"48.68","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(2)","PROJECT_LIST_NAME":"拆除5%水泥稳定碎石层（含外运，运距由投标单位自行考虑）","UNIT":"m3","QUANTITIES":"24.34","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(3)","PROJECT_LIST_NAME":"C30砼路面厚20cm","UNIT":"m2","QUANTITIES":"243.39","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(4)","PROJECT_LIST_NAME":"5%水泥稳定碎石层厚10cm","UNIT":"m2","QUANTITIES":"243.39","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(5)","PROJECT_LIST_NAME":"锯缝机锯缝 (缝深 4cm)","UNIT":"m","QUANTITIES":"580.68","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(6)","PROJECT_LIST_NAME":"土方开挖 用于回填","UNIT":"m3","QUANTITIES":"84.09","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(7)","PROJECT_LIST_NAME":"土方开挖（含外运，运距由投标单位自行考虑）","UNIT":"m3","QUANTITIES":"277.76","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(8)","PROJECT_LIST_NAME":"中粗砂垫层","UNIT":"m3","QUANTITIES":"54.17","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(9)","PROJECT_LIST_NAME":"回填土 利用料","UNIT":"m3实方","QUANTITIES":"73.16","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(10)","PROJECT_LIST_NAME":"回填砂","UNIT":"m3实方","QUANTITIES":"203.2","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(11)","PROJECT_LIST_NAME":"C25砼镇墩","UNIT":"m3","QUANTITIES":"38.4","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(12)","PROJECT_LIST_NAME":"普通标准钢模板","UNIT":"m2","QUANTITIES":"475.05","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(13)","PROJECT_LIST_NAME":"管卡 圆钢筋12","UNIT":"个","QUANTITIES":"479","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(14)","PROJECT_LIST_NAME":"角钢支架","UNIT":"个","QUANTITIES":"191","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(15)","PROJECT_LIST_NAME":"DN315 PE100管 壁厚18.7mm 1.0Mpa","UNIT":"m","QUANTITIES":"3374.7","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(16)","PROJECT_LIST_NAME":"PE管道膜","UNIT":"m2","QUANTITIES":"2856.13","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(17)","PROJECT_LIST_NAME":"铸铁检修阀门DN300","UNIT":"个","QUANTITIES":"2","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(18)","PROJECT_LIST_NAME":"铸铁排泥阀DN300","UNIT":"个","QUANTITIES":"3","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(19)","PROJECT_LIST_NAME":"铸铁排气阀DN300","UNIT":"个","QUANTITIES":"4","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(20)","PROJECT_LIST_NAME":"PE三通DN300","UNIT":"个","QUANTITIES":"2","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(21)","PROJECT_LIST_NAME":"水表DN300","UNIT":"套","QUANTITIES":"1","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(22)","PROJECT_LIST_NAME":"压力表DN300","UNIT":"套","QUANTITIES":"1","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"阀门井","UNIT":"座","QUANTITIES":"8","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(1)","PROJECT_LIST_NAME":"C15砼垫层","UNIT":"m3","QUANTITIES":"0.99","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(2)","PROJECT_LIST_NAME":"C25砼底板","UNIT":"m3","QUANTITIES":"0.7","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(3)","PROJECT_LIST_NAME":"M10砂浆砖砌体","UNIT":"m3","QUANTITIES":"2.4","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(4)","PROJECT_LIST_NAME":"M10砂浆抹面 平均厚度2cm","UNIT":"m2","QUANTITIES":"42.16","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(5)","PROJECT_LIST_NAME":"回填砂碎石","UNIT":"m3","QUANTITIES":"0.43","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(6)","PROJECT_LIST_NAME":"M10砂浆砖砌支墩","UNIT":"m3","QUANTITIES":"0.13","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(7)","PROJECT_LIST_NAME":"铸铁井盖0.9*0.62m","UNIT":"套","QUANTITIES":"8","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"第二部分","PROJECT_LIST_NAME":"施工专项工程","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":"38899"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"安全生产措施费","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":"31119"},{"PROJECT_NUMBER":"(1)","PROJECT_LIST_NAME":"安全生产措施费","UNIT":"项","QUANTITIES":"1","UNIVALENT":"31119","TOTAL":"31119"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"施工现场标准化建设工程","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":"7780"},{"PROJECT_NUMBER":"(1)","PROJECT_LIST_NAME":"施工现场标准化建设工程","UNIT":"项","QUANTITIES":"1","UNIVALENT":"7780","TOTAL":"7780"}],"CONSTRUCTION_PROJECT_AMOUNT_PRICE_LIST":[{"index":"第一部分","name":"输水管线工程","unit":"元","project_amount":"","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"管道工程","unit":"m","project_amount":"3374.7","unit_price":"","combined_price":"","remark":""},{"index":"(1)","name":"拆除C30砼路面（含外运，运距由投标单位自行考虑）","unit":"m3","project_amount":"48.68","unit_price":"","combined_price":"","remark":""},{"index":"(2)","name":"拆除5%水泥稳定碎石层（含外运，运距由投标单位自行考虑）","unit":"m3","project_amount":"24.34","unit_price":"","combined_price":"","remark":""},{"index":"(3)","name":"C30砼路面厚20cm","unit":"m2","project_amount":"243.39","unit_price":"","combined_price":"","remark":""},{"index":"(4)","name":"5%水泥稳定碎石层厚10cm","unit":"m2","project_amount":"243.39","unit_price":"","combined_price":"","remark":""},{"index":"(5)","name":"锯缝机锯缝 (缝深 4cm)","unit":"m","project_amount":"580.68","unit_price":"","combined_price":"","remark":""},{"index":"(6)","name":"土方开挖 用于回填","unit":"m3","project_amount":"84.09","unit_price":"","combined_price":"","remark":""},{"index":"(7)","name":"土方开挖（含外运，运距由投标单位自行考虑）","unit":"m3","project_amount":"277.76","unit_price":"","combined_price":"","remark":""},{"index":"(8)","name":"中粗砂垫层","unit":"m3","project_amount":"54.17","unit_price":"","combined_price":"","remark":""},{"index":"(9)","name":"回填土 利用料","unit":"m3实方","project_amount":"73.16","unit_price":"","combined_price":"","remark":""},{"index":"(10)","name":"回填砂","unit":"m3实方","project_amount":"203.2","unit_price":"","combined_price":"","remark":""},{"index":"(11)","name":"C25砼镇墩","unit":"m3","project_amount":"38.4","unit_price":"","combined_price":"","remark":""},{"index":"(12)","name":"普通标准钢模板","unit":"m2","project_amount":"475.05","unit_price":"","combined_price":"","remark":""},{"index":"(13)","name":"管卡 圆钢筋12","unit":"个","project_amount":"479","unit_price":"","combined_price":"","remark":""},{"index":"(14)","name":"角钢支架","unit":"个","project_amount":"191","unit_price":"","combined_price":"","remark":""},{"index":"(15)","name":"DN315 PE100管 壁厚18.7mm 1.0Mpa","unit":"m","project_amount":"3374.7","unit_price":"","combined_price":"","remark":""},{"index":"(16)","name":"PE管道膜","unit":"m2","project_amount":"2856.13","unit_price":"","combined_price":"","remark":""},{"index":"(17)","name":"铸铁检修阀门DN300","unit":"个","project_amount":"2","unit_price":"","combined_price":"","remark":""},{"index":"(18)","name":"铸铁排泥阀DN300","unit":"个","project_amount":"3","unit_price":"","combined_price":"","remark":""},{"index":"(19)","name":"铸铁排气阀DN300","unit":"个","project_amount":"4","unit_price":"","combined_price":"","remark":""},{"index":"(20)","name":"PE三通DN300","unit":"个","project_amount":"2","unit_price":"","combined_price":"","remark":""},{"index":"(21)","name":"水表DN300","unit":"套","project_amount":"1","unit_price":"","combined_price":"","remark":""},{"index":"(22)","name":"压力表DN300","unit":"套","project_amount":"1","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"阀门井","unit":"座","project_amount":"8","unit_price":"","combined_price":"","remark":""},{"index":"(1)","name":"C15砼垫层","unit":"m3","project_amount":"0.99","unit_price":"","combined_price":"","remark":""},{"index":"(2)","name":"C25砼底板","unit":"m3","project_amount":"0.7","unit_price":"","combined_price":"","remark":""},{"index":"(3)","name":"M10砂浆砖砌体","unit":"m3","project_amount":"2.4","unit_price":"","combined_price":"","remark":""},{"index":"(4)","name":"M10砂浆抹面 平均厚度2cm","unit":"m2","project_amount":"42.16","unit_price":"","combined_price":"","remark":""},{"index":"(5)","name":"回填砂碎石","unit":"m3","project_amount":"0.43","unit_price":"","combined_price":"","remark":""},{"index":"(6)","name":"M10砂浆砖砌支墩","unit":"m3","project_amount":"0.13","unit_price":"","combined_price":"","remark":""},{"index":"(7)","name":"铸铁井盖0.9*0.62m","unit":"套","project_amount":"8","unit_price":"","combined_price":"","remark":""}],"TEMPORARY_PROJECT_AMOUNT_PRICE_LIST":[{"index":"第二部分","name":"施工专项工程","unit":"","project_amount":"","unit_price":"","combined_price":"38899","remark":""},{"index":"1","name":"安全生产措施费","unit":"","project_amount":"","unit_price":"","combined_price":"31119","remark":""},{"index":"(1)","name":"安全生产措施费","unit":"项","project_amount":"1","unit_price":"31119","combined_price":"31119","remark":""},{"index":"2","name":"施工现场标准化建设工程","unit":"","project_amount":"","unit_price":"","combined_price":"7780","remark":""},{"index":"(1)","name":"施工现场标准化建设工程","unit":"项","project_amount":"1","unit_price":"7780","combined_price":"7780","remark":""}],"OTHER_PROJECT_AMOUNT_PRICE_LIST":[],"ELECTRICAL_OR_METALLIC_STRUCTURES_PROJECT_AMOUNT_PRICE_LIST":[],"EQUIPMENT_AND_INSTALLATION_PROJECT_AMOUNT_PRICE_LIST":[],"GRAPH_PAPER_ATTACHMENTS":[{"id":"60b9fecba43b6718f8437a8b","md5":"4513861371279B6FDC321C848AC42C47","name":"马甲至河市应急供水 图纸.pdf","new_id":"60b9fecba43b6718f8437a8b","size":5522606,"url":"/file/getcontent/60b9fecba43b6718f8437a8b.pdf"},{"id":"60bd867ad8486209e03e49e5","md5":"7A9F5D08A37E213B2BBD2E9EE3406472","name":"预算编制说明.doc","new_id":"60bd867ad8486209e03e49e5","size":24064,"url":"/file/getcontent/60bd867ad8486209e03e49e5.doc"},{"id":"60bd867a0a9e670768cfbf59","md5":"211823F906CE569FB8C0D4591F3C194B","name":"工程预算评审报告.doc","new_id":"60bd867a0a9e670768cfbf59","size":49283,"url":"/file/getcontent/60bd867a0a9e670768cfbf59.doc"},{"id":"60bd867a0a9e670768cfbf5b","md5":"7C1553F9AF8CF7FC69C4C35FF1785551","name":"清单编制说明.doc","new_id":"60bd867a0a9e670768cfbf5b","size":24064,"url":"/file/getcontent/60bd867a0a9e670768cfbf5b.doc"}],"TECHNICAL_REQUIREMENTS_ATTACHMENTS":[],"IS_ABLE_USE_DZBH":false,"PM_TABLE_DATA":[{"POST":"技术负责人","POST_NUMBER":"1","PROFESSIONAL_TITLE":"高级及以上职称","PROFESSIONAL":"水利水电工程相关专业"},{"POST":"施工员","POST_NUMBER":"1","PROFESSIONAL_TITLE":"/","PROFESSIONAL":"具备水行政主管部门或行政主管部门授权的单位（需提供授权的依据文件）行政主管部门核发的合格有效的岗位证书。"},{"POST":"材料员","POST_NUMBER":"1","PROFESSIONAL_TITLE":"/","PROFESSIONAL":"具备水行政主管部门或行政主管部门授权的单位（需提供授权的依据文件）行政主管部门核发的合格有效的岗位证书。"},{"POST":"造价员","POST_NUMBER":"1","PROFESSIONAL_TITLE":"/","PROFESSIONAL":"具有合格有效的造价工程师执业资格证书"},{"POST":"质检员","POST_NUMBER":"1","PROFESSIONAL_TITLE":"/","PROFESSIONAL":"具备水行政主管部门或行政主管部门授权的单位（需提供授权的依据文件）行政主管部门核发的合格有效的岗位证书。"},{"POST":"安全员","POST_NUMBER":"1","PROFESSIONAL_TITLE":"/","PROFESSIONAL":"具备水行政主管部门或行政主管部门授权的单位（需提供授权的依据文件）行政主管部门核发的合格有效的岗位证书。"}],"EARNEST_BLOCK_METHOD":["现金","支票","银行保函","电子保函","年度保证金"],"updateContent_cost":{"TENDER_QUANTITIES":{"PROJECT_PRICE_LIST_ATTACHMENTS":[{"id":"60bd6aa30a9e670768cf9543","md5":"9195C7201DA02095D032AD8144BE9E6B","name":"工程项目总价表.xlsx","new_id":"60bd6aa30a9e670768cf9543","size":20426,"url":"/file/getcontent/60bd6aa30a9e670768cf9543.xlsx"}],"TOTAL_PROJECT_PRICE_LIST_SELECT":"工程项目总价表","CONSTRUCTION_PROJECT_AMOUNT_PRICE_LIST_SELECT":"建筑工程工程量清单报价表","TEMPORARY_PROJECT_AMOUNT_PRICE_LIST_SELECT":"临时工程工程量清单报价表","OTHER_PROJECT_AMOUNT_PRICE_LIST_SELECT":"其他项目工程工程量清单报价表","ELECTRICAL_OR_METALLIC_STRUCTURES_PROJECT_AMOUNT_PRICE_LIST_SELECT":"机电或金属结构工程工程量清单报价表","EQUIPMENT_AND_INSTALLATION_PROJECT_AMOUNT_PRICE_LIST_SELECT":"设备及安装工程工程量清单报价表","SUPPLEMENTARY_LIST_ATTACHMENTS":[],"TOTAL_PROJECT_PRICE_LIST":[{"index":"第一部分","name":"输水管线工程","cost":"","remark":""},{"index":"第二部分","name":"施工专项工程","cost":"","remark":""}],"PRIMARY_LIST":[{"PROJECT_NUMBER":"第一部分","PROJECT_LIST_NAME":"输水管线工程","UNIT":"元","QUANTITIES":"","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"管道工程","UNIT":"m","QUANTITIES":"3374.7","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(1)","PROJECT_LIST_NAME":"拆除C30砼路面（含外运，运距由投标单位自行考虑）","UNIT":"m3","QUANTITIES":"48.68","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(2)","PROJECT_LIST_NAME":"拆除5%水泥稳定碎石层（含外运，运距由投标单位自行考虑）","UNIT":"m3","QUANTITIES":"24.34","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(3)","PROJECT_LIST_NAME":"C30砼路面厚20cm","UNIT":"m2","QUANTITIES":"243.39","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(4)","PROJECT_LIST_NAME":"5%水泥稳定碎石层厚10cm","UNIT":"m2","QUANTITIES":"243.39","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(5)","PROJECT_LIST_NAME":"锯缝机锯缝 (缝深 4cm)","UNIT":"m","QUANTITIES":"580.68","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(6)","PROJECT_LIST_NAME":"土方开挖 用于回填","UNIT":"m3","QUANTITIES":"84.09","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(7)","PROJECT_LIST_NAME":"土方开挖（含外运，运距由投标单位自行考虑）","UNIT":"m3","QUANTITIES":"277.76","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(8)","PROJECT_LIST_NAME":"中粗砂垫层","UNIT":"m3","QUANTITIES":"54.17","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(9)","PROJECT_LIST_NAME":"回填土 利用料","UNIT":"m3实方","QUANTITIES":"73.16","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(10)","PROJECT_LIST_NAME":"回填砂","UNIT":"m3实方","QUANTITIES":"203.2","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(11)","PROJECT_LIST_NAME":"C25砼镇墩","UNIT":"m3","QUANTITIES":"38.4","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(12)","PROJECT_LIST_NAME":"普通标准钢模板","UNIT":"m2","QUANTITIES":"475.05","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(13)","PROJECT_LIST_NAME":"管卡 圆钢筋12","UNIT":"个","QUANTITIES":"479","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(14)","PROJECT_LIST_NAME":"角钢支架","UNIT":"个","QUANTITIES":"191","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(15)","PROJECT_LIST_NAME":"DN315 PE100管 壁厚18.7mm 1.0Mpa","UNIT":"m","QUANTITIES":"3374.7","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(16)","PROJECT_LIST_NAME":"PE管道膜","UNIT":"m2","QUANTITIES":"2856.13","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(17)","PROJECT_LIST_NAME":"铸铁检修阀门DN300","UNIT":"个","QUANTITIES":"2","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(18)","PROJECT_LIST_NAME":"铸铁排泥阀DN300","UNIT":"个","QUANTITIES":"3","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(19)","PROJECT_LIST_NAME":"铸铁排气阀DN300","UNIT":"个","QUANTITIES":"4","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(20)","PROJECT_LIST_NAME":"PE三通DN300","UNIT":"个","QUANTITIES":"2","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(21)","PROJECT_LIST_NAME":"水表DN300","UNIT":"套","QUANTITIES":"1","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(22)","PROJECT_LIST_NAME":"压力表DN300","UNIT":"套","QUANTITIES":"1","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"阀门井","UNIT":"座","QUANTITIES":"8","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(1)","PROJECT_LIST_NAME":"C15砼垫层","UNIT":"m3","QUANTITIES":"0.99","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(2)","PROJECT_LIST_NAME":"C25砼底板","UNIT":"m3","QUANTITIES":"0.7","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(3)","PROJECT_LIST_NAME":"M10砂浆砖砌体","UNIT":"m3","QUANTITIES":"2.4","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(4)","PROJECT_LIST_NAME":"M10砂浆抹面 平均厚度2cm","UNIT":"m2","QUANTITIES":"42.16","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(5)","PROJECT_LIST_NAME":"回填砂碎石","UNIT":"m3","QUANTITIES":"0.43","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(6)","PROJECT_LIST_NAME":"M10砂浆砖砌支墩","UNIT":"m3","QUANTITIES":"0.13","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"(7)","PROJECT_LIST_NAME":"铸铁井盖0.9*0.62m","UNIT":"套","QUANTITIES":"8","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"第二部分","PROJECT_LIST_NAME":"施工专项工程","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":"38899"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"安全生产措施费","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":"31119"},{"PROJECT_NUMBER":"(1)","PROJECT_LIST_NAME":"安全生产措施费","UNIT":"项","QUANTITIES":"1","UNIVALENT":"31119","TOTAL":"31119"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"施工现场标准化建设工程","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":"7780"},{"PROJECT_NUMBER":"(1)","PROJECT_LIST_NAME":"施工现场标准化建设工程","UNIT":"项","QUANTITIES":"1","UNIVALENT":"7780","TOTAL":"7780"}],"CONSTRUCTION_PROJECT_AMOUNT_PRICE_LIST":[{"index":"第一部分","name":"输水管线工程","unit":"元","project_amount":"","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"管道工程","unit":"m","project_amount":"3374.7","unit_price":"","combined_price":"","remark":""},{"index":"(1)","name":"拆除C30砼路面（含外运，运距由投标单位自行考虑）","unit":"m3","project_amount":"48.68","unit_price":"","combined_price":"","remark":""},{"index":"(2)","name":"拆除5%水泥稳定碎石层（含外运，运距由投标单位自行考虑）","unit":"m3","project_amount":"24.34","unit_price":"","combined_price":"","remark":""},{"index":"(3)","name":"C30砼路面厚20cm","unit":"m2","project_amount":"243.39","unit_price":"","combined_price":"","remark":""},{"index":"(4)","name":"5%水泥稳定碎石层厚10cm","unit":"m2","project_amount":"243.39","unit_price":"","combined_price":"","remark":""},{"index":"(5)","name":"锯缝机锯缝 (缝深 4cm)","unit":"m","project_amount":"580.68","unit_price":"","combined_price":"","remark":""},{"index":"(6)","name":"土方开挖 用于回填","unit":"m3","project_amount":"84.09","unit_price":"","combined_price":"","remark":""},{"index":"(7)","name":"土方开挖（含外运，运距由投标单位自行考虑）","unit":"m3","project_amount":"277.76","unit_price":"","combined_price":"","remark":""},{"index":"(8)","name":"中粗砂垫层","unit":"m3","project_amount":"54.17","unit_price":"","combined_price":"","remark":""},{"index":"(9)","name":"回填土 利用料","unit":"m3实方","project_amount":"73.16","unit_price":"","combined_price":"","remark":""},{"index":"(10)","name":"回填砂","unit":"m3实方","project_amount":"203.2","unit_price":"","combined_price":"","remark":""},{"index":"(11)","name":"C25砼镇墩","unit":"m3","project_amount":"38.4","unit_price":"","combined_price":"","remark":""},{"index":"(12)","name":"普通标准钢模板","unit":"m2","project_amount":"475.05","unit_price":"","combined_price":"","remark":""},{"index":"(13)","name":"管卡 圆钢筋12","unit":"个","project_amount":"479","unit_price":"","combined_price":"","remark":""},{"index":"(14)","name":"角钢支架","unit":"个","project_amount":"191","unit_price":"","combined_price":"","remark":""},{"index":"(15)","name":"DN315 PE100管 壁厚18.7mm 1.0Mpa","unit":"m","project_amount":"3374.7","unit_price":"","combined_price":"","remark":""},{"index":"(16)","name":"PE管道膜","unit":"m2","project_amount":"2856.13","unit_price":"","combined_price":"","remark":""},{"index":"(17)","name":"铸铁检修阀门DN300","unit":"个","project_amount":"2","unit_price":"","combined_price":"","remark":""},{"index":"(18)","name":"铸铁排泥阀DN300","unit":"个","project_amount":"3","unit_price":"","combined_price":"","remark":""},{"index":"(19)","name":"铸铁排气阀DN300","unit":"个","project_amount":"4","unit_price":"","combined_price":"","remark":""},{"index":"(20)","name":"PE三通DN300","unit":"个","project_amount":"2","unit_price":"","combined_price":"","remark":""},{"index":"(21)","name":"水表DN300","unit":"套","project_amount":"1","unit_price":"","combined_price":"","remark":""},{"index":"(22)","name":"压力表DN300","unit":"套","project_amount":"1","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"阀门井","unit":"座","project_amount":"8","unit_price":"","combined_price":"","remark":""},{"index":"(1)","name":"C15砼垫层","unit":"m3","project_amount":"0.99","unit_price":"","combined_price":"","remark":""},{"index":"(2)","name":"C25砼底板","unit":"m3","project_amount":"0.7","unit_price":"","combined_price":"","remark":""},{"index":"(3)","name":"M10砂浆砖砌体","unit":"m3","project_amount":"2.4","unit_price":"","combined_price":"","remark":""},{"index":"(4)","name":"M10砂浆抹面 平均厚度2cm","unit":"m2","project_amount":"42.16","unit_price":"","combined_price":"","remark":""},{"index":"(5)","name":"回填砂碎石","unit":"m3","project_amount":"0.43","unit_price":"","combined_price":"","remark":""},{"index":"(6)","name":"M10砂浆砖砌支墩","unit":"m3","project_amount":"0.13","unit_price":"","combined_price":"","remark":""},{"index":"(7)","name":"铸铁井盖0.9*0.62m","unit":"套","project_amount":"8","unit_price":"","combined_price":"","remark":""}],"TEMPORARY_PROJECT_AMOUNT_PRICE_LIST":[{"index":"第二部分","name":"施工专项工程","unit":"","project_amount":"","unit_price":"","combined_price":"38899","remark":""},{"index":"1","name":"安全生产措施费","unit":"","project_amount":"","unit_price":"","combined_price":"31119","remark":""},{"index":"(1)","name":"安全生产措施费","unit":"项","project_amount":"1","unit_price":"31119","combined_price":"31119","remark":""},{"index":"2","name":"施工现场标准化建设工程","unit":"","project_amount":"","unit_price":"","combined_price":"7780","remark":""},{"index":"(1)","name":"施工现场标准化建设工程","unit":"项","project_amount":"1","unit_price":"7780","combined_price":"7780","remark":""}],"OTHER_PROJECT_AMOUNT_PRICE_LIST":[],"ELECTRICAL_OR_METALLIC_STRUCTURES_PROJECT_AMOUNT_PRICE_LIST":[],"EQUIPMENT_AND_INSTALLATION_PROJECT_AMOUNT_PRICE_LIST":[]}},"updateContent_price":{"CONTROL_PRICE":"1594825","COMPETITION_PRICE":"1555926","NON_COMPETITION_PRICE":"38899"},"UUM_ENTP_BASE_INFO":{"tbwjAttachments":{"Socattachments":[{"id":"5eeb28a95eba44dca45d32f7","md5":"FBCAC7D447E4BE2DC7DEDCADE5D47179","name":"福建省闽水项目管理有限公司（营业执照副本）.jpg","new_id":"5eeb28a95eba44dca45d32f7","size":449529,"url":"/file/getcontent/5eeb28a95eba44dca45d32f7.jpg"}],"Orgattachments":[],"Busattachments":[],"Staattachments":[],"Locattachments":[],"Govattachments":[]},"BasicUnitName":"福建省闽水项目管理有限公司","Legal":"林振强","LeTypeLabel":"法人","LeType":"1","LeRoleLabel":"招标代理机构","LeRole":"2","LeOrTypeLabel":"其他","LeOrType":"9","businessStatus":"正常","LeInCode":"无","LeAddress":"福州市东大路229号13层","Country":"中国","Province":"福建省","City":"福州市","Administration":"鼓楼区","CompanyWeb":"无","Email":"fjmsxmgl@163.com","Contacts":"王昕","ConPhone":"15306999167","ConAdderss":"福州市东大路229号13层","PostalCode":"350001","Fax":"0591-87560944","leCode":"91350000158141030F","ENTP_REGION_CODE":"350100","ENTP_PROPERTY":"9","Registered":"工程项目管理；工程造价咨询服务；工程材料咨询服务；工程建设项目招标代理；政府采购招标代理；矿产品、建材、机械设备及化工产品（不含危险化学品及易制毒化学品）批发。","LeoPhone":"13906912316","leoName":"林振强","LeoIDTypeLabel":"身份证","LeoIDType":"身份证","LeoIDNumber":"350102196309210352","BasicBank":"福建兴业银行福州晋安支行","BasicBaNumber":"无","CreditRatingLabel":"AA+","CreditRating":"AA+","BasicNumber":"117120100179796395","BasicName":"福建省闽水项目管理有限公司","RegisteredCapital":"1000","CurrencyLabel":"人民币","Currency":"156","ReUnitLabel":"万元","ReUnit":"1","Decisionss":true,"SocietyNumber":"91350000158141030F","SocietyData":"|
招标
|
- 关注我们可获得更多采购需求 |
关注 |
最近搜索
无
热门搜索
无
