第二节 专用合同条款
【注：专用合同条款是补充、细化通用合同条款款号相同或当需要时增加新的条款，除通用合同条款明确规定可以作出不同约定外，专用合同条款补充和细化的内容不得与通用合同条款相抵触，不得违反法律、行政法规的强制性规定，以及平等、自愿、公平和诚实信用原则。】
本招标项目专用合同条款如下：
1 一般约定
1.1词语定义
1.1.2 合同当事人和人员
1.1.2.2 发包人：_____________________________
1.1.2.3 承包人：_____________________________
1.1.2.5 分包人：_____________________________
1.1.2.6 监理人：_____________________________
1.1.4 日期
1.1.4.3 工期：____210_____日历天（其中各关键节点的工期：_____/_____）
1.1.4.5缺陷责任期（工程质量保修期）：____1年_________________________
1.4 合同文件的优先顺序
进入合同文件的各项文件及其优先顺序是_____________________________。
1.7 联络
1.7.2来往函件均应按技术标准和要求（合同技术条款）约定的期限送达__________________。
2 发包人义务
2.3 提供施工场地
2.3.2 发包人提供的施工用地范围为：______________________。
2.3.3 承包人自行勘察的施工场地范围为：_____________________。
2.8 其它义务
(根据发包人的合同管理要求补充)
（1）……
（2）……
3 监理人
3.1 监理人的职责和权力
3.1.1监理人须根据发包人事先批准的权力范围行使权力，发包人批准的权力范围：（填写监理人须经发包人批准才能行使的权力，以下示例供参考）
（1）按第4.3条约定，批准工程的分包。
（2）按第11.3条约定，确定延长完工期限。
（3）按第15.6条约定，批准暂列金额的使用。
……
4 承包人
4.1 承包人的一般义务
4.1.10其他义务
1、一、清淤作业安全检查措施
（1）清淤工程项目组将建立施工期每周进行一次安全检查的制度，由项目部组织实施。检查内容为：
施工现场安全情况，有无“三违”现象；特殊施工部位安全监督情况；临时用电安全情况；机械设备、消防器材安全性能完好情况；机械、油料、配件现场保卫情况；
信号装置完好情况；住宿区安全、卫生情况，对检查出的安全隐患，由检查负责人负责组织研究，制定整改措施，通知人员进行整改。安全科 负责对整改到位情况进行督查。
二、清淤施工人员安全防护措施
（1）清淤作业人员必须穿戴救生衣，其穿戴方法要符合要求。
（2）施工人员工作前不许饮酒，酒后严禁操作。
（3）挖泥船及辅助船等经常检查救生、堵漏、系缆等设备的技术性能，确保能满足应变需要。
（4）经常检查本船声号、灯号、旗号、通讯设备是否齐全、良好。
（5）各种机械要挂安全技术操作规程牌。
（6）各种机械、设备不准带病作业。
三、船泊施工安全措施
（1）施工单位所使用的船舶，必须使用经过海事部门船检合格的船舶，须在签订合同之日起15日内提供合法船舶进场作业。新购船舶的，须在签订合同之日起15日内，提供与造船厂的购船合同，并附上支付购船的定金凭证，在60日内提供合法船舶进场作业，如未在规定时间内提供，招标人有权取消其中标资格，并没收履约保证金。船泊施工中，作业船配足实用合理的救生器材及消防设备。施工船只往来及时互相通报 ，作好可能的碰撞警报工作。
（2）在船泊作业区段设置安全标志和信号装置。
①在施工区内设置道路、报警、危险、控制、安全、指示等信号。
②弃土区附近设立安全警告牌，防止来往行人及车辆发生意外。
③雨季施工做好防滑工作。退水附近竖立提示警告牌。
（3）在施工区域划定生活船、辅助船泊的停靠及修理位置，指派专人进行安全保卫工作。
（4）清淤施工过程中，要防止浮管脱节、拔爆，遇有情况立即停工，避免泥浆外溢，影响施工 质量，危害航道安全。
2、本项目质量监督部门为市水利局监督，对内外业的时效性、规范性严格要求，严禁施工单位对河道清淤所产生的富余混合料私自进行转运，如有发现，处以所违法所得的10倍罚金。
3、河道清淤所产生的富余混合料起岸转运点、临时堆放点和转运至公路的便道由施工单位负责建设，并且施工区域内只允许设置一个，转运点、临时堆放点、一条便道必须在签订合同之日起10日内建设完成，转运点、临时堆放点的场地必须符合相关规定，施工便道的宽度必须能让前四后八车辆顺利通行，到公路的运输道路能够保证通畅使用。施工过程中，需要改变或增加施工便道，须提前向招标人报批，由此产生的费用由施工单位承担，如未在规定时间内提供转运点、临时堆放点和运输便道，招标人有权取消其中标资格，并没收履约保证金。
4、在签订施工合同时，应随附：经招标单位、施工单位、业主单位盖章（加盖骑缝章）的中标工程量清单和单价，合同履约保证金收据复印件、农民工欠薪保证金收据复印件、工程一切险、工地意外保险收据复印件、工伤保险收据复印件。合同要上交水利局一式叁份，供备案和结算审计用。同时签定廉政合同、安全生产合同、与施工合同一同装订成册。
5.承包人应严格遵守国家有关解决拖欠工程款和民工工资的法律、法规，及时支付工程中的材料、设备货款及民工工资等费用。承包人不得以任何借口拖欠材料、设备货款及民工工资等费用，如果出现此种现象，发包人有权代为支付其拖欠的材料、设备货款及民工工资，并从应付给承包人的工程款中扣除相应款项。对恶意拖欠和拒不按计划支付的，作为不良记录纳入水利建设市场信用信息管理系统。
4.3 分包
4.3.2 本招标项目不允许分包
4.11 不利物质条件
4.11.1 不利物质条件的范围：/ 。
5 材料和工程设备
5.2发包人提供的材料和工程设备
5.2.1 发包人提供的材料和工程设备见下表：
发包人提供的材料表（参考格式）
序号 | 材料名称 | 材料规格 | 数量 | 交货地点 | 交货方式 | 计划交货日期 | 备注 |
| | | | | | | |
| | | | | | | |
| | | | | | | |
发包人提供的工程设备表（参考格式）
序号 | 工程设备名称 | 型号及规格 | 数量 | 交货地点 | 交货方式 | 计划交货日期 | 备注 |
| | | | | | | |
| | | | | | | |
| | | | | | | |
6 施工设备和临时设施
6.2 发包人提供的施工设备和临时设施
（1）发包人提供的的施工设备见下表：
发包人提供的施工设备表（参考格式）
序号 | 设备名称 | 型号及规格 | 设备状况 | 数量 | 移交地点 | 计划移交日期 | 备注 |
| | | | | | | |
| | | | | | | |
| | | | | | | |
注：设备状况栏内填写该设备的新旧程度、购进时间、已使用小时数和最近一次的大修时间。
（2）发包人提供的临时设施：本招标项目发包人不提供施工设备和临时设施。
7 交通运输
7.1道路通行权和场外设施
道路通行权和场外设施的约定： 按通用合同条款执行，由承包人负责 。
8 测量放线
8.1 施工控制网
8.1.1 施工控制网的约定： 按通用合同条款执行，由承包人负责。
9 施工安全、治安保卫和环境保护
9.1 发包人的施工安全责任
9.1.4 发包人提供 （另行约定）资料，其余资料由承包人负责收集。
9.2 承包人的施工安全责任
9.2.12 下列工程应编制专项施工方案：_______/____。其中____/_____应组织专家论证和审查。
9.7 文明工地
9.7.1本合同文明工地的约定：_____/________________。
11 开工和竣工（完工）
11.4 异常恶劣的气候条件
11.4.3 本合同工程界定异常恶劣气候条件的范围为：
（ 1 ）日降雨量大于 50 mm 。
（ 2 ） 8 级以上台风灾害 。
（ 3 ） 烈度 7 度以上地震 。
（ 4 ） 其他异常恶劣气候灾害 。
11.5 承包人工期延误
（1）逾期竣工违约金表（参考格式）
（ 1 ）因承包人原因造成工期延误，承包人应支付逾期完工违约金 5000 元 / 天。
（ 2 ）逾期完工违约金按天计算，时间自预定的完工日期起到工程完工证书中写明的实际完工日期止（扣除已批准的延长工期）。
（ 3 ）全部逾期完工违约金的总限额为 （不超过合同总价的 5 % ） 。
11.6 工期提前
工期提前的奖金约定：_不奖励______。
12 暂停施工
12.1 承包人暂停施工的责任
（5）承包人承担暂停施工责任的其它情形：______/_______________。
12.2 发包人暂停施工的责任
（3）发包人承担暂停施工责任的其它情形：____/__________。
13 工程质量
13.7 质量评定
13.7.4 重要隐蔽单元工程和关键部位单元工程质量评定的约定： 按通用合同条款执行。
13.7.7 工程合格标准为：《水利水电工程施工质量检验与评定规程》 SL176— 2007、《水利水电建设工程验收规程》SL1223—2008标准及现行工程质量规范合格标准要求；优良标准为：/。达到优良的奖金为：/。
13.8 质量事故处理
13.8.4 工程竣工验收时，________________向竣工验收委员会汇报并提交历次质量缺陷处理的备案资料。
14试验和检验
14.1 材料、工程设备和工程的试验和检验
14.1.5 水工金属结构、启闭机及机电产品进场后的交货检查和验收中，承包人负责 按通用合同条款执行。
14.1.6 本工程实行见证取样的试块、试件及有关材料：主体结构及防渗体的混凝土试块、有防渗功能的土方填筑、用于承重结构的砌筑砂浆试块、钢筋、水泥等重要原材料。
15 变更
15.1 变更的范围和内容
（6）增加或减少合同中关键项目的工程量超过其工程总量的_______%，关键项目：______，单价调整方式：_____________________。
15.5 承包人的合理化建议
15.5.2承包人实现合理化建议的奖励金额为：______/______。
15.8 暂估价
15.8.1（1）发包人和承包人组织招标的暂估价项目：签约后填入；发包人组织招标的暂估价项目：__（ 签约后填入）_。
（2）发包人和承包人以招标方式选择暂估价项目供应商或分包人时，双方的权利义务关系：/_。
16 价格调整
16.1 物价波动引起的价格调整
物价波动引起的价格调整 在合同执行期间（包括工期拖延期间），由于人工、材料和设备价格的上涨而引起工程施工成本增加的风险由承包人自行承担，合同价格不会因此而调整
17 计量与支付
17.2 预付款
本招标项目无预付款。
17.3工程进度款
工程按完成工程量支付进度款，支付比例为当期完成且经业主和监理单位确认的合同内清单工程量的50%，支付至合同造价的30%，完成工程量的70%，支付至合同造价的50%，合同外工程量暂不支付。工程完工验收合格后进行结算，待结算审核结束后支付至审定造价的97%；余款3%作为质量保证金以完工验收时间为准12个月工程无质量问题后无息退还。
17.4质量保证金
17.4.1扣留的质量保证金总额为签约合同价的___3____%。
17.5 竣工（完工）结算
17.5.1竣工（完工）付款申请单
（1）承包人应提交完工付款申请单一式___陆____份。
17.6 最终结清
17.6.1最终结清申请单
（1）承包人应提交最终结清申请单一式__陆_____份。
17.7 竣工财务决算
承包人应为竣工财务决算编制提供的资料： 按国家有关规定 。
18 竣工验收（验收）
18.1 验收工作分类
（签订合同时商定）
18.5 阶段验收
18.5.1 本合同工程阶段验收类别包括： （签订合同时商定）
18.6 专项验收
18.6.2 本合同工程专项验收类别包括： （签订合同时商定）。
18.7 竣工验收
18.7.3 本工程不需要_（需要/不需要）竣工验收技术鉴定（蓄水安全鉴定）。
18.8 施工期运行
18.8.1 需要在施工期运行的单位工程或工程设备为：（签订合同时商定）。
18.9 试运行
18.9.1 试运行的组织：（签订合同时商定）；费用承担：（签订合同时商定）。
19 缺陷责任与保修责任
19.1 缺陷责任期（工程质量保修期）的起算时间
本工程缺陷责任期（工程质量保修期）计算如下：工程通过合同工程完工验收后 1年。
20 保险
20.1 工程保险
建筑工程一切险和（或）安装工程一切险投保人 按通用合同条款执行；投保内容：为本合同工程的永久工程、临时工程和设备及已运至施工工地用于永久工程的材料和设备所投的保险 _；保险金额、保险费率和保险期限： 开工日起直至本合同工程竣工验收合格之日止。
20.4 第三者责任险
承包人应对本工程施工范围内的第三者进行保险，其费用含在报价中
20.5 其他保险
需要投保的其他内容：______________；保险金额、保险费率和保险期限：______________。
20.6 对各项保险的一般要求
20.6.1保险凭证
承包人向发包人提交各项保险生效的证据和保险单副本的期限：开工后 14 天内。
20.6.4保险金不足的补偿
保险金不足的补偿：承包人和发包人各自负责补偿_。
24争议的解决
24.1 争议的解决方式
合同当事人友好协商解决不成、不愿提请争议评审或不接受争议评审组意见的，约定的合同争议解决方式： 向建瓯市人民法院提起诉讼。
","template":"","PROJECT_PRICE_LIST_ATTACHMENTS":[{"id":"60f77779d8f8791d84fcef4f","md5":"345398C27254C5BB3EA514FEF2C1A848","name":"工程项目总价表.xlsx","new_id":"60f77779d8f8791d84fcef4f","size":15718,"url":"/file/getcontent/60f77779d8f8791d84fcef4f.xlsx"}],"TOTAL_PROJECT_PRICE_LIST_SELECT":"工程项目总价表","CONSTRUCTION_PROJECT_AMOUNT_PRICE_LIST_SELECT":"建筑工程工程量清单报价表","TEMPORARY_PROJECT_AMOUNT_PRICE_LIST_SELECT":"临时工程工程量清单报价表","OTHER_PROJECT_AMOUNT_PRICE_LIST_SELECT":"其他项目工程工程量清单报价表","ELECTRICAL_OR_METALLIC_STRUCTURES_PROJECT_AMOUNT_PRICE_LIST_SELECT":"机电或金属结构工程工程量清单报价表","EQUIPMENT_AND_INSTALLATION_PROJECT_AMOUNT_PRICE_LIST_SELECT":"设备及安装工程工程量清单报价表","OTHER_INDUSTRY_PROJECT_AMOUNT_LIST_ATTACHMENTS":[],"SUPPLEMENTARY_LIST_ATTACHMENTS":[{"id":"60f6a7a37accd523b8d27092","md5":"CA0E071D4970A0DD2F69FF39E
*******","name":"(无关联式)建瓯市松溪东峰河段清淤疏浚河道整治工程（东峰c5段）.xls","new_id":"60f6a7a37accd523b8d27092","size":123392,"url":"/file/getcontent/60f6a7a37accd523b8d27092.xls"},{"id":"60f6a7a37accd523b8d27094","md5":"29749B5AF059785D4E804C0C89F1B87D","name":"工程项目总价表.xlsx","new_id":"60f6a7a37accd523b8d27094","size":16554,"url":"/file/getcontent/60f6a7a37accd523b8d27094.xlsx"},{"id":"60f6a7a36454a40f1014f5f8","md5":"77CCC214EAC4FFE62D44300F2CD08870","name":"建瓯市松溪东峰河段清淤疏浚河道整治工程（东峰C5段）.yst21","new_id":"60f6a7a36454a40f1014f5f8","size":
*******,"url":"/file/getcontent/60f6a7a36454a40f1014f5f8.yst21"}],"TOTAL_PROJECT_PRICE_LIST":[{"index":"第一部分","name":"建筑工程","cost":"
*******","remark":""},{"index":"第二部分","name":"施工临时工程","cost":"301693","remark":""},{"index":"","name":"小计","cost":"
*******","remark":""},{"index":"","name":"总 计","cost":"
*******","remark":""}],"PRIMARY_LIST":[{"PROJECT_NUMBER":"第一部分","PROJECT_LIST_NAME":"建筑工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"
*******"},{"PROJECT_NUMBER":"一","PROJECT_LIST_NAME":"东峰C5段","UNIT":"","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"
*******"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"链斗式挖泥船（150m3/h）(运距2km)","UNIT":"m3","QUANTITIES":"71019","UNIVALENT":"20.7","TOTAL":"
*******"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"挖掘机开挖（运距2km）","UNIT":"m3","QUANTITIES":"30437","UNIVALENT":"14.78","TOTAL":"449859"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"抛填砂卵石护岸","UNIT":"m3抛投方","QUANTITIES":"4690","UNIVALENT":"7.25","TOTAL":"34003"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"河滩平整","UNIT":"m2","QUANTITIES":"18375","UNIVALENT":"1.71","TOTAL":"31421"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"合计","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":"
*******"},{"PROJECT_NUMBER":"第二部分","PROJECT_LIST_NAME":"施工临时工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"301693"},{"PROJECT_NUMBER":"一","PROJECT_LIST_NAME":"施工临时围堰","UNIT":"","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"164728"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"建筑物砂石料回填 砂砾料 夯填","UNIT":"m3实方","QUANTITIES":"7128","UNIVALENT":"23.11","TOTAL":"164728"},{"PROJECT_NUMBER":"二","PROJECT_LIST_NAME":"施工临时堆场","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"13119"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"临时堆场清表","UNIT":"m2","QUANTITIES":"7248","UNIVALENT":"1.81","TOTAL":"13119"},{"PROJECT_NUMBER":"三","PROJECT_LIST_NAME":"施工交通工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"24577"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"施工便道（宽度4m）","UNIT":"m3实方","QUANTITIES":"248","UNIVALENT":"99.1","TOTAL":"24577"},{"PROJECT_NUMBER":"四","PROJECT_LIST_NAME":"暂列金","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"99269"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"暂列金","UNIT":"元","QUANTITIES":"
*******","UNIVALENT":"5","TOTAL":"99269"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"合计","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":"301693"}],"CONSTRUCTION_PROJECT_AMOUNT_PRICE_LIST":[{"index":"第一部分","name":"建筑工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"
*******","remark":""},{"index":"一","name":"东峰C5段","unit":"","project_amount":"0","unit_price":"0","combined_price":"
*******","remark":""},{"index":"","name":"链斗式挖泥船（150m3/h）(运距2km)","unit":"m3","project_amount":"71019","unit_price":"20.7","combined_price":"
*******","remark":""},{"index":"","name":"挖掘机开挖（运距2km）","unit":"m3","project_amount":"30437","unit_price":"14.78","combined_price":"449859","remark":""},{"index":"","name":"抛填砂卵石护岸","unit":"m3抛投方","project_amount":"4690","unit_price":"7.25","combined_price":"34003","remark":""},{"index":"","name":"河滩平整","unit":"m2","project_amount":"18375","unit_price":"1.71","combined_price":"31421","remark":""},{"index":"","name":"合计","unit":"","project_amount":"","unit_price":"","combined_price":"
*******","remark":""}],"TEMPORARY_PROJECT_AMOUNT_PRICE_LIST":[{"index":"第二部分","name":"施工临时工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"301693","remark":""},{"index":"一","name":"施工临时围堰","unit":"","project_amount":"0","unit_price":"0","combined_price":"164728","remark":""},{"index":"","name":"建筑物砂石料回填 砂砾料 夯填","unit":"m3实方","project_amount":"7128","unit_price":"23.11","combined_price":"164728","remark":""},{"index":"二","name":"施工临时堆场","unit":"元","project_amount":"0","unit_price":"0","combined_price":"13119","remark":""},{"index":"","name":"临时堆场清表","unit":"m2","project_amount":"7248","unit_price":"1.81","combined_price":"13119","remark":""},{"index":"三","name":"施工交通工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"24577","remark":""},{"index":"","name":"施工便道（宽度4m）","unit":"m3实方","project_amount":"248","unit_price":"99.1","combined_price":"24577","remark":""},{"index":"四","name":"暂列金","unit":"元","project_amount":"0","unit_price":"0","combined_price":"99269","remark":"不可竞争金额"},{"index":"","name":"暂列金","unit":"元","project_amount":"
*******","unit_price":"5","combined_price":"99269","remark":""},{"index":"","name":"合计","unit":"","project_amount":"","unit_price":"","combined_price":"301693","remark":""}],"OTHER_PROJECT_AMOUNT_PRICE_LIST":[],"ELECTRICAL_OR_METALLIC_STRUCTURES_PROJECT_AMOUNT_PRICE_LIST":[],"EQUIPMENT_AND_INSTALLATION_PROJECT_AMOUNT_PRICE_LIST":[],"GRAPH_PAPER_ATTACHMENTS":[{"id":"60f793cad8f8791d84fd941b","md5":"
*******F
*******C0BD404E07B93726D","name":"plot.log","new_id":"60f793cad8f8791d84fd941b","size":4161,"url":"/file/getcontent/60f793cad8f8791d84fd941b.log"},{"id":"60f793cad8f8791d84fd941d","md5":"B4857C57AFF68B0F6A984AEA094E6179","name":"C5图纸封面 - 副本.docx","new_id":"60f793cad8f8791d84fd941d","size":12829,"url":"/file/getcontent/60f793cad8f8791d84fd941d.docx"},{"id":"60f793cad8f8791d84fd941f","md5":"2682CFE
********9CF64263E45C75F84","name":"C5图纸总目录 - 副本.doc","new_id":"60f793cad8f8791d84fd941f","size":57102,"url":"/file/getcontent/60f793cad8f8791d84fd941f.doc"},{"id":"60f793cdd8f8791d84fd9438","md5":"CBBC829E55F64FA57C
*******C1EDB97","name":"松溪（东峰段）河道疏浚整治工程平面图.dwg","new_id":"60f793cdd8f8791d84fd9438","size":
********,"url":"/file/getcontent/60f793cdd8f8791d84fd9438.dwg"}],"TECHNICAL_REQUIREMENTS_ATTACHMENTS":[],"ISUNION":"否","UNIONTENDER":"","UNIONCODE":"","UNIONCODETYPE":"","XM_BID_SECTION_NUM":"","PRICE_FORM_CODE":"1","MARGIN_PERCENT":"","FJGGZY_FILE_LIST":[{"name":"立项批复文件（项目审批核准文件）","key":"SGG_LXPFWJ","val":[{"id":"60f7df0ed8f8791d84febb84","md5":"DA1EA4F05CD084779C4179DBBA8514CC","name":"4699ea17688f7ddb62b58d336858c4f.jpg","new_id":"60f7df0ed8f8791d84febb84","size":26903,"url":"/file/getcontent/60f7df0ed8f8791d84febb84.jpg"},{"id":"60f7df0ed8f8791d84febb86","md5":"C2C5220A8400F699A8F9A5D7F286A192","name":"3f11266df3fa046fabc03e7a01d7a51.jpg","new_id":"60f7df0ed8f8791d84febb86","size":49437,"url":"/file/getcontent/60f7df0ed8f8791d84febb86.jpg"},{"id":"60f7df0ed8f8791d84febb88","md5":"B97C521AAABA6054AC7DC196E8D244FE","name":"82b61b2864b575b3ff7e1dc589227e2.jpg","new_id":"60f7df0ed8f8791d84febb88","size":53270,"url":"/file/getcontent/60f7df0ed8f8791d84febb88.jpg"},{"id":"60f7df0ebef9000ed
*******","md5":"7BCFD6E
********4D2EAB6F1D747A254","name":"627bb208316cf8e263aa0928ffad1c9.jpg","new_id":"60f7df0ebef9000ed
*******","size":62417,"url":"/file/getcontent/60f7df0ebef9000ed
*******.jpg"}],"isUpload":true,"limit":""},{"name":"招标文件附件","key":"SGG_ZBWJFJ","val":[{"id":"60f92383e
*******d8e12fa3","md5":"F6F87F12123D9CAC0BD42C6C86575DA7","name":"招标文件.pdf","new_id":"60f92383e
*******d8e12fa3","size":
*******,"url":"/file/getcontent/60f92383e
*******d8e12fa3.pdf"}],"isUpload":true,"limit":""},{"name":"招标公告PDF文件（招标人或其代理机构盖章并由项目负责人签名或者电子签名）","key":"SGG_ZBGGPDFWJ","val":[{"id":"60f
*******c0b52a0078bf39","md5":"7B502AC3F0B8D0B9BC2F189E0661EB83","name":"招标公告.pdf","new_id":"60f
*******c0b52a0078bf39","size":682112,"url":"/file/getcontent/60f
*******c0b52a0078bf39.pdf"}],"isUpload":true,"limit":""},{"name":"招标公告电子签章文件（招标人或其代理机构盖章并由项目负责人签名或者电子签名）","key":"SGG_ZBGGDZQZWJ","val":[{"id":"60f
*******c0b52a0078be2c","md5":"55D383E
*******C124D311B77AEFB3CE","name":"东峰C5公告1.jpg","new_id":"60f
*******c0b52a0078be2c","size":271072,"url":"/file/getcontent/60f
*******c0b52a0078be2c.jpg"},{"id":"60f
*******c0b52a0078be2e","md5":"34C1E859E2DFCB54EE3AE4A18F5189A5","name":"东峰C5公告.jpg","new_id":"60f
*******c0b52a0078be2e","size":273497,"url":"/file/getcontent/60f
*******c0b52a0078be2e.jpg"}],"isUpload":true,"limit":""},{"name":"主要负责人的授权书","key":"SGG_ZYFZRDSQS","val":[{"id":"60f923eee
*******d8e130c3","md5":"773596E7FC6C38E8D5D2EA16A9682A8C","name":"授权委托书.jpg","new_id":"60f923eee
*******d8e130c3","size":172504,"url":"/file/getcontent/60f923eee
*******d8e130c3.jpg"}],"isUpload":true,"limit":""},{"name":"资金来源落实证明文件","key":"SGG_ZJLYLSZMWJ","val":[{"id":"60f923fa08c0b52a0078bdd4","md5":"8F2755AEB32AD086A06454A6C769376C","name":"东峰C5资金来源证明.jpg","new_id":"60f923fa08c0b52a0078bdd4","size":204230,"url":"/file/getcontent/60f923fa08c0b52a0078bdd4.jpg"}],"isUpload":true,"limit":""},{"name":"招标代理合同","key":"SGG_ZBDLHT","val":[],"isUpload":false,"limit":""},{"name":"公共资源交易入场登记表","key":"SGG_GGZYJYRCDJB","val":[{"id":"60f
*******c0b52a0078bdeb","md5":"E4FCF60678D
*******D88FBAF188143D","name":"东峰C5备案表.jpg","new_id":"60f
*******c0b52a0078bdeb","size":153873,"url":"/file/getcontent/60f
*******c0b52a0078bdeb.jpg"}],"isUpload":false,"limit":""},{"name":"招标代理机构承诺书","key":"SGG_ZBDLJGCNS","val":[],"isUpload":false,"limit":""},{"name":"其他招标代理机构认为需要上传的文件资料","key":"SGG_QTZBDLJGRWXYSCDWJZL","val":[],"isUpload":false,"limit":""},{"name":"入场登记表中由行政主管部门明确入场意见","key":"SGG_RCDJBZYXZZGBMMQRCYJ","val":[],"isUpload":false,"limit":""},{"name":"加盖电子印章的澄清、答疑及补充PDF电子文件","key":"SGG_JGDZYZDCQDYJBCPDFDZWJ","val":[],"isUpload":false,"limit":""},{"name":"投标邀请书","key":"SGG_TBYQS","val":[],"isUpload":false,"limit":""}],"SGG_ZBWJFJ":[{"id":"60f92383e
*******d8e12fa3","md5":"F6F87F12123D9CAC0BD42C6C86575DA7","name":"招标文件.pdf","new_id":"60f92383e
*******d8e12fa3","size":
*******,"url":"/file/getcontent/60f92383e
*******d8e12fa3.pdf"}],"IS_ABLE_USE_DZBH":false,"REVIEW_STATUS":"","REVIEW_COMMENT":"","PROJECT_NAME_disabled":false,"SJD_TENDER_PROJECT_CODE":"N
****************20001","GGZY_UNIFIED_DEAL_CODE":"","Is_MultiSegment":"否","PM_TABLE_DATA":[{"POST":"项目经理","POST_NUMBER":"1","PROFESSIONAL_TITLE":"/","PROFESSIONAL":"水利水电工程"},{"POST":"技术负责人","POST_NUMBER":"1","PROFESSIONAL_TITLE":"中级","PROFESSIONAL":"水利水电工程相关行业"},{"POST":"施工员","POST_NUMBER":"1","PROFESSIONAL_TITLE":"/","PROFESSIONAL":"/"},{"POST":"材料员","POST_NUMBER":"1","PROFESSIONAL_TITLE":"/","PROFESSIONAL":"/"},{"POST":"质检员","POST_NUMBER":"1","PROFESSIONAL_TITLE":"/","PROFESSIONAL":"/"},{"POST":"安全员","POST_NUMBER":"1","PROFESSIONAL_TITLE":"/","PROFESSIONAL":"/"}],"EARNEST_BLOCK_METHOD":["现金","支票","银行保函","电子保函","年度保证金"],"updateContent_cost":{"TENDER_QUANTITIES":{"PROJECT_PRICE_LIST_ATTACHMENTS":[{"id":"60f77779d8f8791d84fcef4f","md5":"345398C27254C5BB3EA514FEF2C1A848","name":"工程项目总价表.xlsx","new_id":"60f77779d8f8791d84fcef4f","size":15718,"url":"/file/getcontent/60f77779d8f8791d84fcef4f.xlsx"}],"TOTAL_PROJECT_PRICE_LIST_SELECT":"工程项目总价表","CONSTRUCTION_PROJECT_AMOUNT_PRICE_LIST_SELECT":"建筑工程工程量清单报价表","TEMPORARY_PROJECT_AMOUNT_PRICE_LIST_SELECT":"临时工程工程量清单报价表","OTHER_PROJECT_AMOUNT_PRICE_LIST_SELECT":"其他项目工程工程量清单报价表","ELECTRICAL_OR_METALLIC_STRUCTURES_PROJECT_AMOUNT_PRICE_LIST_SELECT":"机电或金属结构工程工程量清单报价表","EQUIPMENT_AND_INSTALLATION_PROJECT_AMOUNT_PRICE_LIST_SELECT":"设备及安装工程工程量清单报价表","SUPPLEMENTARY_LIST_ATTACHMENTS":[{"id":"60f6a7a37accd523b8d27092","md5":"CA0E071D4970A0DD2F69FF39E
*******","name":"(无关联式)建瓯市松溪东峰河段清淤疏浚河道整治工程（东峰c5段）.xls","new_id":"60f6a7a37accd523b8d27092","size":123392,"url":"/file/getcontent/60f6a7a37accd523b8d27092.xls"},{"id":"60f6a7a37accd523b8d27094","md5":"29749B5AF059785D4E804C0C89F1B87D","name":"工程项目总价表.xlsx","new_id":"60f6a7a37accd523b8d27094","size":16554,"url":"/file/getcontent/60f6a7a37accd523b8d27094.xlsx"},{"id":"60f6a7a36454a40f1014f5f8","md5":"77CCC214EAC4FFE62D44300F2CD08870","name":"建瓯市松溪东峰河段清淤疏浚河道整治工程（东峰C5段）.yst21","new_id":"60f6a7a36454a40f1014f5f8","size":
*******,"url":"/file/getcontent/60f6a7a36454a40f1014f5f8.yst21"}],"TOTAL_PROJECT_PRICE_LIST":[{"index":"第一部分","name":"建筑工程","cost":"
*******","remark":""},{"index":"第二部分","name":"施工临时工程","cost":"301693","remark":""},{"index":"","name":"小计","cost":"
*******","remark":""},{"index":"","name":"总 计","cost":"
*******","remark":""}],"PRIMARY_LIST":[{"PROJECT_NUMBER":"第一部分","PROJECT_LIST_NAME":"建筑工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"
*******"},{"PROJECT_NUMBER":"一","PROJECT_LIST_NAME":"东峰C5段","UNIT":"","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"
*******"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"链斗式挖泥船（150m3/h）(运距2km)","UNIT":"m3","QUANTITIES":"71019","UNIVALENT":"20.7","TOTAL":"
*******"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"挖掘机开挖（运距2km）","UNIT":"m3","QUANTITIES":"30437","UNIVALENT":"14.78","TOTAL":"449859"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"抛填砂卵石护岸","UNIT":"m3抛投方","QUANTITIES":"4690","UNIVALENT":"7.25","TOTAL":"34003"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"河滩平整","UNIT":"m2","QUANTITIES":"18375","UNIVALENT":"1.71","TOTAL":"31421"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"合计","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":"
*******"},{"PROJECT_NUMBER":"第二部分","PROJECT_LIST_NAME":"施工临时工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"301693"},{"PROJECT_NUMBER":"一","PROJECT_LIST_NAME":"施工临时围堰","UNIT":"","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"164728"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"建筑物砂石料回填 砂砾料 夯填","UNIT":"m3实方","QUANTITIES":"7128","UNIVALENT":"23.11","TOTAL":"164728"},{"PROJECT_NUMBER":"二","PROJECT_LIST_NAME":"施工临时堆场","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"13119"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"临时堆场清表","UNIT":"m2","QUANTITIES":"7248","UNIVALENT":"1.81","TOTAL":"13119"},{"PROJECT_NUMBER":"三","PROJECT_LIST_NAME":"施工交通工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"24577"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"施工便道（宽度4m）","UNIT":"m3实方","QUANTITIES":"248","UNIVALENT":"99.1","TOTAL":"24577"},{"PROJECT_NUMBER":"四","PROJECT_LIST_NAME":"暂列金","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"99269"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"暂列金","UNIT":"元","QUANTITIES":"
*******","UNIVALENT":"5","TOTAL":"99269"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"合计","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":"301693"}],"CONSTRUCTION_PROJECT_AMOUNT_PRICE_LIST":[{"index":"第一部分","name":"建筑工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"
*******","remark":""},{"index":"一","name":"东峰C5段","unit":"","project_amount":"0","unit_price":"0","combined_price":"
*******","remark":""},{"index":"","name":"链斗式挖泥船（150m3/h）(运距2km)","unit":"m3","project_amount":"71019","unit_price":"20.7","combined_price":"
*******","remark":""},{"index":"","name":"挖掘机开挖（运距2km）","unit":"m3","project_amount":"30437","unit_price":"14.78","combined_price":"449859","remark":""},{"index":"","name":"抛填砂卵石护岸","unit":"m3抛投方","project_amount":"4690","unit_price":"7.25","combined_price":"34003","remark":""},{"index":"","name":"河滩平整","unit":"m2","project_amount":"18375","unit_price":"1.71","combined_price":"31421","remark":""},{"index":"","name":"合计","unit":"","project_amount":"","unit_price":"","combined_price":"
*******","remark":""}],"TEMPORARY_PROJECT_AMOUNT_PRICE_LIST":[{"index":"第二部分","name":"施工临时工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"301693","remark":""},{"index":"一","name":"施工临时围堰","unit":"","project_amount":"0","unit_price":"0","combined_price":"164728","remark":""},{"index":"","name":"建筑物砂石料回填 砂砾料 夯填","unit":"m3实方","project_amount":"7128","unit_price":"23.11","combined_price":"164728","remark":""},{"index":"二","name":"施工临时堆场","unit":"元","project_amount":"0","unit_price":"0","combined_price":"13119","remark":""},{"index":"","name":"临时堆场清表","unit":"m2","project_amount":"7248","unit_price":"1.81","combined_price":"13119","remark":""},{"index":"三","name":"施工交通工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"24577","remark":""},{"index":"","name":"施工便道（宽度4m）","unit":"m3实方","project_amount":"248","unit_price":"99.1","combined_price":"24577","remark":""},{"index":"四","name":"暂列金","unit":"元","project_amount":"0","unit_price":"0","combined_price":"99269","remark":"不可竞争金额"},{"index":"","name":"暂列金","unit":"元","project_amount":"
*******","unit_price":"5","combined_price":"99269","remark":""},{"index":"","name":"合计","unit":"","project_amount":"","unit_price":"","combined_price":"301693","remark":""}],"OTHER_PROJECT_AMOUNT_PRICE_LIST":[],"ELECTRICAL_OR_METALLIC_STRUCTURES_PROJECT_AMOUNT_PRICE_LIST":[],"EQUIPMENT_AND_INSTALLATION_PROJECT_AMOUNT_PRICE_LIST":[]}},"updateContent_price":{"CONTROL_PRICE":"
*******","COMPETITION_PRICE":"
*******","NON_COMPETITION_PRICE":"99269"},"UUM_ENTP_BASE_INFO":{"BusinessData":"2069-06-19","OrganizationNumber":"
********MA32YCJ544","Email":"
********71@qq.com","LocaltaxData":"","tbwjAttachments":{"Busattachments":[{"id":"5f365c7c021b7049f4f8bec7","md5":"0BB8F47CE4F7AC3C118236B246B0F0D8","name":"营业执照.jpg","new_id":"5f365c7c021b7049f4f8bec7","size":1402509,"url":"/file/getcontent/5f365c7c021b7049f4f8bec7.jpg"}],"Socattachments":[{"id":"5f365cf7021b7049f4f8bfad","md5":"DBD00E9BB03F54085A5D9857321CA746","name":"营业执照.jpg","new_id":"5f365cf7021b7049f4f8bfad","size":5594929,"url":"/file/getcontent/5f365cf7021b7049f4f8bfad.jpg"}],"Staattachments":[{"id":"5f365c8928d0c94de09bd300","md5":"0BB8F47CE4F7AC3C118236B246B0F0D8","name":"营业执照.jpg","new_id":"5f365c8928d0c94de09bd300","size":1402509,"url":"/file/getcontent/5f365c8928d0c94de09bd300.jpg"}],"Govattachments":[{"id":"5f365ca028d0c94de09bd36e","md5":"0BB8F47CE4F7AC3C118236B246B0F0D8","name":"营业执照.jpg","new_id":"5f365ca028d0c94de09bd36e","size":1402509,"url":"/file/getcontent/5f365ca028d0c94de09bd36e.jpg"}],"Orgattachments":[{"id":"5f365c6cf2dde960e4fdb5c7","md5":"0BB8F47CE4F7AC3C118236B246B0F0D8","name":"营业执照.jpg","new_id":"5f365c6cf2dde960e4fdb5c7","size":1402509,"url":"/file/getcontent/5f365c6cf2dde960e4fdb5c7.jpg"}],"Locattachments":[{"id":"5f365c93a4d60d1048153320","md5":"0BB8F47CE4F7AC3C118236B246B0F0D8","name":"营业执照.jpg","new_id":"5f365c93a4d60d1048153320","size":1402509,"url":"/file/getcontent/5f365c93a4d60d1048153320.jpg"}]},"BasicName":"福建阳紫工程管理有限公司","BasicUnitName":"福建阳紫工程管理有限公司","LocaltaxNumber":"
********MA32YCJ544","LeType":"1","Currency":"156","LeoIDType":"身份证","GoverData":"","StateTaxNumberDas":true,"LeoIDNumber":"352601197608021524","ConPhone":"18250958959","CreditRatingLabel":"A","OrganizationData":"","unitName":"福建阳紫工程管理有限公司","CreditRating":"A","ENTP_PROPERTY":"5","LeoPhone":"13328615361","City":"龙岩市","Province":"福建省","GoverNumber":"
********MA32YCJ544","SocietyData":"2069-06-19","OrganizationNumberDas":true,"Country":"中国
