江阴港城经济区新厝产业区原水管道工程(施工)

江阴港城经济区新厝产业区原水管道工程(施工)

本招标项目专用合同条款如下:

通用条款所述的“竣工验收”均指“完工验收”

1 一般约定

1.1 词语定义

1.1.2 合同当事人和人员

1.1.2.2 发包人:_(填入发包人的名称)

1.1.2.3 承包人:指与发包人在合同协议书中签署的当事人。(签约后填入承包人的名称)

1.1.2.5 分包人:/

1.1.2.6 监理人:_(填入监理人名称) _

1.1.4 日期

1.1.4.3 工期:_(中标后根据投标人承诺填入) _日历天(其中各关键节点的工期:__(中标后根据投标人承诺填入) __)

1.1.4.5 缺陷责任期(工程质量保修期):工程通过合同工程完工验收后1年。

1.4 合同文件的优先顺序

进入合同文件的各项文件及其优先顺序是

(1)合同协议书及各种合同附件(含评标期间和合同谈判过程中的澄清文件和补充资料);

(2)中标通知书;

3)专用合同条款;

4)通用合同条款;

5)投标函及投标函附录;

(6)技术标准和要求;

(7)图纸;

(8)已标价工程量清单;

(9)承包人有关人员、设备投入的承诺及投标文件中的施工组织设计;

(10)本工程施工招标文件(含招标文件补充答疑等);

(11)其他合同文件。

1.7 联络

1.7.2 来往函件均应按技术标准和要求(合同技术条款)约定的期限送达下列通知地址(双方签订合同时 填写文件送达地点)。

任何一方在发送本合同项下的或与本合同有关的通知、信函、报告等材料时,应采用书面形式并发往下列地址,在对方接到一方发出的变更其收件人/地址的通知之前,该方收件人/地址仍以先前为准。双方同意以下列通知地址作为双方司法/仲裁文书的送达地址,如有变化,规则同前。

(1)发给发包人的通知地址:

收件人:

收件地址:

联系电话:

邮编:

(2)发给承包人的通知地址:

收件人:

收件地址:

联系电话:

邮编:

2 发包人义务

2.3 提供施工场地

2.3.2 发包人提供的施工用地范围为:发包人负责办理招标图纸所示范围内用地征地和移民,向承包人提供能满足施工条件所需的用地。超出招标图纸所示范围的用地,由承包人报监理人及发包人审批,若确需增加,则由发包人负责征用。

2.3.3 承包人自行勘察的施工场地范围为:发包人提供的资料不足的部分,由承包人自行补充勘察,发包人不承担由此产生的任何费用。

2.8 其它义务

(根据发包人的合同管理要求补充)

(1)提供施工用水用电接入点, 所有使用费用均由承包人承担,承包人应向有关部门及时缴交费用,逾期不交的,发包人有权从承包人的工程款中扣除,并追究承包人责任,承包人对此不得有异议。电讯线路和供应问题由承包人自行联系和解决,并承担相关费用

3 监理人

3.1 监理人的职责和权力

3.1.1 监理人须根据发包人事先批准的权力范围行使权力,发包人批准的权力范围:

(1)按第4.3条约定,批准工程的某些非主体和非关键性工作分包;

(2)确定第4.11款下产生的费用增加额;

(3)按第11.3条约定,确定延长完工期限;

(4)根据第12.3款、第12.4款发布开工通知、暂停施工指示或复工通知;

(5)确定第15.4款下变更工作的单价;

(6)按第15.6条约定,批准暂列金额的使用;

(7)确定第15.8款项下的暂估价金额;

(8)确定第23.1款项下的索赔额。

承包人无论何种原因以书面形式提出调整主要工程技术人员、调换主要材料、品种、规格、质量、数量、重量或技术参数等,均须取得监理单位和发包人代表的书面许可。发包人在工程开工前将监理工程师的职责和权限通知承包人。具体行使职权的范围依据发包人和监理公司签订的监理合同内容为准,监理合同未作说明的,按国家监理条例履行监理职责;除合同内有明确约定或经发包人同意外,总监无权解除本协议约定的承包人的任何权利和义务。

如果发生紧急情况,监理人认为将造成人员伤亡,或危及本工程或邻近的财产需立即采取行动,监理人有权在未征得发包人的批准的情况下发布处理紧急情况所必须的指令,承包人应予执行,由此造成的费用增加由监理人按第3.5款确定

4 承包人

4.1 承包人的一般义务

4.1.4 对施工作业和施工方法的完备性负责

增加以下内容:

(1)合同签订后10个日历天内承包人须向发包人及监理人提交实施性施工组织设计方案、专项施工安全方案、施工专顶技术方案、具有相应资质的安全评估企业出具施工方案评估报告、抗台、雨季确保施工安全的方案和措施,施工场地内的排水组织方案以及工程施工总进度计划壹式肆份;

(2) 每周星期一及每月25日前向发包人报送经监理人审核的《周例会报告》及包含“下一月度施工计划”、“实际进度与计划进度对比”(格式符合发包人要求)的当月完成进度报告,一式贰份。

(3) 合同签订后15个日历天内及每月25日前向发包人提供项目建设资金使用计划及每月用款计划,一式贰份。

(4) 工程完工后7日内向发包人提交完工报告书,遇其它异常情况应及时向发包人及监理人报告。

(5) 发包人要求承包人提供的其他相关资料与表格。

以上报表、资料承包人均应按时提供,每延迟一天发包人有权要求承包人支付5000元的违约金,并从当期进度款中扣除。

(6)承包人应负责协调处理好与其承包的工程所在地的地方政府、农民及附近的有关单位的关系,尽可能的避免发生纠纷,还应该注意做好环境保护工作,以利工程顺利进行。在投标前现场勘查阶段,承包人应充分考虑上述因素,制定相应的措施及施工方案,并将由此产生的相关费用计入投标报价中。如因承包人处理不当导致工程暂停施工的按工期延误承担违约责任,如有第三方向发包人索赔,则由承包人负责赔偿。如承包人确无责任导致施工暂停施工,或者有第三方向发包人索赔,则由发包人、监理人及承包人与发生矛盾的对方协商解决,因此导致实际延迟的工期可按一半时间顺延,相关费用、损失等由承包人承担。

(7)承包人应采取适当的防洪排涝等渡汛措施,并将有关费用列入工程报价,应防止洪水给施工工区造成损失,由此所发生的一切费用应计入在相关项目的单价和合同总价之中,发包人不另行支付

(8)承包人提供的材料设备必须满足以下要求:

A. 承包人应向发包人提交《工程材料设备一览表》,详细填报如下数据:材料设备名称、规格型号、品牌、计量单位、数量、单价、供应时间、送达地点,附送材料的实物样品、设备的彩页样张。

B. 承包人采购的材料设备必须是正规厂家所拥有的正式注册的正品,不得使用次品或仿冒品,进口材料设备产品必须是从国家规定的正规渠道进口的产品,具有合法手续,其所发生的一切法律责任由承包人负责。

C.承包人提供的材料设备产品的质量必须符合国家建材行业和机电行业等标准要求。

D.材料设备运抵现场时,应由发包人及承包人双方及监理工程师就材料设备的种类、产地、品牌、数量、规格、单价、技术参数、质量等级等,按发包人规定的统一品牌项目和国家制定的有关产品质量标准规范要求进行验收或抽查试验,承包人并应向验收人员提供有关产品合格证、许可证、准用证等证明和出厂日期等以供核对。

E.承包人采购的建筑装修材料、大宗设备须向发包人提供正式发票复印件备案。

F.承包人应负责材料的保管及成品半成品的保管工作。

G.在合同实施过程中,承包人应就材料设备满足招标文件“第7章技术标准和要求”提供相关证明材料,若提供的证明材料不满足技术要求,招标人有权更换为满足技术要求的品牌型号,且合同价格不予调整。

H.材料设备管理方面的违约责任:

①承包人必须保证用于本工程所有的材料设备的品牌、型号、规格、质量等符合本合同及招投标文件的要求。如发生不符合上述要求的情况,发包人有权要求承包人必须无条件在发包人限定的时间内全部更换为符合要求的产品,并由承包人按所需更换的符合要求的货物价款的20%向发包人支付违约金,因此给发包人造成损失的,由承包人负责赔偿。如因此致使发包人需要另行采购符合本合同及招投标文件要求的货物的,承包人按另行采购的货物总价款的120%向发包人支付违约金,并赔偿发包人一切损失(包括但不限于工期延误、货物价格上涨、招标代理费用等)。

②承包人不按合同的约定对用于本工程的材料设备进行管理的,视同不服从发包人及监理人管理,情节较轻的,可给予书面警告,发包人有权暂停支付本工程进度款,直到承包人完成相关整改工作为止,并由承包人承担由此造成的一切经济损失。情节特别严重的,发包人有权单方面解除合同,承包人须支付签约合同价款的10%违约金,并赔偿发包人一切损失。

③承包人拒绝执行发包人对设计、主要材料及设备进行的变更时,自变更发出之日起,每拖延一天,发包人有权要求承包人支付10000元/天的违约金,导致工期延误的,还需承担工期延误违约责任。

④因承包人所供货物质量问题造人身伤害或发包人损失的,承包人应承担全部赔偿责任,并应在发包人通知的期限内修复故障或调换合格成品。

(8)本项目承包人应进行管道压力试验、管道冲洗和消毒,并满足相关规范要求。另,工程全部完工后,本标段承包人应参与到全线通水试验中,通水试验的实施方案和时间由监理人确定,承包人应在通水试验过程中和通水试验完成后对本标段由承包人施工的管道进行再次质量检查,相应承包人施工范围内的管道通水试验费和质量检查费不单独计价,含在工程单价或总价中,发包人不另行支付。

4.1.10 其他义务

(1) 临时占地范围包括承包人驻地的办公室、食堂、宿舍、道路和机械设备停放场、材料(包括爆破所需材料)堆放场地、弃土场、预制场、拌合场、仓库、进场临时道路、临时便道、便桥等。承包人应在临时占地计划表范围内按实际需要与先后次序,提出具体计划报监理人、发包人同意。

临时占地退还前,承包人应按照复垦方案及业主要求对临时占地进行复垦或复耕。如因承包人撤离后未按要求对临时占地进行恢复或虽进行了恢复但未达到使用标准的,将由发包人委托第三方对其恢复,所发生的费用将从应付给承包人的任何款项内扣除。

(2) 承包人应严格遵守国家有关解决拖欠工程款和民工工资的法律、法规,及时支付工程中的材料、设备货款及民工工资等费用。承包人不得以任何借口拖欠材料、设备货款及民工工资等费用,如果出现此种现象,发包人代为支付拖欠的材料、设备货款及民工工资,从应付给承包人的工程款中扣除相应款项。对承包人恶意拖欠和拒不按计划支付的,作为不良记录纳入水利建设市场信用信息管理系统。

(3)承包人在实施和完成承建合同工程及修复缺陷过程中的一切作业应保证发包人免于承担因承包人借用、占用或进出其他标段工区或影响作业等所引起的索赔、诉讼费、损害赔偿及其他开支。承包人有义务提供与相邻标段工程施工的配合与协调,包括:

①工作面的安全和施工质量影响。

②施工进度的影响。

③及时提供或移交工作面。

④保持相邻界面附近的结构质量。

⑤为其他标段承包人提供交通道路、交叉工作面的作业场地。

(4) 承包人应接受工程质量监督和工程安全鉴定单位的检查,并及时提交相关的自检报告。

(5) 承包人应努力做到保证完工资料编制与施工同步进行,保证完工资料的完整性和准确性。

(6) 承包人应对设计图纸中的标高等进行复核、测量,发现设计与现状不符,应在施工前书面提出,报监理人及发包人并与设计部门进行协调、修改。若承包人对设计图纸不进行校核,擅自施工,造成返工或其他损失的,一切损失由承包人负责承担。

(7)承包人应在施工组织设计建议书中就可预见的抗台风、雨季确保施工安全等制定方案和措施,并在工程实施过程中切实执行该方案和措施,由此所发生的一切费用应计入在相关项目的单价和合同总价之中,发包人不另行支付。未按此方案或措施进行施工而造成的一切损失或后果,发包人将不承担任何责任,由承包人自行承担。

(8)承包人在施工过程中应采取一切措施防止对施工现场及其周边地区的污染,应根据环保部门的规定制定保护方案并予以实施。由于承包人措施不力或未采取相应的措施造成的一切责任、损失及相应违约金均由承包人承担。

(9)承包人的施工组织应充分考虑施工期间的交通组织、设备、材料运输过程中的运输距离、安全问题、施工干扰问题,制定社会交通组织方案等,制定详细的保证措施并在施工中予以实施,由此所发生的一切费用承包人均应计入在相关项目的单价和合同总价中,发包人不另行支付。

(10)包括安全、质量、外观在内的所有永久性工程的施工,承包人必须提前一周提供专门的施工组织计划和施工方案报监理人审批同意后方可实施。

(11)承包人必须对本项目履行合同的管理班子主要成员进行书面授权,并于本合同签订后5日内将书面授权书报监理人审批后送发包人备案。

(12)跟踪本项目范围内的征地拆迁工作进展情况,协调解决施工中与当地居民发生矛盾,及时反馈与征地拆迁相关信息。

(13)承包人应按照相关规定,建立工程档案管理工作领导责任制和相关人员岗位责任制,明确工程档案管理配备管理必要人员及设施、设备地,统筹安排工程档案管理工作所需资金,建立健全工程档案管理各项规章制度,保证合理有序进行。凡未完成工程档案归档任务或工程档案质量不合格的,承包人应在发包人规定的期限内进行整改直至满足要求,否则发包人不予进行完工结算并上报有关行政主管部门,且承包人须支付违约金10万元。

(14)承包人在工程开工前必须考察了解各公用道路的通行能力,并据此制定相应的施工材料、设备的运输(通行)方案。承包人施工材料、设备的运输超出各公用道路的通行能力而造成的公用道路损害,承包人必须承担修复责任及修复费用。

(15)施工用水由承包人自行解决,发包人不另行支付。

(16)因承包人施工引发工程事故或安全事故,造成发包人及其他第三方人身、财产损失的,由承包人承担全部责任并赔偿全部损失。发包人的批准、验收等不作为承包人拒绝赔偿的理由。

(17)施工过程中,应注意施工安全重点关注部位及环节(基坑开挖、基坑监测、施工排水及异常处理等,具体详见施工图纸设计总说明)以及做好防范施工安全事故(如涉及到爆破安全作业、极端天气安全防护、基坑边坡监测等,具体详见具体详见施工图纸设计总说明),由此而产生的一切费用和工期延误责任由承包人承担。

4.3 分包

4.3.2 允许承包人分包的工程项目、工作内容与分包金额限额为:

(1)工程项目:_本工程不允许分包

(2)工作内容:本工程不允许分包

(3)分包金额限额:本工程不允许分包_。

4.3.10 分包人项目管理机构的设立:本工程不允许分包

4.5 承包人项目经理

4.5.1承包人应按投标承诺指派项目经理到职。合同期间承包人更换项目经理不论何种原因(含身体原因),都必须事先征得发包人批准同意,并应在更换14天前将拟代之以相当资历(投标时要求的项目经理资历)人员报经发包人、监理人批准,工作移接完毕并经发包人、监理人确认后方可离开。本合同的项目经理每次变更需缴纳违约金20万。若本合同的项目经理未到职,则每次须缴纳违约金人民币20万元。本合同的项目经理每月出勤不得少于22天,发包人有权制定考勤办法,承包人应遵守招标人制定的考勤制度。本合同的项目经理需常驻现场,短期离开施工场地,应事先征得监理人及发包人同意,并委派代表代行其职责。如发现项目经理未签到或没有在现场履行职责,且未事先征得监理人及发包人同意,则发包人可按承包人项目经理擅自离岗,每人每天3000元标准向发包人支付违约金。

4.6 承包人人员的管理

4.6.3承包人应按投标承诺指派技术负责人等主要管理人员到职,合同期间如需更换技术负责人等,需提前14天将拟代之以相应资历(投标时要求的技术负责人资历)人员报经发包人、监理人批准,工作移接完毕并经发包人、监理人确认后方可离开。本合同的技术负责人不论何种原因(含身体原因)未到职或更换的,都必须经招标人批准同意,每次变更需缴纳违约金20万。若本合同的技术负责人未到职,则每次须缴纳违约金人民币20万元。本合同的关键岗位人员(施工员、质检员、安全员、材料员、造价员、档案管理员)未到职或擅自更换每人次收取违约金人民币1万元。本合同的技术负责人和关键岗位人员每月出勤不得少于22天,发包人有权制定考勤办法。本合同的技术负责人和关键岗位人员需常驻现场,短期离开施工场地,应事先征得监理人及发包人同意。技术负责人擅自离岗,经发现每天收取违约金人民币3000元。关键岗位人员擅自离岗,经发现每天收取违约金人民币500元。承包人要求更换的人数不得超过总人数的30%,更换人员条件不得低于原配备的人员,并且除重大疾病无法履行岗位职责和人员离职外,其余情形项目部人员不得更换。本项目要求承包人应设置档案管理员岗位,并配备专职档案管理人员负责本项目合同实施过程的档案管理工作。

注:①重大疾病需提供“三甲”医院的证明材料,人员离职需提供本单位和当地社保部门盖章确认的减员证明。若开具虚假证明材料(因重大疾病而被更换的项目部人员,在半年内发现参与其他项目投标的视同开具虚假证明),将上报主管部门列入黑名单,并支付违约金人民币伍拾万元整;②以上违约金将直接在工程款中扣除。

4.11 不利物质条件

4.11.1 不利物质条件的范围:_无 _

5 材料和工程设备

5.1 承包人提供的材料和工程设备

5.1.2主要材料和工程设备选用表

序号

材料和工程设备名称

规格型号

选用的品牌/厂家

备注

1

2

3

甲控材料采购时,承包人应向发包人提交采购计划、采购品牌、采购价格,经发包人确认同意后方可采购;发包人有权对主要设备材料的生产、发货、出厂时的质量进行验收,必要时可派人进厂监造,同时保留对生产厂家的考察权利,费用由承包人承担。

增加5.1.4 本合同开挖渣料的所有权及调度权属发包人,在施工期间由承包人负责管理。承包人若需将渣料使用于本工程,需通过监理人,并经发包人批准。

5.2 发包人提供的材料和工程设备

5.2.1 发包人提供的材料和工程设备见下表:

发包人提供的材料表(参考格式)

序号

材料名称

材料规格

数量

交货地点

交货方式

计划交货日期

备注

/

/

/

/

/

/

/

/

发包人提供的工程设备表(参考格式)

序号

材料和工程设备名称

规格型号

选用的品牌/厂家

备注

/

/

/

/

/

6 施工设备和临时设施

6.2 发包人提供的施工设备和临时设施

(1)发包人提供的的施工设备见下表:

发包人提供的施工设备表(参考格式)

序号

设备名称

型号及规格

设备状况

数量

移交地点

计划移交日期

备注

/

/

/

/

/

/

/

/

注:设备状况栏内填写该设备的新旧程度、购进时间、已使用小时数和最近一次的大修时间。

(2)发包人提供的临时设施:_本招标项目发包人不提供施工设备和临时设施

7 交通运输

7.1 道路通行权和场外设施

道路通行权和场外设施的约定:承包人应根据合同工程的需要,负责办理并取得进入施工场地包括但不限于国道、省道、县道、乡道、村道(含村村通工程)、田间作业道等各级道路的通行权,同时负责办理各级路口使用手续和道路施工许可,以及取得为工程建设所需修建场外设施的权利,并承担相关费用。发包人协助承包人办理上述手续 。

其它:承包人应负责全部施工道路在整个施工期内的养护维修工作并承担相关费用。如改建、扩建而需要相关征地时,由承包人负责并承担相关费用

8 测量放线

8.1 施工控制网

8.1.1 施工控制网的约定:_按通用合同条款执行,由承包人负责_。

9 施工安全、治安保卫和环境保护

9.1 发包人的施工安全责任

9.1.4 发包人提供__招标文件所包含 _资料,其余资料由承包人负责收集。

9.2 承包人的施工安全责任

9.2.12 下列工程应编制专项施工方案:

(1)基坑支护与降水、度汛工程;

(2)土方和石方开挖工程;

(3)模板工程;

(4)起重吊装工程;

(5)脚手架工程;

(6)拆除、爆破工程;

(7)围堰工程;

(8)其他危险性较大的工程。

其中对前款所列工程涉及高边坡、深基坑、地下暗挖工程、高大模板工程的专项施工方案,承包人 应组织专家论证和审查,并承担相关费用。

9.3 承包人负责施工工区的安全保卫,费用由承包人承担,发包人不另行支付。

9.4 环境保护

增加 :施工现场需要排放有害污水的由承包人办理相关手续(包含特别相应许可手续),承包人在施工过程中应采取一切措施防止对施工现场和周边地区的污染,并按环保部门的规定指定保护方案严格实施。相应环保费用在投标时自行综合考虑报价,发包人不再另行支付。承包人应保障发包人免于承担因此引起的索赔、诉讼和律师费等其他费用。如发生上述费用,应由承包人承担。

9.7 文明工地

9.7.1 本合同文明工地的约定:承包人应制定详细完整的工程文明施工保证措施方案,方案中应明确人力、设备和资金准备投入情况。承包人必须遵守工程安全、文明施工管理等有关制度,并建立相应的管理体系和管理制度,实现安全无事故、创建文明施工现场的目标

9.7.2若工程所处位置在人口稠密的乡村城镇处、与乡道、县道及以上等级的交通路段交叉,围挡设计、围挡使用材料及安装应符合相关规范及规定,且费用由承包人承担,发包人不另行支付

9.7.3因工程施工临时用地的交地时间不同,发包人需提前协调有关单位对部分用地先行围挡,费用由承包人承担,发包人不在另行支付。

9.7.4承包人应按照相关规定和要求,切实做好项目施工期的环境保护、水土保持和湿地保护工作。环境保护和湿地保护工作所需费用由承包人承担

11 开工和完工

11.4 异常恶劣的气候条件

11.4.3 本合同工程界定异常恶劣气候条件的范围为:

(1)日降雨量大于50 mm的雨日连续超过3天;

(2)8 级以上热带气旋灾害;

(3)烈度7度以上地震。

11.5 承包人工期延误

(1)工期要求:总工期(日历天);其中关键节点要求:。

(2)因承包人原因造成工期(包括节点工期)延误,招标人有权要求承包人应按延误的工期天数支付逾期违约金人民币10000元/日历天。若承包人工期延误累计30日历天,发包人有权解除合同。

(3)逾期完工违约金按日历天计算,时间自预定的完工日期起到工程完工证书中写明的实际完工日期止(扣除已批准的延长工期)。

(4)全部逾期完工违约金的总限额为/

11.6 工期提前

工期提前的奖金约定:不奖励

12 暂停施工

12.1 承包人暂停施工的责任

(5)承包人承担暂停施工责任的其它情形:_/__。

12.2 发包人暂停施工的责任

(3)发包人承担暂停施工责任的其它情形:发包人可以根据不可预见的特殊情况暂停部分项目的施工,发包人只延长因该部分暂停施工增加的工期,不承担任何费用。如在此期间,发生物价波动,需调整价格的按专用合同条款第16条执行

13 工程质量

13.7 质量评定

13.7.4 重要隐蔽单元工程和关键部位单元工程质量评定的约定:达到合格标准

13.7.7 工程合格标准为:达到《水利水电工程施工质量检验与评定规程》(SL176-2007)及其它相关规范合格标准

13.8 质量事故处理

13.8.4 工程完工验收时,_承包人 向完工验收委员会汇报并提交历次质量缺陷处理的备案资料。

14 试验和检验

14.1 材料、工程设备和工程的试验和检验

14.1.5 水工金属结构、启闭机及机电产品进场后的交货检查和验收中,承包人负责_按通用合同条款执行

14.1.6 本工程实行见证取样的试块、试件及有关材料:按照水利工程质量检测技术规程执行

15 变更

15.1 变更的范围和内容

(6)单个项目工程量变动幅度超过±30%并导致合同总价变动幅度超过±1%的,单价调整方式:增加部分的工程量或减少后剩余部分的工程量,发、承包一方可以重新提出综合单价,经另一方审核后作为进度款付款依据,最终结算以财政审核为准;未超过上述幅度的,按合同已有的价格变更合同价款

15.4变更的估价原则

15.4.2 原规定外,增加“其单价或合价均应按本工程招标工程最高控制价编审依据的有关计价规定计算后,按承包人投标时投标总价与招标工程最高控制价的同等降低幅度计算该部分工程价格,送监理人、发包人审核,并由结算审核单位核定。

15.4.3原规定外,增加“其单价或合价均应按本工程招标工程最高控制价编审依据的有关计价规定计算后,按承包人投标时投标总价与招标工程最高控制价的同等降低幅度计算该部分工程价格,送监理人、发包人审核,并由结算审核单位核定。

15.5 承包人的合理化建议

15.5.2 承包人实现合理化建议的奖励金额为:不予奖励

15.6暂列金额

暂列金额只能按照发包人的批准使用,并对合同价格进行相应调整。

该项金额应按监理人指示,并经发包人批准后才能动用。承包人仅有权得到列入暂列金有关工作所需的费用和利润。监理人应报发包人批准后,将根据本款作出的决定通知承包人。

15.8 暂估价

15.8.1(1)发包人和承包人组织招标的暂估价项目:;发包人组织招标的暂估价项目:

(2)发包人和承包人以招标方式选择暂估价项目供应商或分包人时,双方的权利义务关系:/

16 价格调整

由于物价波动原因引起合同价格需要调整的,其价格调整方式16.1.2采用造价信息调整价格差额。

16.1.2.1在本工程实施中,无论发生任何物价波动等原因引起的价格变化,除钢板(钢管原材料)外的其它所有的承包人自行采购材料的价格等,均不作调整。承包人在投标报价时应考虑到任何可能引起价格波动的风险

16.1.2.2合同价款可按以下方式进行调整:

增减工程量按规定程序按实核增核减

增减工程量的单价确定i在工程量清单之内的项目,按承包人投标书中的工程量清单的综合单价计算;ii在工程量清单之外的项目,按照省市及项目所在地造价主管部门颁布的招标时使用的定额、费用标准、价格信息及中标价降幅系数计算。中标价降幅系数=投标总价(暂列金除外)/控制价总价(暂列金除外)。若定额缺项的,由承包人提出适当的单价(附单价分析表),经发包人会同监理人、工程预结算审核部门审核后确定。

③材料变更时价格确定:i承包人在投标文件中价格明细表已有的材料,按承包人材料价格明细表所列的材料单价计算;ii承包人材料价格明细表中没有的材料,参照福清市建设工程信息材料价格(福清市没有的,参照福州市)在投标期间公布的材料单价按中标价的综合单价编制原则计算;iii福清市建设工程信息材料价格及福州市建设工程信息材料价格没有公布的材料,由承包人提出适当的价格,发包人经市场询价后会同监理人、工程预决算审核部门询价审核后确定并报送造价管理部门备案

当施工期物价变动幅度较大,可以对钢板(钢管原材料)的价格进行调整,价格调整办法为:

以《福州建设工程造价管理信息》福清市2021年4信息价项目所在地(福清市没有的,参照福州市)(具体以编制预算采用的信息价月份为准)的建设工程主要材料综合价汇总价格为“基期价格”,与施工期间各月《福州工程造价管理》发布的项目所在地的建设工程主要材料综合价汇总价格为“报告期价格”对比,材料报告期价格与基期价格上涨或下降幅度在5%以内(含5%)的,其差价由承包人承担或受益,材料价格上涨或下降幅度超出上述约定幅度以外的,其超过的部分,按以下办法处理:

材料价格调整只计取材料差价和税金,不计取其他费用。

a.材料价差调整总额确定:材料价差调整总额=Σ月材料差价单价×月材料用量×(1+税率)。

b.材料用量的确定:按当月经核定实际完成合同合格工程量相应的月材料用量。

c.月材料差价单价调整的确定:月材料差价=[|(报告期价格-基期价格)|÷基期价格×100%-“约定幅度”]×基期价格。

因承包人造成工期延误的,在延误期间的材料上涨价差全部由承包人承担,下降幅度超过“约定幅度”的由发包人受益。

16.2 法律变化引起的价格调整

16.2.1法律法规政策引起的价格调整在基准日期后,因福建省水行政、建设行政主管部门颁布调整人工预算单价,从调整生效之日起按最新规定执行,只计取差价和税金,不计其他费用;调整规定生效之日前发生的不予调整。

17 计量与支付

17.1.3计量周期

按月对已完成的质量合格的工程进行计量。

17.2 预付款

17.2.1预付款

(1)工程预付款的总金额为签约合同价(不含暂列金)的10%。承包人须向发包人递交预付款使用计划,经监理人、发包人审查批准后支付给承包人,承包人应按批准的预付款使用计划实施。

(2)预付款的支付时间为:在合同协议书签订后,项目管理人员全部到位、主要设备进场后且发包人收到承包人的履约担保及发包人要求的相关材料(含预付款使用计划)后,经监理人出具付款证书报送发包人批准后予以支付(具体拨付以财政拨款规定为准);发包人有权根据现场准备情况及开工量分批支付预付款并调整预付款支付时间。

3)承包人不得将该预付款用于与本工程无关的支出,发包人有权监督检查承包人对该预付款的使用,如经查实承包人滥用工程预付款,发包人有权从工程进度款中提前收回全部预付款,并要求承包人按签约合同价的1%支付违约金,并赔偿发包人一切损失。

17.2.2预付款保函

(1)本项目不要求承包人提交预付款保函。

17.2.3 预付款的扣回与还清

在支付的各期工程进度款中按当期支付的工程款的10%扣回工程预付款。当工程支付至签约合同价的80%时,预付款应全部扣回。

17.3 工程进度款

17.3.1①按月支付工程进度款。清单内项目按当月确定的符合质量要求的工程量所含款项的80%支付进度款,变更项目支付的价款按照福清市有关规定执行;

②工程完工并经有关部门进行验收合格,承包人提交完整的结算资料后,工程进度款支付至合格工程量所含款项(不超过签约合同价)的 85%。

③工程完工验收合格并结算经财政审定后,款项付至审核价的97%;工程缺陷责任期满后付至100%。

(各阶段拨付以财政拨款规定为准,发包人付款前,承包人须提交等额的增值税专用发票,否则,发包人有权不支付款项且无需承担违约责任)。

17.4 质量保证金

17.4.1 扣留的质量保证金总额为签约合同价的工程完工验收结算价款的3%

17.5 完工结算

17.5.1完工付款申请单

(1)承包人应提交完工付款申请单一式 份。

(3)工程完工验收合格后,在3个月内编制完成工程结算,并经监理审核,由监理出具初审报告后,送达建设单位审核,资料必须完整、真实、有效。每延误一天,按5000元/天支付违约金。

17.6 最终结清

17.6.1 最终结清申请单

(1)承包人应提交最终结清申请单一式__份。

17.7 财务决算

承包人应为财务决算编制提供的资料:_按国家有关规定

18验收

18.1 验收工作分类

本工程为法人验收,按照完工验收要求进行验收。

18.2 分部工程验收

18.2.2 本工程由发包人主持的分部工程验收为/,其余由监理人主持。

18.3 单位工程验收

18.3.4 提前投入使用的单位工程包括:_/

18.5 阶段验收

18.5.1 本合同工程阶段验收类别包括:/

18.6 专项验收

18.6.2 本合同工程专项验收类别包括:/

18.7 验收

18.7.3 本工程_按有关规定,视情况确定_(需要/不需要)验收技术鉴定(蓄水安全鉴定)。

18.8 施工期运行

18.8.1 需要在施工期运行的单位工程或工程设备为:/

18.9 试运行

18.9.1 试运行的组织:按通用合同条款约定 ;费用承担:按通用合同条款约定__。

增加18.12 完工验收资料

(1)本工程完工验收前,承包人必须按本合同及有关法规、规程的要求完成相应的验收签证、质量评定工作及编制完工资料,发包人将制定印发具体的管理办法,完工资料须经监理人审定,具体内容执行:国家档案局、国家发改委等政府颁布的法规的要求。

(2)完工资料壹式陆份,主要内容包括(但不限于):

①原始资料部分(原件一式1份,复印件3份,A4纸,电子文件1套):

a.主要原材料出厂合格证和质量检查、试验资料,材料代用的批准文件;

b.土建与金结制安工程质量检验原始记录;

c.隐蔽工程质量验收原始记录;

d.重大质量事故和工程缺陷处理资料;

e.按有关法规、规程和发包人合理要求的其它资料;

②重要文件部分

a.工程施工总结及大事记(一式陆份);

b.生产性试验总结及成果分析报告;

c.工程实施进度及措施的记录(包括文字记录和图象资料);

d.工程完工图及工程量清单;

e.单元工程质量等级评定资料及其验收鉴定证书;

f.重大质量事故及处理记录;

g.重要财务和完工决算资料;

h.设备供应厂商的技术通知单;

i.工程施工报告及完工报告;

j.设备、备品、专用工具和专用器材清单;

k.设计通知单;

l.监理通知单;

m.发包人文件;

n.工程施工《会议纪要》;

o.发包人、承包人往来文件;

p.发包人和监理人认为其它重要的文件。

③完工图纸(一式陆份)

a.各工程完工图(含资料等);

b.各项隐蔽工程详图(含资料等);

c.制造厂提供的有关技术文件及图纸;

e.工程测量图。

④需提交验收委员会及汇编成册的完工资料陆套(电子文件1套)。

⑤承包人应根据发包人提供的表格式样制作各类验收单,费用由承包人承担。

⑥承包人应协助发包人完成工程完工验收、质量安全鉴定等工作,提供相关验收、鉴定资料,相关费用由承包人承担。

上述材料根据由承包人根据实际情况提供,并对完整性负责。

19 缺陷责任与保修责任

19.1 缺陷责任期(工程质量保修期)的起算时间

本工程缺陷责任期(工程质量保修期)计算如下:_工程通过合同工程完工验收后1年。发包人在缺陷责任期满,且工程完工结算审核完成后将剩余质量保证金返还承包人(不计利息)

20 保险

20.1 工程保险

建筑工程一切险和(或)安装工程一切险投保人_承包人购买,费用包括在报价中

投保内容:为本合同工程的永久工程、临时工程和设备及已运至施工工地用于永久工程的材料和设备所投的保险;

保险金额、保险费率和保险期限:开工日期直至本合同工程签发完工验收证书之日止。

20.4 第三者责任险

20.4.2 第三者责任险保险费率:承包人投保 ,费用包括在报价中__;

第三者责任险保险金额:第三者责任系指在保险期内,对因工程意外事故造成的、依法应由被保险人负责的工地上及毗邻地区的第三者人身伤亡、疾病或财产损失(本工程除外), 以及被保险人因此而支付的诉讼费用和事先经保险人书面同意支付的其他费用等赔偿责任

20.5 其他保险

20.5.1承包人应根据国家、福建省和福清市行政管理部门关于保险险种方面的要求(特别是意外伤害保险)购买施工总承包方应购买的相关保险,并使相关保险在本合同要求的保险有效期内保持足额、持续有效。相关费用已包含在合同价款中。

20.5.2承包人应承担为其施工设备、进场的材料、工程设备和农民工等办理保险。

20.6 对各项保险的一般要求

20.6.1 保险凭证

承包人提交保险凭证的期限:承包人向发包人提交各项保险生效的证据和保险单副本的期限:开工前;

保险条件:__满足发包人及施工现场的保险需求_。

20.6.4 保险金不足的补偿

承包人负责补偿的范围与金额:承包人确认不因发包人或承包人购买保险而免除承包人在本工程实施中的相关义务和需承担的责任,保险赔偿不足的部分由承包人自行承担,包括但不限于免赔额、赔偿限额以外的损失、保险责任不成立的损失等。发包人负责补偿的范围与金额:/

增加

20.6.8保险事项的事故发生时,承包人应及时对现场情况、损坏物品进行拍照或摄像,第一时间做好安抚解释工作,并采取一切必要合理的措施防止损失进一步扩大,注意保留好事故现场照片作为事故发生的证据。

20.6.9承包人充分理解,无论保险为发包人购买还是承包人购买,承包人均可能构成一项保险合同中的被保险人。当保险事故发生后,承包人应负责准备保险理赔资料或证明,并履行保险合同中被保险人的其他义务。若发生理赔被拒绝或理赔不足是承包人原因造成的,则该部分未理赔损失由承包人承担。对于理赔程序,双方都应有配合对方的义务。

20.6.10发包人及承包人从保险公司处收到的付款应用于修正工程项目的对应损失或损害。

20.6.11承包人应在项目公司内设置对接部门及专职人员对项目的工程保险(包括但不限于建筑(安装)工程一切险及第三者责任险)的报险和理赔进行统筹管理。各标段(包括但不限于土建、常规设备安装与装修、系统设备安装标等)发生保险事故时由项目公司统一组织并安排保险理赔的相关工作,包括但不限于事故报案、资料提交、定责定损谈判等。

20.6.12承包人充分了解,由发包人负责购买的保险在发包人签订保险合同之前,向承包人提供的保险合同承保条件均只供承包人参考。承包人承诺,不因发包人与保险公司最终签订的保险合同的承保条件与发包人在签订保险合同之前提供的不一致,而向发包人提出任何权利主张。

20.6.13承包人应提前对周边第三者建筑物、交叉或临近设施进行事先勘查,必须采取一切必要、安全预防措施以防止本工程沿线临近区域第三者建筑物或设施开裂、沉降等损坏,发现临近房屋出现开裂,或安全设施移动、软弱或其他异常状况应做好拍照或摄像并留底。

20.6.14承包人应在施工过程中严格按照行业标准规范施工,并对爆破振速、沿线周边房屋情况等内容进行监测,出具初步监测观察报告,如有必要请第三方爆破监测机构,按规范出具监测报告。

20.6.15现场接到受损村民报损后,由承包人立即通知业主、保险经纪人及保险公司。

20.6.16承包人组织到场保险公司、鉴定机构人员、保险经纪人一起进行全面现场查勘。

20.6.17承包人负责准备各项理赔单证、证明材料等,汇总并提交保险经纪人,并索取材料送达清单。

20.6.18在各方对保险责任、损失金额等项问题发生争议时,承包人应积极配合处理,尽早解决争议,达成一致。

20.6.19承包人承担鉴证、鉴定费用,按鉴定结果向受损居民先行赔付。对于超出保险公司理赔限额的部分,承包人承担赔付责任。

22.违约

22.1.3承包人违约解除合同

22.1.4 承包人违反本合同约定的义务,除依约承担违约责任外,给发包人造成损失的,还应承担赔偿责任,赔偿范围包括但不限于律师费、调查取证费、公证费、差旅费、工期延误损失、对外经济赔偿等。合同涉及的承包人的违约金和赔偿款等,从履约担保或发包人支付的合同款项中扣减,不足的由承包人补足。

23.索赔

23.5 以下情况不属于索赔范围

发包人认为承包人不能按时完工时,可将剩余工程的全部或部分另行发包,承包人不得提出索赔要求。

24 争议的解决

24.1 争议的解决方式

合同当事人友好协商解决不成、不愿提请争议评审或不接受争议评审组意见的,约定的合同争议解决方式:_向福州仲裁委员会提出仲裁 _。

25.其他特别事项

同“第二章 投标人须知 其他要求”。


第三节 合同附件格式

附件一:合同协议书(格式)

合同协议书

_________________(发包人名称,以下简称“发包人”)为实施_________________(项目名称), 已接受_________________(承包人名称,以下简称“承包人”)对_________________(项目名称)_________________(标段名称)的投标, 并确定其为中标人。发包人和承包人共同达成如下协议。

1. 本协议书与下列文件一起构成合同文件:

(1)合同协议书及各种合同附件(含评标期间和合同谈判过程中的澄清文件和补充资料);

(2)中标通知书;

(3)专用合同条款;

(4)通用合同条款;

(5)投标函及投标函附录;

(6)技术标准和要求;

(7)图纸;

(8)已标价工程量清单;

(9)承包人有关人员、设备投入的承诺及投标文件中的施工组织设计;

(10)本工程施工招标文件(含招标文件补充答疑等);

(11)其他合同文件。

2. 上述文件互相补充和解释,如有不明确或不一致之处,以合同约定次序在先者为准。

3. 签约合同价:人民币(大写)______________(¥______________)。

4. 承包人项目经理:______________。

5. 工程质量符合______________标准。

6. 承包人承诺按合同约定承担工程的实施、完成及缺陷修复。

7. 发包人承诺按合同约定的条件、时间和方式向承包人支付合同价款。

8. 承包人应按照监理人指示开工,合同工期为______天。

9. 本协议书一式______份,合同双方各执______份。

10. 合同未尽事宜,双方另行签订补充协议。补充协议是合同的组成部分。

发包人:_______________________________(盖单位章)

法定代表人或其委托代理人:_______(签字)

_________年______月_____日

承包人:_______________________________(盖单位章)

法定代表人或其委托代理人:______(签字)

_________年______月_____日

附件二:履约保证金(格式)

附件2-1:履约担保

履约担保

(发包人名称):

鉴于(发包人名称,以下简称“发包人”)已接受(承包人名称,以下称“承包人”)于年月日递交的(项目名称)( 标段名称)的投标文件。我方愿意无条件地、不可撤销地就承包人履行与你方订立的合同,向你方提供担保。

1. 担保金额人民币(大写)元(¥元)。

2. 担保有效期自发包人与承包人签订的合同生效之日起至发包人签发合同工程完工证书之日止。

3. 在本担保有效期内,因承包人违反合同约定的义务,我方在收到你方以书面形式提出的在担保金额内的赔偿要求后,无条件地在7天内予以支付。

4. 发包人和承包人按 《通用合同条款》第15条变更合同时,我方承担本担保规定的义务不变。

担保人:(盖银行单位章)

法定代表人或其委托代理人:(签字)

地 址:

邮政编码:

电 话:

传 真:

年月日

附件2-2-工程担保保函格式:

工程担保保函

(发包人名称):

鉴于(发包人名称,以下简称“发包人”)与

(承包人名称)(以下称“承包人”)于 年 月 日参加

(项目名称) 标段施工的投标。我方愿意无条件地、不可撤销地就承包人履行与你方签订的合同,向你方提供连带责任担保。

1. 担保金额人民币(大写)元(¥)。

2. 担保有效期自你方与承包人签订的合同生效之日起至发包人签发合同工程完工证书之日止。

3. 在本担保有效期内,因承包人违反合同约定的义务,我方在收到你方以书面形式提出的在担保金额内的赔偿要求后,在7天内无条件支付。

4. 你方和承包人按合同约定变更合同时,我方承担本担保规定的义务不变。

5. 因本保函发生的纠纷,可由双方协商解决;协商不成的,任何一方应向《建设工程施工合同》专用条款约定的同一仲裁机构提起仲裁;《建设工程施工合同》未约定仲裁机构的,向工程所在地人民法院提起诉讼。

6. 本保函自我方法定代表人(或其委托代理人)签字并加盖公章之日起生效。

担 保 人:(盖单位章)

法定代表人或其委托代理人:(签字)

地 址:

邮政编码:

电 话:

传 真:

年月日

备注:本履约担保格式可以采用经发包人同意的其他格式,但相关内容不得违背合同约定的实质性内容。

附件2-3-建设工程保证保险格式:

履约保证保险(凭证)

(发包人名称):

鉴于(发包人名称,以下简称“发包人”)接受(承包人名称,以下称“承包人”)于年月日参加(项目名称)标段施工的投标。我方愿意无条件地、不可撤销地就承包人履行与你方订立的合同,向你方提供履约保证保险。

1. 保险单号:。

2. 履约保证保险金额人民币(大写)元(¥ )。

3. 保险有效期自发包人与承包人签订的合同生效之日起至发包人签发合同工程完工证书之日止。

4. 在本保险有效期内,因承包人违反合同约定的义务,我方在收到你方以书面形式提出的在履约保证保险金额内的赔偿要求后,在7天内无条件支付。

5. 发包人和承包人按合同约定变更合同时,我方承担保险合同约定的义务不变。

6. 因本保险发生的纠纷,可由双方协商解决,协商不成的,任何一方应向《建设工程施工合同》专用条款约定的同一仲裁机构提起仲裁;《建设工程施工合同》未约定仲裁机构的,向工程所在地人民法院提起诉讼。

7. 本保险自我方法定代表人(或其委托代理人)签字并加盖公章之日起生效。

保 险 人:(盖单位章)

法定代表人或其委托代理人:(签字)

地 址:

邮政编码:

电 话:

传 真:

年月日

备注:本履约保证保险(凭证)格式可以采用经发包人同意的其他格式,但相关内容不得违背合同约定的实质性内容。

附件三:预付款担保函(格式)(本项目不适用)

如采用银行保函,格式如下。

预付款担保函

___________________(发包人名称):

根据___________________(承包人名称,以下简称“承包人”)与___________________(发包人名称,以下简称“发包人”)于_____年_____月_____日签订的___________________(项目名称)___________________(标段名称)合同协议书,承包人按约定的金额向发包人提交一份预付款担保,即有权得到发包人支付相等金额的预付款。我方愿意就你方提供给承包人的预付款提供担保。

1. 担保金额人民币(大写)________________(¥________________)。

2. 担保有效期自预付款支付给承包人起生效,至发包人签发的进度付款证书说明预付款已完全扣清止。

3. 在本担保有效期内,因承包人违反合同约定的义务而要求收回预付款时,我方在收到你方的书面通知后,无条件地在7天内予以支付。但本担保的担保金额,在任何时候不应超过预付款金额减去发包人按合同约定在向承包人签发的进度付款证书中已扣回的金额。

4. 发包人和承包人按《通用合同条款》第15条变更合同时,我方承担本担保规定的义务不变。

担保人名称 :_____________________________(盖单位章)

法定代表人(单位负责人)或其委托代理人:________签字)

地 址:____________________________________________

邮政编码:____________________________________________

电 话:____________________________________________

________年_____月____日

附件四:法定代表人授权书(格式)

法定代表人授权书

兹授权我单位 ______________ (姓名)担任_____________工程项目的(施工)项目负责人,对该工程项目的(施工)工作实施组织管理,依据国家有关法律法规及标准规范履行职责,并依法对设计使用年限内的工程质量承担相应终身责任。

本授权书自授权之日起生效。

被授权人基本情况

姓名

_______

身份证号

______

技术职称

_______

职称证书号

______

注册执业资格

_______

注册执业证号

______

被授权人签字:

授权单位(盖章)________________

法定代表人(签字):________________

授权日期:________年________月________日

附件五:工程质量终身责任承诺书(格式)

工程质量终身责任承诺书

本人受 ________________________单位(法定代表人________________)授权,担任______________________工程项目的(施工)项目负责人,对该工程项目的(施工)工作实施组织管理。本人承诺严格依据国家有关法律法规及标准规范履行职责,并对设计使用年限内的工程质量承担相应终身责任。

承诺人签字:________________

身 份 证 号:________________

注册执业资格________________

注册执业证号:________________

签 字 日 期:________年________月________日

附件六:安全生产合同

安全生产合同

为在(工程名称)施工合同的实施过程中创造安全、高效的施工环境,切实搞好本项目的安全管理工作,本项目发包人(发包人名称,以下简称“发包人”)与承包人(承包人名称,以下简称“承包人”)特此签订安全生产合同:

一、发包人职责

1、严格遵守国家有关安全生产的法律法规,认真执行工程承包合同中的有关安全要求。

2、按照“安全第一、预防为主”和坚持“管生产必须管安全”的原则进行安全生产管理,做到生产与安全工作同时计划、布置、检查、总结和评比。

3、重要的安全设施必须坚持与主体工程“三同时”的原则,即:同时设计、审批,同时施工,同时验收,投入使用。

4、定期召开安全生产调度会,及时传达中央及地方有关安全生产的精神。

5、组织对承包人施工现场安全生产检查,监督承包人及时处理发现的各种安全隐患。

二、承包人职责

1、严格遵守《中华人民共和国安全生产法》、《建设工程安全生产管理条例》等国家有关安全生产的法律法规、《水利工程建设安全生产管理规定》等水利部颁发的有关安全生产的规定。认真执行工程承包合同中的有关安全要求。

2、坚持“安全第一、预防为主”和“管生产必须管安全”的原则,加强安全生产宣传教育,增强全员安全生产意识,建立健全各项安全生产的管理机构和安全生产管理制度,配备专职及兼职安全检查人员,有组织有领导地开展安全生产活动。各级领导、工程技术人员、生产管理人员和具体操作人员,必须熟悉和遵守本合同的各项规定,做到生产与安全工作同时计划、布置、检查、总结和评比。

3、建立健全安全生产责任制。从派往项目实施的项目经理到生产工人(包括临时雇请的民工)的安全生产管理系统必须做到纵向到底,一环不漏;各职能部门、人员的安全生产责任制做到横向到边,人人有责。项目经理是安全生产的第一责任人。现场设置的安全机构,应按施工人员的1%~3%配备专职安全生产管理人员,专职负责所有员工的安全和治安保卫工作及预防事故的发生。安全机构人员有权按有关规定发布指令,并采取保护措施防止事故发生。

4、承包人在任何时候都应采取各种合理的预防措施,防止其员工发生任何违法、违禁、暴力或妨碍治安的行为。

5、承包人必须具有劳动安全管理部门颁发的安全生产考核合格证书,参加施工的人员,必须接受安全技术教育,熟知和遵守本工种的各项安全技术操作规程,定期进行安全技术考核,合格者方准上岗操作。对于从事电气、起重、建筑登高架设作业、锅炉、压力容器、焊接、机动车船艇驾驶、爆破、潜水、瓦斯检验特殊工种的人员,经过专业培训,获得《安全操作合格证》后,方准持证上岗。施工现场如出现特种作业无证操作现象时,项目经理必须承担管理责任。

6、对于易燃易爆的材料除应专门妥善保管之外,还应配备有足够的消防设施,所有施工人员都应熟悉消防设备的性能和使用方法;承包人不得将任何种类的爆炸物给予、易货或以其他方式转让给任何其他人,或允许、容忍上述同样行为。

7、操作人员上岗,必须按规定穿戴防护用品,施工负责人和安全检查员应随时检查劳动防护用品的穿戴情况,不按规定穿戴防护用品的人员不得上岗。

8、所有施工机具设备和高空作业的设备均应定期检查,并有安全员的签字记录,保证其经常处于完好状态;不合格的机具、设备和劳动保护用品严禁使用:

9、施工中采用新技术、新工艺、新设备、新材料时,必须制定相应的安全技术措施,施工现场必须具有相关的安全标志牌。

10、承包人必须按照本工程项目特点,组织制定本工程实施中的生产安全事故应急救预案;如果发生安全事故,应按照《国务院关于特大安全事故行政责任追究的规定》以及其他有关规定,及时上报有关部门,并坚持“四不放过”的原则,严肃处理相关责任人。

三、违约责任

如因发包人或承包人违约造成安全事故,将依法追究责任。

在安全文明施工检查中,承包人在接到整改通知书、意见单等文件后7天内未整改到位的,须向发包人缴纳违约金,具体如下:

1、在业主、监理的检查中,承包人未在7天内整改到位的,应向发包人支付违约金1万元。违约金在当月支付工程进度款中扣除,并同时按要求整改到位。

2、在行业行政主管部门及上级有关部门的检查中,承包人未在7天内整改到位的,应向发包人支付违约金5万元。违约金在当月支付工程进度款中扣除,并同时按要求整改到位。

3、承包人工地因安全、文明施工问题被媒体曝光的,承包人应向发包人支付违约金10万元。违约金在当月支付工程进度款中扣除,并同时按要求整改到位。

4、承包人工地发生安全事故的,除依法追究责任外,承包人应向发包人支付违约金20万元。违约金在当月支付工程进度款中扣除,并同时按要求整改到位。

5、违约金如有不足,发包人有权追偿。

四、本合同由双方法定代表人或其授权的代理人签署并加盖单位章或合同章后生效,全部工程完工验收后失效。

五、本合同一式拾份,双方各执伍份。

发包人:(盖单位公章或合同章) 承包人:(盖单位公章或合同章)

法定代表人 法定代表人

或其委托代理人:(签章) 或其委托代理人:(签章)

年月日 年月日

附件七:工程质量保修书

工程质量保修书

发包人:发包人名称)承包人承包人名称)

发包人、承包人经协商一致,对(工程名称 )签订工程质量保修书。

第一条工程质量保修范围和内容

1、承包人在质量保修期内,按照有关法律、法规、规章的管理规定和双方约定,承担本工程质量保修责任。

2、质量保修范围以工程量清单及图纸的内容为准。具体保修的内容,双方约定如下:承包人负责保修(工程名称)施工图纸包含的由承包人承包施工的全部工程内容。

第二条质量保修期

本工程质量保修期为:工程通过合同工程完工验收后1

第三条质量保修责任

1、属于保修范围、内容的项目,承包人应当在接到保修通知之日起24小时内派人保修。承包人不在约定期限内派人保修的,发包人可以委托他人修理。维修费用从质量保证金内扣除。

2、发生紧急抢修事故的,承包人在接到事故通知后,应当在接到事故通知后12小时内到达事故现场抢修。非承包人施工质量引起的事故,抢修费用由发包人承担。

3、质量保修完成后,由发包人组织验收。

第四条保修费用

保修费用由造成质量缺陷的责任方承担。

第五条其他

1、发包人在缺陷责任期满,且工程完工结算审核完成后将剩余保证金返还承包人(不计利息)。

2、双方约定的其他工程质量保修事项:无。

3、本工程质量保修书为施工合同附件,由合同双方法定代表人或其授权的代理人签署并加盖单位公章(或合同章)后生效。

发包人:(盖单位公章或合同章) 承包人:(盖单位公章或合同章)

法定代表人 法定代表人

或其委托代理人:(签章) 或其委托代理人:(签章)

年月日 年月日

附件八:廉政合同

廉政合同

根据有关工程建设、廉政建设的规定,为做好工程建设中的党风廉政建设,保证工程建设高效优质,保证建设资金的安全和有效使用以及投资效益,建设工程的项目法人(以下简称“甲方”)与施工单位(以下简称“乙方”),特订立如下合同。

1. 甲乙双方的权利和义务

(1)严格遵守党的政策规定和国家有关法律法规有关规定。

(2)严格执行工程的合同文件,自觉按合同办事。

(3)双方的业务活动坚持公开、公正、诚信、透明的原则(法律认定的商业秘密、国家涉密项目和合同文件另有规定除外),不得损害国家和集体利益,违反工程建设管理规章制度。

(4)建立健全廉政制度,开展廉政教育,设计廉政告示牌,公布举报电话,监督并认真查处违法违纪行为。

(5)发现对方在业务活动中有违反廉政规定的行为,有及时提醒对方纠正的权利和义务。

(6)发现对方严重违反合同义务条款的行为,有向其上级有关部门举报、建议给予处理并要求告知处理结果的权利。

2. 甲方的义务

(1)甲方及其工作人员不得以任何形式向乙方索要和收受回扣等好处费。

(2)甲方及其工作人员不得索要或接受乙方的礼金、有价证券和贵重物品,不得在乙方报销任何应由甲方或甲方工作人员个人支付的费用等。

(3)甲方工作人员不得参加乙方安排的宴请和娱乐活动;不得接受乙方提供的通讯工具和高档办公用品等。

(4)甲方及其工作人员不得要求或者接受乙方为其住房装修、婚丧嫁娶活动、配偶子女的工作安排以及出国出境、旅游等提供方便等。

(5)甲方工作人员及其配偶、子女不得从事与甲方工程有关的材料设备供应、工程分包、劳务等经济活动等。

(6)甲方及其工作人员不得以任何理由向乙方推荐分包单位或推销材料,不得要求乙方购买合同规定外的材料和设备。

(7)甲方工作人员要秉公办事,不准营私舞弊,不准利用职权从事各种个人有偿中介活动和安排个人施工队伍。

3. 乙方义务

(1)乙方不得以任何理由向甲方及其工作人员行贿或馈赠礼金、有价证券、贵重礼品。

(2)乙方不得以任何名义为甲方及其工作人员报销应由甲方单位或个人支付的任何费用。

(3)乙方不得以任何理由安排甲方工作人员参加宴请及娱乐活动和参加可能对公正执行公务有影响的邀请。

(4)乙方不得为甲方单位和个人购置或提拱通讯工具和高档办公用品等。

(5)乙方不得为谋取私利擅自与甲方工作人员就项目承包、费用、材料设备供应、数量变动、完工验收、质量问题处理等进行私下商谈或者达成默契。

4. 违约责任

(1)甲方及其工作人员违反本合同规定者,按管理权限,依据有关规定给予党纪、政纪或组织处理;涉嫌犯罪的,移交司法机关追究刑事责任;给乙方单位造成经济损失的,应予以赔偿。

(2)乙方及其工作人员违反本合同规定或者采用不正当的手段行贿甲方工作人员者,按管理权限,依据有关规定给予党纪、政纪组织处理;给甲方单位造成经济损失的,应予以赔偿;情节严重的,甲方建议建设主管部门给予乙方一至三年内不得进入其主管的工程建设市场的违约责任。。

5. 双方约定:本合同由双方或双方上级单位的纪检监察机关负责监督执行。由甲方或甲方上级单位的纪检监察机关约请乙方或乙方上级单位纪检监察机关对本合同执行情况进行检查,提出在本合规定范围内的裁定意见。

6. 本合同有效期为甲乙双方法定代表人或其授权的代理人签署并加盖单位章(或合同章)之日起至保修期届满后终止。

7. 本合同作为江阴港城经济区新厝产业区原水管道工程 (施工)合同》的附件,与主合同具有同等的法律效力,经合同双方签署立即生效。

8. 本合同一式十份,甲乙双方正本各执一份,副本各执四份。

甲 方:(盖单位公章或合同章) 乙 方:盖单位公章或合同章

法 定 代 表 人: 法 定 代 表 人:

或 或

其授权的代理人:(签字或盖章其授权的代理人:(签字或盖章

电 话: 电 话:

日 期: 日 期:

附件九:保密协议书

江阴港城经济区新厝产业区原水管道工程 (施工)保密协议书

甲方:福清市水系联排联调中心

乙方:

甲方与乙方就江阴港城经济区新厝产业区原水管道工程 (施工)招投标和实施过程相关的保密事宜达成如下协议:

1.甲、乙方对江阴港城经济区新厝产业区原水管道工程 (施工)招投标和实施过程中从对方获知的保密信息,互负保密义务。

2.上述保密信息,包括但不限于以下非可经公共途径获取的信息:

1)以书面文件、计算机生成或存储等其他形式记载的信息;

2)以口头方式披露,且披露时说明须保密的信息。

3.上述保密信息只能在 江阴港城经济区新厝产业区原水管道工程 (施工)招投标和实施过程范围内使用,而不能用于项目招投标和实施过程范围外的其他目的;

4.甲、乙方各自确认双方涉密人员范围,范围之外人员未经双方授权不得接触相关保密信息;

5.非经对方书面同意,甲、乙双方不得以任何方式向任何第三方泄露、出售、出租、转让、许可使用或共享对方的保密信息;

6.如果因履行相关协议的需要,乙方需向第三方披露甲方的保密信息,应事先获得甲方的书面许可,并确保第三方遵守与本协议内容实质相同之保密义务;

7.双方应妥善保护所获取的对方的保密信息,并对涉密人员进行经常性保密教育,检查纠正保密工作中的偏差,一旦发生保密信息泄露事件,应主动及时采取补救措施,并依照有关规定,尽快向对方及有关部门(含保密行政管理部门)做出书面报告;

8.一方违反本协议给对方造成损失的,应承担相应的赔偿责任。若造成严重后果,将依据《中华人民共和国保守国家秘密法》等有关法律法规承担相关责任;

9.本协议的效力及于相关协议的履行期间及协议完成后十年;

10.本保密协议为施工合同附件,由合同双方法定代表人或其授权的代理人签署并加盖单位章(或合同章)后生效。一式拾份,双方各执伍份。

甲方:(盖单位公章或合同章)

乙方:(盖单位公章或合同章)

法定代表人

或其委托代理人:

法定代表人

或其委托代理人:

电话:

电话:

传真:

传真:

地址:

地址:

附件十:保密承诺书

保密承诺书

(适用在岗人员)

我了解有关保密法规制度,知悉应当承担的保密义务和法律责任。本人庄重承诺:

一、认真遵守国家保密法律、法规和规章制度,履行保密义务;

二、不提供虚假个人信息,自愿接受保密审查;

三、不违规记录、存储、复制国家秘密信息,不违规留存国家秘密载体;

四、不以任何方式泄露所接触和知悉的国家秘密;

五、未经单位审查批准,不擅自发表涉及未公开工作内容的文章、著述;

六、离岗时,自愿接受脱密期管理,签订保密承诺书。违反上述承诺,自愿承担党纪、政纪责任和法律后果。

七:本保密承诺书为施工合同附件,自签署之日生效,壹式拾份。

法定代表人签名:

承诺人签名:

单位名称(公章):

年 月 日

","template":"","PROJECT_PRICE_LIST_ATTACHMENTS":[{"id":"6109f8e661b96f2060d1a33e","md5":"FC83440316A793322D736ACF840DEB85","name":"工程项目总价表.xlsx","new_id":"6109f8e661b96f2060d1a33e","size":21937,"url":"/file/getcontent/6109f8e661b96f2060d1a33e.xlsx"}],"TOTAL_PROJECT_PRICE_LIST_SELECT":"工程项目总价表","CONSTRUCTION_PROJECT_AMOUNT_PRICE_LIST_SELECT":"建筑工程工程量清单报价表","TEMPORARY_PROJECT_AMOUNT_PRICE_LIST_SELECT":"临时工程工程量清单报价表","OTHER_PROJECT_AMOUNT_PRICE_LIST_SELECT":"无","ELECTRICAL_OR_METALLIC_STRUCTURES_PROJECT_AMOUNT_PRICE_LIST_SELECT":"无","EQUIPMENT_AND_INSTALLATION_PROJECT_AMOUNT_PRICE_LIST_SELECT":"设备及安装工程工程量清单报价表","OTHER_INDUSTRY_PROJECT_AMOUNT_LIST_ATTACHMENTS":[],"SUPPLEMENTARY_LIST_ATTACHMENTS":[],"TOTAL_PROJECT_PRICE_LIST":[{"index":"第一部分","name":"建筑工程","cost":"","remark":""},{"index":"第二部分","name":"输水管线设备及安装工程","cost":"","remark":""},{"index":"第三部分","name":"临时工程","cost":"","remark":""},{"index":"","name":"小计(元)","cost":"","remark":""},{"index":"","name":"总 计","cost":"","remark":""}],"PRIMARY_LIST":[{"PROJECT_NUMBER":"第一部分","PROJECT_LIST_NAME":"建筑工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"一","PROJECT_LIST_NAME":"管道土建工程","UNIT":"","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"拆除混凝土路面","UNIT":"m3","QUANTITIES":"1165.83","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"拆除路面水泥稳定层","UNIT":"m3","QUANTITIES":"1133.78","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"拆除路面碎石层","UNIT":"m3","QUANTITIES":"1207.71","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"拆除路沿石(立缘石) (石质截面半周长50cm以内)","UNIT":"m","QUANTITIES":"579.86","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"拆除路沿石(立缘石) (石质截面半周长50cm以外)","UNIT":"m","QUANTITIES":"222","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"商品混凝土路面 厚度22cm","UNIT":"m2","QUANTITIES":"5299.22","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"路基预拌商品5%水泥稳定层厚度20cm","UNIT":"m2","QUANTITIES":"5299.22","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"路面基层 碎石 压实厚度20cm","UNIT":"m2","QUANTITIES":"5299.22","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"拆除人行道面砖","UNIT":"m3","QUANTITIES":"66.54","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"人行道20*10*6cm彩色环保透水砖(1:3干拌水泥砂浆厚30)","UNIT":"m2","QUANTITIES":"739.32","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"人行道预拌商品5%水泥稳定层厚度10cm","UNIT":"m2","QUANTITIES":"739.32","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"人行道基层 碎石 压实厚度20cm","UNIT":"m2","QUANTITIES":"739.32","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"13","PROJECT_LIST_NAME":"路缘石铺设 石质缘石(利用旧路缘石)","UNIT":"延长m","QUANTITIES":"801.86","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"14","PROJECT_LIST_NAME":"挖沟槽土方2m以内 土类级别 Ⅲ","UNIT":"m3","QUANTITIES":"7406.75","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"15","PROJECT_LIST_NAME":"挖沟槽土方4m以内 土类级别 Ⅲ","UNIT":"m3","QUANTITIES":"4645.71","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"16","PROJECT_LIST_NAME":"挖装沟槽淤泥外弃7km","UNIT":"m3","QUANTITIES":"2074.19","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"17","PROJECT_LIST_NAME":"工作坑及接收坑开挖三类土","UNIT":"m3","QUANTITIES":"32","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"18","PROJECT_LIST_NAME":"管槽土料回填夯实(利用开挖料)","UNIT":"m3实方","QUANTITIES":"9474.65","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"19","PROJECT_LIST_NAME":"管道中粗砂垫层","UNIT":"m3","QUANTITIES":"1762.79","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"20","PROJECT_LIST_NAME":"管槽抛填块石","UNIT":"m3","QUANTITIES":"3476.68","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"21","PROJECT_LIST_NAME":"C20商品混凝土包管","UNIT":"m3","QUANTITIES":"2204.14","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"22","PROJECT_LIST_NAME":"普通平面钢模板 制作安拆","UNIT":"m2","QUANTITIES":"4390.65","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"23","PROJECT_LIST_NAME":"C20商品砼管道镇墩","UNIT":"m3","QUANTITIES":"34.3","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"24","PROJECT_LIST_NAME":"流量阀井(JYGS-S530-142-143)","UNIT":"座","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"25","PROJECT_LIST_NAME":"蝶阀井(05S502-90)","UNIT":"座","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"26","PROJECT_LIST_NAME":"排气阀井(05S502-164)","UNIT":"座","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"27","PROJECT_LIST_NAME":"蝶阀井(05S502-89)","UNIT":"座","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"28","PROJECT_LIST_NAME":"排水泥阀井(详见设计图纸)","UNIT":"座","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"29","PROJECT_LIST_NAME":"湿井(详见设计图纸)","UNIT":"座","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"30","PROJECT_LIST_NAME":"拆除混凝土挡墙","UNIT":"m3","QUANTITIES":"120","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"31","PROJECT_LIST_NAME":"C20商品砼挡墙","UNIT":"m3","QUANTITIES":"120","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"32","PROJECT_LIST_NAME":"普通平面钢模板 制作安拆","UNIT":"m2","QUANTITIES":"80","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"33","PROJECT_LIST_NAME":"石立柱安装(50%利旧)","UNIT":"根","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"34","PROJECT_LIST_NAME":"石栏杆安装(利旧)","UNIT":"m","QUANTITIES":"5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"35","PROJECT_LIST_NAME":"石栏杆安装","UNIT":"m","QUANTITIES":"5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"36","PROJECT_LIST_NAME":"人工拆除石栏杆","UNIT":"m","QUANTITIES":"10","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"37","PROJECT_LIST_NAME":"C20砼标志桩制作安装","UNIT":"m3","QUANTITIES":"0.61","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"38","PROJECT_LIST_NAME":"标志桩钢筋制作与安装","UNIT":"t","QUANTITIES":"0.015","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"二","PROJECT_LIST_NAME":"阀井工程","UNIT":"","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"钢筋砼流量计阀井(井径2.6*2.6m,井深2.73m)","UNIT":"座","QUANTITIES":"1","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"C15商品砼垫层100厚","UNIT":"m3","QUANTITIES":"1.32","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"C25商品砼底板300厚","UNIT":"m3","QUANTITIES":"3.47","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"C25商品砼井壁300厚","UNIT":"m3","QUANTITIES":"9.5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"C25预制商品混凝土井室盖板制作安装","UNIT":"m3","QUANTITIES":"1.09","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"集水坑砼管管径DN300mm","UNIT":"m","QUANTITIES":"0.5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"C15商品砼管道支墩","UNIT":"m3","QUANTITIES":"0.22","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"球墨铸铁井盖井座φ800","UNIT":"套","QUANTITIES":"1","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"爬梯 (φ25)","UNIT":"步","QUANTITIES":"9","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"钢筋制作与安装","UNIT":"t","QUANTITIES":"2.107","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"井壁普通平面钢模板制作安拆","UNIT":"m2","QUANTITIES":"63.34","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"胶合木模板 制作安拆","UNIT":"m2","QUANTITIES":"6.96","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"DN800钢筋砼蝶阀井(井径1.8*2.6m,井深2.41m,详05S502P90)","UNIT":"座","QUANTITIES":"4","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"C15商品砼垫层100厚","UNIT":"m3","QUANTITIES":"3.07","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"C25商品砼底板250厚","UNIT":"m3","QUANTITIES":"6.6","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"C25商品砼井壁200厚","UNIT":"m3","QUANTITIES":"17.65","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"C25预制商品混凝土井室盖板制作安装","UNIT":"m3","QUANTITIES":"5.56","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"集水坑砼管管径DN300mm","UNIT":"m","QUANTITIES":"2","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"C15商品砼管道支墩","UNIT":"m3","QUANTITIES":"0.58","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"球墨铸铁井盖井座φ800","UNIT":"套","QUANTITIES":"4","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"塑钢爬梯踏步","UNIT":"步","QUANTITIES":"28","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"钢筋制作与安装","UNIT":"t","QUANTITIES":"4.785","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"井壁普通平面钢模板制作安拆","UNIT":"m2","QUANTITIES":"176.49","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"胶合木模板 制作安拆","UNIT":"m2","QUANTITIES":"18.72","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"DN300钢筋砼蝶阀井(井径1.4*1.4m,井深2.13m,详05S502P89)","UNIT":"座","QUANTITIES":"2","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"C15商品砼垫层100厚","UNIT":"m3","QUANTITIES":"0.72","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"C25商品砼底板200厚","UNIT":"m3","QUANTITIES":"1.16","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"C25商品砼井壁150厚","UNIT":"m3","QUANTITIES":"3.92","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"C25预制商品混凝土井室盖板制作安装","UNIT":"m3","QUANTITIES":"0.62","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"集水坑砼管管径DN300mm","UNIT":"m","QUANTITIES":"1","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"C15商品砼管道支墩","UNIT":"m3","QUANTITIES":"0.05","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"球墨铸铁井盖井座φ800","UNIT":"套","QUANTITIES":"2","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"塑钢爬梯踏步","UNIT":"步","QUANTITIES":"12","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"钢筋制作与安装","UNIT":"t","QUANTITIES":"0.93","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"井壁普通平面钢模板制作安拆","UNIT":"m2","QUANTITIES":"52.21","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"胶合木模板 制作安拆","UNIT":"m2","QUANTITIES":"4.96","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"DN800钢筋砼排气阀井(井径1.4*1.4m,井深1.89m,详05S502P164)","UNIT":"座","QUANTITIES":"9","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"C15商品砼垫层100厚","UNIT":"m3","QUANTITIES":"3.6","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"C25商品砼底板250厚","UNIT":"m3","QUANTITIES":"7.29","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"C25商品砼井壁200厚","UNIT":"m3","QUANTITIES":"19.85","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"C25预制商品混凝土井室盖板制作安装","UNIT":"m3","QUANTITIES":"4.32","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"C15商品砼管道支墩","UNIT":"m3","QUANTITIES":"1.3","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"球墨铸铁井盖井座φ800","UNIT":"套","QUANTITIES":"9","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"塑钢爬梯踏步","UNIT":"步","QUANTITIES":"45","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"钢筋制作与安装","UNIT":"t","QUANTITIES":"4.498","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"井壁普通平面钢模板制作安拆","UNIT":"m2","QUANTITIES":"198.5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"胶合木模板 制作安拆","UNIT":"m2","QUANTITIES":"32.04","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"DN800钢筋砼排水泥阀井(圆形)(井径2.0m,井深2.44m)","UNIT":"座","QUANTITIES":"5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"砂碎石垫层200厚","UNIT":"m3","QUANTITIES":"6.6","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"C15商品砼垫层100厚","UNIT":"m3","QUANTITIES":"3.3","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"C25商品砼底板250厚","UNIT":"m3","QUANTITIES":"7.15","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"C25商品砼井壁250厚","UNIT":"m3","QUANTITIES":"21.46","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"C25预制商品混凝土井室盖板制作安装","UNIT":"m3","QUANTITIES":"2.2","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"集水坑砼管管径DN300mm","UNIT":"m","QUANTITIES":"2.75","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"C15商品砼管道支墩","UNIT":"m3","QUANTITIES":"0.22","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"球墨铸铁井盖井座φ800","UNIT":"套","QUANTITIES":"5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"爬梯 (φ20)","UNIT":"步","QUANTITIES":"30","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"钢筋制作与安装","UNIT":"t","QUANTITIES":"5.569","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"井壁普通曲面钢模板制作安拆","UNIT":"m2","QUANTITIES":"172.03","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"胶合木模板 制作安拆","UNIT":"m2","QUANTITIES":"18.04","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"钢筋砼排泥湿井(圆形)(井径1.2m,井深2.44m)","UNIT":"座","QUANTITIES":"5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"砂碎石垫层200厚","UNIT":"m3","QUANTITIES":"3.46","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"C15商品砼垫层100厚","UNIT":"m3","QUANTITIES":"1.73","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"C25商品砼底板250厚","UNIT":"m3","QUANTITIES":"3.54","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"C25商品砼井壁250厚","UNIT":"m3","QUANTITIES":"13.83","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"C25预制商品混凝土井室盖板制作安装","UNIT":"m3","QUANTITIES":"0.88","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"球墨铸铁井盖井座φ800","UNIT":"套","QUANTITIES":"5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"爬梯 (φ20)","UNIT":"步","QUANTITIES":"30","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"钢筋制作与安装","UNIT":"t","QUANTITIES":"3.478","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"井壁普通曲面钢模板制作安拆","UNIT":"m2","QUANTITIES":"110.64","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"胶合木模板 制作安拆","UNIT":"m2","QUANTITIES":"10.75","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"合计","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"第三部分","PROJECT_LIST_NAME":"临时工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"一","PROJECT_LIST_NAME":"施工便道","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"泥结碎石路面 厚度16cm","UNIT":"m2","QUANTITIES":"3262.5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"碎石垫层 厚度20cm","UNIT":"m2","QUANTITIES":"3770","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"石渣混合料路基填筑(利用开挖料)","UNIT":"m3实方","QUANTITIES":"4809.82","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"石渣混合料路基填筑(外购)","UNIT":"m3实方","QUANTITIES":"6404.59","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"二","PROJECT_LIST_NAME":"钢板桩支护","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"打拔槽钢钢板桩 支护 (含使用费)","UNIT":"t钢板桩","QUANTITIES":"471.169","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"打拔拉森钢板桩 支护 (含使用费)","UNIT":"t钢板桩","QUANTITIES":"8415.744","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"工作坑及接收井打拔槽钢钢板桩 支护(含使用费)","UNIT":"t钢板桩","QUANTITIES":"6.827","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"型钢横梁及支撑安装拆除(含使用费)","UNIT":"t","QUANTITIES":"648.757","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"三","PROJECT_LIST_NAME":"抽水台班","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"点工抽水台班","UNIT":"台班","QUANTITIES":"150","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"四","PROJECT_LIST_NAME":"施工专项工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"安全生产措施费","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"安全生产措施费","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"施工现场标准化建设工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"施工现场标准化建设工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"五","PROJECT_LIST_NAME":"施工房屋建筑工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"办公、生活及文化福利建筑","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"办公、生活及文化福利建筑","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"六","PROJECT_LIST_NAME":"其他临时工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"其他临时工程","UNIT":"元","QUANTITIES":"25170042","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"合计","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"第二部分","PROJECT_LIST_NAME":"输水管线设备及安装工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"一","PROJECT_LIST_NAME":"管线工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"水平定向钻开挖发送沟土方","UNIT":"m3","QUANTITIES":"4893.75","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"水平定向钻开挖发送沟回填土","UNIT":"m3实方","QUANTITIES":"4893.75","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"拆除玻璃钢管 管径 (DN1400)","UNIT":"m","QUANTITIES":"5","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"铺设Q235B钢管φ1420×14(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"m","QUANTITIES":"5","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"铺设Q235B钢管φ820×10(工作压力0.4Mpa,管道试压及冲洗,外包砼段,含内外壁防腐)","UNIT":"m","QUANTITIES":"1518.63","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"铺设Q235B钢管φ325×8(工作压力0.4Mpa,管道试压及冲洗,埋地段,含内外壁防腐)","UNIT":"m","QUANTITIES":"50","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"铺设Q235B钢管φ820×10(工作压力0.4Mpa,管道试压及冲洗,外露段,含内外壁防腐)","UNIT":"m","QUANTITIES":"12.13","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"铺设Q235B钢管φ820×10(工作压力0.4Mpa,管道试压及冲洗,埋地段,含内外壁防腐)","UNIT":"m","QUANTITIES":"3018.58","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"定向钻机穿越敷管 DN800(1#)","UNIT":"m","QUANTITIES":"0","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"定向钻机穿越敷管 DN800(2#)","UNIT":"m","QUANTITIES":"0","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"(1#)定向钻机穿越敷Q235B钢管φ820×12(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐,土壤类别详见地勘报告)","UNIT":"m","QUANTITIES":"351.6","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"(2#)定向钻机穿越敷Q235B钢管φ820×12(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐,土壤类别详见地勘报告)","UNIT":"m","QUANTITIES":"350.46","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"13","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管35.4°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"14","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管27.6°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"15","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管25.7°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"16","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管24.4°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"17","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管26.1°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"18","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管22.6°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"19","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管41.8°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"20","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管32.5°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"21","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管64.9°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"22","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管35.6°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"23","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管60.9°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"24","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管35.2°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"25","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管25.6°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"26","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管29.1°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"二","PROJECT_LIST_NAME":"配水工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"IFC300W DN800流量计","UNIT":"套","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"C2F-10 DN300伸缩节","UNIT":"个","QUANTITIES":"7","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"C2F-6 DN800伸缩节","UNIT":"个","QUANTITIES":"5","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"φ1020*10-300钢套管","UNIT":"个","QUANTITIES":"0","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"钢套管及止水环制作安装( φ1020*10-300,φ1320/φ1020*10)","UNIT":"个","QUANTITIES":"2","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"钢套管及止水环制作安装( φ960*10-300,φ1200/φ962*10)","UNIT":"个","QUANTITIES":"8","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"钢套管及止水环制作安装( φ1040*10-290,φ1340/φ1042*10)","UNIT":"个","QUANTITIES":"18","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"钢套管及止水环制作安装( φ540*10-260,φ800/φ542*10)","UNIT":"个","QUANTITIES":"14","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"DN300偏心半球阀PN1.0MPa","UNIT":"个","QUANTITIES":"5","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"Dd941X-6,DN300蝶阀","UNIT":"个","QUANTITIES":"2","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"Dd941X-6,DN800蝶阀","UNIT":"个","QUANTITIES":"4","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"P42X-10,DN100排气阀","UNIT":"个","QUANTITIES":"9","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"13","PROJECT_LIST_NAME":"Z45X-10,DN100闸阀","UNIT":"个","QUANTITIES":"9","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"14","PROJECT_LIST_NAME":"钢制弯管DN800","UNIT":"个","QUANTITIES":"0","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"15","PROJECT_LIST_NAME":"钢制排泥三通DN800*325","UNIT":"个","QUANTITIES":"5","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"16","PROJECT_LIST_NAME":"φ1320/φ1020*10止水环","UNIT":"个","QUANTITIES":"0","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"17","PROJECT_LIST_NAME":"无缝钢管DN108*5-220","UNIT":"m","QUANTITIES":"1.98","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"合计","UNIT":"","QUANTITIES":"","UNIVALENT":0,"TOTAL":0}],"CONSTRUCTION_PROJECT_AMOUNT_PRICE_LIST":[{"index":"第一部分","name":"建筑工程","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"一","name":"管道土建工程","unit":"","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"拆除混凝土路面","unit":"m3","project_amount":"1165.83","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"拆除路面水泥稳定层","unit":"m3","project_amount":"1133.78","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"拆除路面碎石层","unit":"m3","project_amount":"1207.71","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"拆除路沿石(立缘石) (石质截面半周长50cm以内)","unit":"m","project_amount":"579.86","unit_price":"","combined_price":"","remark":""},{"index":"5","name":"拆除路沿石(立缘石) (石质截面半周长50cm以外)","unit":"m","project_amount":"222","unit_price":"","combined_price":"","remark":""},{"index":"6","name":"商品混凝土路面 厚度22cm","unit":"m2","project_amount":"5299.22","unit_price":"","combined_price":"","remark":""},{"index":"7","name":"路基预拌商品5%水泥稳定层厚度20cm","unit":"m2","project_amount":"5299.22","unit_price":"","combined_price":"","remark":""},{"index":"8","name":"路面基层 碎石 压实厚度20cm","unit":"m2","project_amount":"5299.22","unit_price":"","combined_price":"","remark":""},{"index":"9","name":"拆除人行道面砖","unit":"m3","project_amount":"66.54","unit_price":"","combined_price":"","remark":""},{"index":"10","name":"人行道20*10*6cm彩色环保透水砖(1:3干拌水泥砂浆厚30)","unit":"m2","project_amount":"739.32","unit_price":"","combined_price":"","remark":""},{"index":"11","name":"人行道预拌商品5%水泥稳定层厚度10cm","unit":"m2","project_amount":"739.32","unit_price":"","combined_price":"","remark":""},{"index":"12","name":"人行道基层 碎石 压实厚度20cm","unit":"m2","project_amount":"739.32","unit_price":"","combined_price":"","remark":""},{"index":"13","name":"路缘石铺设 石质缘石(利用旧路缘石)","unit":"延长m","project_amount":"801.86","unit_price":"","combined_price":"","remark":""},{"index":"14","name":"挖沟槽土方2m以内 土类级别 Ⅲ","unit":"m3","project_amount":"7406.75","unit_price":"","combined_price":"","remark":""},{"index":"15","name":"挖沟槽土方4m以内 土类级别 Ⅲ","unit":"m3","project_amount":"4645.71","unit_price":"","combined_price":"","remark":""},{"index":"16","name":"挖装沟槽淤泥外弃7km","unit":"m3","project_amount":"2074.19","unit_price":"","combined_price":"","remark":""},{"index":"17","name":"工作坑及接收坑开挖三类土","unit":"m3","project_amount":"32","unit_price":"","combined_price":"","remark":""},{"index":"18","name":"管槽土料回填夯实(利用开挖料)","unit":"m3实方","project_amount":"9474.65","unit_price":"","combined_price":"","remark":""},{"index":"19","name":"管道中粗砂垫层","unit":"m3","project_amount":"1762.79","unit_price":"","combined_price":"","remark":""},{"index":"20","name":"管槽抛填块石","unit":"m3","project_amount":"3476.68","unit_price":"","combined_price":"","remark":""},{"index":"21","name":"C20商品混凝土包管","unit":"m3","project_amount":"2204.14","unit_price":"","combined_price":"","remark":""},{"index":"22","name":"普通平面钢模板 制作安拆","unit":"m2","project_amount":"4390.65","unit_price":"","combined_price":"","remark":""},{"index":"23","name":"C20商品砼管道镇墩","unit":"m3","project_amount":"34.3","unit_price":"","combined_price":"","remark":""},{"index":"24","name":"流量阀井(JYGS-S530-142-143)","unit":"座","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"25","name":"蝶阀井(05S502-90)","unit":"座","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"26","name":"排气阀井(05S502-164)","unit":"座","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"27","name":"蝶阀井(05S502-89)","unit":"座","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"28","name":"排水泥阀井(详见设计图纸)","unit":"座","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"29","name":"湿井(详见设计图纸)","unit":"座","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"30","name":"拆除混凝土挡墙","unit":"m3","project_amount":"120","unit_price":"","combined_price":"","remark":""},{"index":"31","name":"C20商品砼挡墙","unit":"m3","project_amount":"120","unit_price":"","combined_price":"","remark":""},{"index":"32","name":"普通平面钢模板 制作安拆","unit":"m2","project_amount":"80","unit_price":"","combined_price":"","remark":""},{"index":"33","name":"石立柱安装(50%利旧)","unit":"根","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"34","name":"石栏杆安装(利旧)","unit":"m","project_amount":"5","unit_price":"","combined_price":"","remark":""},{"index":"35","name":"石栏杆安装","unit":"m","project_amount":"5","unit_price":"","combined_price":"","remark":""},{"index":"36","name":"人工拆除石栏杆","unit":"m","project_amount":"10","unit_price":"","combined_price":"","remark":""},{"index":"37","name":"C20砼标志桩制作安装","unit":"m3","project_amount":"0.61","unit_price":"","combined_price":"","remark":""},{"index":"38","name":"标志桩钢筋制作与安装","unit":"t","project_amount":"0.015","unit_price":"","combined_price":"","remark":""},{"index":"二","name":"阀井工程","unit":"","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"钢筋砼流量计阀井(井径2.6*2.6m,井深2.73m)","unit":"座","project_amount":"1","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"C15商品砼垫层100厚","unit":"m3","project_amount":"1.32","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"C25商品砼底板300厚","unit":"m3","project_amount":"3.47","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"C25商品砼井壁300厚","unit":"m3","project_amount":"9.5","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"C25预制商品混凝土井室盖板制作安装","unit":"m3","project_amount":"1.09","unit_price":"","combined_price":"","remark":""},{"index":"5","name":"集水坑砼管管径DN300mm","unit":"m","project_amount":"0.5","unit_price":"","combined_price":"","remark":""},{"index":"6","name":"C15商品砼管道支墩","unit":"m3","project_amount":"0.22","unit_price":"","combined_price":"","remark":""},{"index":"7","name":"球墨铸铁井盖井座φ800","unit":"套","project_amount":"1","unit_price":"","combined_price":"","remark":""},{"index":"8","name":"爬梯 (φ25)","unit":"步","project_amount":"9","unit_price":"","combined_price":"","remark":""},{"index":"9","name":"钢筋制作与安装","unit":"t","project_amount":"2.107","unit_price":"","combined_price":"","remark":""},{"index":"10","name":"井壁普通平面钢模板制作安拆","unit":"m2","project_amount":"63.34","unit_price":"","combined_price":"","remark":""},{"index":"11","name":"胶合木模板 制作安拆","unit":"m2","project_amount":"6.96","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"DN800钢筋砼蝶阀井(井径1.8*2.6m,井深2.41m,详05S502P90)","unit":"座","project_amount":"4","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"C15商品砼垫层100厚","unit":"m3","project_amount":"3.07","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"C25商品砼底板250厚","unit":"m3","project_amount":"6.6","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"C25商品砼井壁200厚","unit":"m3","project_amount":"17.65","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"C25预制商品混凝土井室盖板制作安装","unit":"m3","project_amount":"5.56","unit_price":"","combined_price":"","remark":""},{"index":"5","name":"集水坑砼管管径DN300mm","unit":"m","project_amount":"2","unit_price":"","combined_price":"","remark":""},{"index":"6","name":"C15商品砼管道支墩","unit":"m3","project_amount":"0.58","unit_price":"","combined_price":"","remark":""},{"index":"7","name":"球墨铸铁井盖井座φ800","unit":"套","project_amount":"4","unit_price":"","combined_price":"","remark":""},{"index":"8","name":"塑钢爬梯踏步","unit":"步","project_amount":"28","unit_price":"","combined_price":"","remark":""},{"index":"9","name":"钢筋制作与安装","unit":"t","project_amount":"4.785","unit_price":"","combined_price":"","remark":""},{"index":"10","name":"井壁普通平面钢模板制作安拆","unit":"m2","project_amount":"176.49","unit_price":"","combined_price":"","remark":""},{"index":"11","name":"胶合木模板 制作安拆","unit":"m2","project_amount":"18.72","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"DN300钢筋砼蝶阀井(井径1.4*1.4m,井深2.13m,详05S502P89)","unit":"座","project_amount":"2","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"C15商品砼垫层100厚","unit":"m3","project_amount":"0.72","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"C25商品砼底板200厚","unit":"m3","project_amount":"1.16","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"C25商品砼井壁150厚","unit":"m3","project_amount":"3.92","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"C25预制商品混凝土井室盖板制作安装","unit":"m3","project_amount":"0.62","unit_price":"","combined_price":"","remark":""},{"index":"5","name":"集水坑砼管管径DN300mm","unit":"m","project_amount":"1","unit_price":"","combined_price":"","remark":""},{"index":"6","name":"C15商品砼管道支墩","unit":"m3","project_amount":"0.05","unit_price":"","combined_price":"","remark":""},{"index":"7","name":"球墨铸铁井盖井座φ800","unit":"套","project_amount":"2","unit_price":"","combined_price":"","remark":""},{"index":"8","name":"塑钢爬梯踏步","unit":"步","project_amount":"12","unit_price":"","combined_price":"","remark":""},{"index":"9","name":"钢筋制作与安装","unit":"t","project_amount":"0.93","unit_price":"","combined_price":"","remark":""},{"index":"10","name":"井壁普通平面钢模板制作安拆","unit":"m2","project_amount":"52.21","unit_price":"","combined_price":"","remark":""},{"index":"11","name":"胶合木模板 制作安拆","unit":"m2","project_amount":"4.96","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"DN800钢筋砼排气阀井(井径1.4*1.4m,井深1.89m,详05S502P164)","unit":"座","project_amount":"9","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"C15商品砼垫层100厚","unit":"m3","project_amount":"3.6","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"C25商品砼底板250厚","unit":"m3","project_amount":"7.29","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"C25商品砼井壁200厚","unit":"m3","project_amount":"19.85","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"C25预制商品混凝土井室盖板制作安装","unit":"m3","project_amount":"4.32","unit_price":"","combined_price":"","remark":""},{"index":"5","name":"C15商品砼管道支墩","unit":"m3","project_amount":"1.3","unit_price":"","combined_price":"","remark":""},{"index":"6","name":"球墨铸铁井盖井座φ800","unit":"套","project_amount":"9","unit_price":"","combined_price":"","remark":""},{"index":"7","name":"塑钢爬梯踏步","unit":"步","project_amount":"45","unit_price":"","combined_price":"","remark":""},{"index":"8","name":"钢筋制作与安装","unit":"t","project_amount":"4.498","unit_price":"","combined_price":"","remark":""},{"index":"9","name":"井壁普通平面钢模板制作安拆","unit":"m2","project_amount":"198.5","unit_price":"","combined_price":"","remark":""},{"index":"10","name":"胶合木模板 制作安拆","unit":"m2","project_amount":"32.04","unit_price":"","combined_price":"","remark":""},{"index":"5","name":"DN800钢筋砼排水泥阀井(圆形)(井径2.0m,井深2.44m)","unit":"座","project_amount":"5","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"砂碎石垫层200厚","unit":"m3","project_amount":"6.6","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"C15商品砼垫层100厚","unit":"m3","project_amount":"3.3","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"C25商品砼底板250厚","unit":"m3","project_amount":"7.15","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"C25商品砼井壁250厚","unit":"m3","project_amount":"21.46","unit_price":"","combined_price":"","remark":""},{"index":"5","name":"C25预制商品混凝土井室盖板制作安装","unit":"m3","project_amount":"2.2","unit_price":"","combined_price":"","remark":""},{"index":"6","name":"集水坑砼管管径DN300mm","unit":"m","project_amount":"2.75","unit_price":"","combined_price":"","remark":""},{"index":"7","name":"C15商品砼管道支墩","unit":"m3","project_amount":"0.22","unit_price":"","combined_price":"","remark":""},{"index":"8","name":"球墨铸铁井盖井座φ800","unit":"套","project_amount":"5","unit_price":"","combined_price":"","remark":""},{"index":"9","name":"爬梯 (φ20)","unit":"步","project_amount":"30","unit_price":"","combined_price":"","remark":""},{"index":"10","name":"钢筋制作与安装","unit":"t","project_amount":"5.569","unit_price":"","combined_price":"","remark":""},{"index":"11","name":"井壁普通曲面钢模板制作安拆","unit":"m2","project_amount":"172.03","unit_price":"","combined_price":"","remark":""},{"index":"12","name":"胶合木模板 制作安拆","unit":"m2","project_amount":"18.04","unit_price":"","combined_price":"","remark":""},{"index":"6","name":"钢筋砼排泥湿井(圆形)(井径1.2m,井深2.44m)","unit":"座","project_amount":"5","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"砂碎石垫层200厚","unit":"m3","project_amount":"3.46","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"C15商品砼垫层100厚","unit":"m3","project_amount":"1.73","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"C25商品砼底板250厚","unit":"m3","project_amount":"3.54","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"C25商品砼井壁250厚","unit":"m3","project_amount":"13.83","unit_price":"","combined_price":"","remark":""},{"index":"5","name":"C25预制商品混凝土井室盖板制作安装","unit":"m3","project_amount":"0.88","unit_price":"","combined_price":"","remark":""},{"index":"6","name":"球墨铸铁井盖井座φ800","unit":"套","project_amount":"5","unit_price":"","combined_price":"","remark":""},{"index":"7","name":"爬梯 (φ20)","unit":"步","project_amount":"30","unit_price":"","combined_price":"","remark":""},{"index":"8","name":"钢筋制作与安装","unit":"t","project_amount":"3.478","unit_price":"","combined_price":"","remark":""},{"index":"9","name":"井壁普通曲面钢模板制作安拆","unit":"m2","project_amount":"110.64","unit_price":"","combined_price":"","remark":""},{"index":"10","name":"胶合木模板 制作安拆","unit":"m2","project_amount":"10.75","unit_price":"","combined_price":"","remark":""},{"index":"","name":"合计","unit":"","project_amount":"","unit_price":"","combined_price":"","remark":""}],"TEMPORARY_PROJECT_AMOUNT_PRICE_LIST":[{"index":"第三部分","name":"临时工程","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"一","name":"施工便道","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"泥结碎石路面 厚度16cm","unit":"m2","project_amount":"3262.5","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"碎石垫层 厚度20cm","unit":"m2","project_amount":"3770","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"石渣混合料路基填筑(利用开挖料)","unit":"m3实方","project_amount":"4809.82","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"石渣混合料路基填筑(外购)","unit":"m3实方","project_amount":"6404.59","unit_price":"","combined_price":"","remark":""},{"index":"二","name":"钢板桩支护","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"打拔槽钢钢板桩 支护 (含使用费)","unit":"t钢板桩","project_amount":"471.169","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"打拔拉森钢板桩 支护 (含使用费)","unit":"t钢板桩","project_amount":"8415.744","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"工作坑及接收井打拔槽钢钢板桩 支护(含使用费)","unit":"t钢板桩","project_amount":"6.827","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"型钢横梁及支撑安装拆除(含使用费)","unit":"t","project_amount":"648.757","unit_price":"","combined_price":"","remark":""},{"index":"三","name":"抽水台班","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"点工抽水台班","unit":"台班","project_amount":"150","unit_price":"","combined_price":"","remark":""},{"index":"四","name":"施工专项工程","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"安全生产措施费","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"安全生产措施费","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"施工现场标准化建设工程","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"施工现场标准化建设工程","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"五","name":"施工房屋建筑工程","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"办公、生活及文化福利建筑","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"办公、生活及文化福利建筑","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"六","name":"其他临时工程","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"其他临时工程","unit":"元","project_amount":"25170042","unit_price":"","combined_price":"","remark":""},{"index":"","name":"合计","unit":"","project_amount":"","unit_price":"","combined_price":"","remark":""}],"OTHER_PROJECT_AMOUNT_PRICE_LIST":[],"ELECTRICAL_OR_METALLIC_STRUCTURES_PROJECT_AMOUNT_PRICE_LIST":[],"EQUIPMENT_AND_INSTALLATION_PROJECT_AMOUNT_PRICE_LIST":[{"index":"第二部分","name":"输水管线设备及安装工程","unit":"元","project_amount":"0","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"一","name":"管线工程","unit":"元","project_amount":"0","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"1","name":"水平定向钻开挖发送沟土方","unit":"m3","project_amount":"4893.75","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"2","name":"水平定向钻开挖发送沟回填土","unit":"m3实方","project_amount":"4893.75","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"3","name":"拆除玻璃钢管 管径 (DN1400)","unit":"m","project_amount":"5","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"4","name":"铺设Q235B钢管φ1420×14(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"m","project_amount":"5","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"5","name":"铺设Q235B钢管φ820×10(工作压力0.4Mpa,管道试压及冲洗,外包砼段,含内外壁防腐)","unit":"m","project_amount":"1518.63","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"6","name":"铺设Q235B钢管φ325×8(工作压力0.4Mpa,管道试压及冲洗,埋地段,含内外壁防腐)","unit":"m","project_amount":"50","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"7","name":"铺设Q235B钢管φ820×10(工作压力0.4Mpa,管道试压及冲洗,外露段,含内外壁防腐)","unit":"m","project_amount":"12.13","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"8","name":"铺设Q235B钢管φ820×10(工作压力0.4Mpa,管道试压及冲洗,埋地段,含内外壁防腐)","unit":"m","project_amount":"3018.58","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"9","name":"定向钻机穿越敷管 DN800(1#)","unit":"m","project_amount":"0","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"10","name":"定向钻机穿越敷管 DN800(2#)","unit":"m","project_amount":"0","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"11","name":"(1#)定向钻机穿越敷Q235B钢管φ820×12(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐,土壤类别详见地勘报告)","unit":"m","project_amount":"351.6","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"12","name":"(2#)定向钻机穿越敷Q235B钢管φ820×12(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐,土壤类别详见地勘报告)","unit":"m","project_amount":"350.46","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"13","name":"Q235B钢管φ820×10弯管35.4°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"14","name":"Q235B钢管φ820×10弯管27.6°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"15","name":"Q235B钢管φ820×10弯管25.7°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"16","name":"Q235B钢管φ820×10弯管24.4°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"17","name":"Q235B钢管φ820×10弯管26.1°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"18","name":"Q235B钢管φ820×10弯管22.6°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"19","name":"Q235B钢管φ820×10弯管41.8°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"20","name":"Q235B钢管φ820×10弯管32.5°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"21","name":"Q235B钢管φ820×10弯管64.9°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"22","name":"Q235B钢管φ820×10弯管35.6°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"23","name":"Q235B钢管φ820×10弯管60.9°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"24","name":"Q235B钢管φ820×10弯管35.2°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"25","name":"Q235B钢管φ820×10弯管25.6°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"26","name":"Q235B钢管φ820×10弯管29.1°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"二","name":"配水工程","unit":"元","project_amount":"0","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"1","name":"IFC300W DN800流量计","unit":"套","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"2","name":"C2F-10 DN300伸缩节","unit":"个","project_amount":"7","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"3","name":"C2F-6 DN800伸缩节","unit":"个","project_amount":"5","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"4","name":"φ1020*10-300钢套管","unit":"个","project_amount":"0","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"5","name":"钢套管及止水环制作安装( φ1020*10-300,φ1320/φ1020*10)","unit":"个","project_amount":"2","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"6","name":"钢套管及止水环制作安装( φ960*10-300,φ1200/φ962*10)","unit":"个","project_amount":"8","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"7","name":"钢套管及止水环制作安装( φ1040*10-290,φ1340/φ1042*10)","unit":"个","project_amount":"18","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"8","name":"钢套管及止水环制作安装( φ540*10-260,φ800/φ542*10)","unit":"个","project_amount":"14","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"9","name":"DN300偏心半球阀PN1.0MPa","unit":"个","project_amount":"5","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"10","name":"Dd941X-6,DN300蝶阀","unit":"个","project_amount":"2","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"11","name":"Dd941X-6,DN800蝶阀","unit":"个","project_amount":"4","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"12","name":"P42X-10,DN100排气阀","unit":"个","project_amount":"9","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"13","name":"Z45X-10,DN100闸阀","unit":"个","project_amount":"9","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"14","name":"钢制弯管DN800","unit":"个","project_amount":"0","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"15","name":"钢制排泥三通DN800*325","unit":"个","project_amount":"5","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"16","name":"φ1320/φ1020*10止水环","unit":"个","project_amount":"0","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"17","name":"无缝钢管DN108*5-220","unit":"m","project_amount":"1.98","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"","name":"合计","unit":"","project_amount":"","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""}],"GRAPH_PAPER_ATTACHMENTS":[{"id":"6109fa1961b96f2060d1a82e","md5":"8E2E4CE49DEC9250C0FE6C6CA72CFA37","name":"第四章 合同条款及格式-江阴港城经济区新厝产业区原水管道工程合同技术条款.docx","new_id":"6109fa1961b96f2060d1a82e","size":326731,"url":"/file/getcontent/6109fa1961b96f2060d1a82e.docx"}],"TECHNICAL_REQUIREMENTS_ATTACHMENTS":[{"id":"6109fa3ff178671528365199","md5":"BBE89B4B1650019EF4EB4A06E006E0A2","name":"第二章 投标人须知-附件1-招标文件的其他要求.doc","new_id":"6109fa3ff178671528365199","size":79360,"url":"/file/getcontent/6109fa3ff178671528365199.doc"},{"id":"6109fa3f61b96f2060d1a8d3","md5":"8E2E4CE49DEC9250C0FE6C6CA72CFA37","name":"第四章 合同条款及格式-江阴港城经济区新厝产业区原水管道工程合同技术条款.docx","new_id":"6109fa3f61b96f2060d1a8d3","size":326731,"url":"/file/getcontent/6109fa3f61b96f2060d1a8d3.docx"},{"id":"6109fa40f17867152836519b","md5":"CE78E2B949082306019662CA9AA1DBC5","name":"第四章 合同条款及格式-第二节专用合同条款.doc","new_id":"6109fa40f17867152836519b","size":194048,"url":"/file/getcontent/6109fa40f17867152836519b.doc"}],"ISUNION":"否","UNIONTENDER":"","UNIONCODE":"","UNIONCODETYPE":"","XM_BID_SECTION_NUM":"","PRICE_FORM_CODE":"3","MARGIN_PERCENT":"投标保证金的金额:270000.00 元","IS_REPORT_PROVINCE_OUTSIDE":"","IS_REPORT_CTBA":"","NOTICE_CONTENT_ATTACHMENTS_PDF":[],"FJGGZY_FILE_LIST":[{"name":"立项批复文件(项目审批核准文件)","key":"SGG_LXPFWJ","val":[{"id":"6109fbec6fd5361c68186888","md5":"4124F67478838CF62398677655ADCDB6","name":"立项批复1.jpg","new_id":"6109fbec6fd5361c68186888","size":124819,"url":"/file/getcontent/6109fbec6fd5361c68186888.jpg"},{"id":"6109fbecf1786715283658f5","md5":"D5938E8CC1E4F165E3052FA0E3F47F6B","name":"立项批复2.jpg","new_id":"6109fbecf1786715283658f5","size":83603,"url":"/file/getcontent/6109fbecf1786715283658f5.jpg"}],"isUpload":true,"limit":""},{"name":"招标文件附件","key":"SGG_ZBWJFJ","val":[{"id":"6109fd93f178671528365f65","md5":"916CEB6E6B642B3B53DBA4D80D533DC5","name":"发给投标人资料.zip","new_id":"6109fd93f178671528365f65","size":4929527,"url":"/file/getcontent/6109fd93f178671528365f65.zip"}],"isUpload":true,"limit":""},{"name":"招标公告PDF文件(招标人或其代理机构盖章并由项目负责人签名或者电子签名)","key":"SGG_ZBGGPDFWJ","val":[],"isUpload":true,"limit":""},{"name":"招标公告电子签章文件(招标人或其代理机构盖章并由项目负责人签名或者电子签名)","key":"SGG_ZBGGDZQZWJ","val":[],"isUpload":true,"limit":""},{"name":"主要负责人的授权书","key":"SGG_ZYFZRDSQS","val":[],"isUpload":true,"limit":""},{"name":"资金来源落实证明文件","key":"SGG_ZJLYLSZMWJ","val":[],"isUpload":true,"limit":""},{"name":"招标代理合同","key":"SGG_ZBDLHT","val":[],"isUpload":false,"limit":""},{"name":"公共资源交易入场登记表","key":"SGG_GGZYJYRCDJB","val":[],"isUpload":false,"limit":""},{"name":"招标代理机构承诺书","key":"SGG_ZBDLJGCNS","val":[],"isUpload":false,"limit":""},{"name":"其他招标代理机构认为需要上传的文件资料","key":"SGG_QTZBDLJGRWXYSCDWJZL","val":[],"isUpload":false,"limit":""},{"name":"入场登记表中由行政主管部门明确入场意见","key":"SGG_RCDJBZYXZZGBMMQRCYJ","val":[],"isUpload":false,"limit":""},{"name":"加盖电子印章的澄清、答疑及补充PDF电子文件","key":"SGG_JGDZYZDCQDYJBCPDFDZWJ","val":[],"isUpload":false,"limit":""},{"name":"投标邀请书","key":"SGG_TBYQS","val":[],"isUpload":false,"limit":""}],"SGG_ZBWJFJ":[{"id":"6109fd93f178671528365f65","md5":"916CEB6E6B642B3B53DBA4D80D533DC5","name":"发给投标人资料.zip","new_id":"6109fd93f178671528365f65","size":4929527,"url":"/file/getcontent/6109fd93f178671528365f65.zip"}],"IS_ABLE_USE_DZBH":false,"REVIEW_STATUS":"1","REVIEW_COMMENT":"","PROJECT_NAME_disabled":true,"SJD_TENDER_PROJECT_CODE":"N763501812107260010001","GGZY_UNIFIED_DEAL_CODE":"","Is_MultiSegment":"否","PM_TABLE_DATA":[{"POST":"项目经理","POST_NUMBER":"1","PROFESSIONAL_TITLE":"中级工程师及以上","PROFESSIONAL":"水利水电工程(指建造师专业)"},{"POST":"技术负责人","POST_NUMBER":"1","PROFESSIONAL_TITLE":"中级工程师及以上","PROFESSIONAL":"水利水电工程相关专业(指职称专业)。注:水利水电工程相关专业职称包括水利水电工程建筑、水利工程施工、农田水利工程、工程地质及水文地质专业职称。(下同)"},{"POST":"施工员","POST_NUMBER":"1","PROFESSIONAL_TITLE":"/","PROFESSIONAL":"具备 水行政主管部门或建设行政主管部门或行政主管部门授权的单位(需提供授权的依据文件) 核发的合格有效的岗位证书。"},{"POST":"材料员","POST_NUMBER":"1","PROFESSIONAL_TITLE":"/","PROFESSIONAL":"具备水行政主管部门或建设行政主管部门或行政主管部门授权的单位(需提供授权的依据文件)核发的合格有效的岗位证书。"},{"POST":"质检员","POST_NUMBER":"1","PROFESSIONAL_TITLE":"/","PROFESSIONAL":"具备水行政主管部门或建设行政主管部门或行政主管部门授权的单位(需提供授权的依据文件)核发的合格有效的岗位证书。"},{"POST":"安全员","POST_NUMBER":"1","PROFESSIONAL_TITLE":"/","PROFESSIONAL":"具备水行政主管部门或建设行政主管部门或行政主管部门授权的单位(需提供授权的依据文件)核发的合格有效的岗位证书和水行政主管部门颁发的安全考核合格证书(C证)。"}],"EARNEST_BLOCK_METHOD":["现金","支票","银行保函","电子保函","年度保证金"],"updateContent_cost":{"TENDER_QUANTITIES":{"PROJECT_PRICE_LIST_ATTACHMENTS":[{"id":"6109f8e661b96f2060d1a33e","md5":"FC83440316A793322D736ACF840DEB85","name":"工程项目总价表.xlsx","new_id":"6109f8e661b96f2060d1a33e","size":21937,"url":"/file/getcontent/6109f8e661b96f2060d1a33e.xlsx"}],"TOTAL_PROJECT_PRICE_LIST_SELECT":"工程项目总价表","CONSTRUCTION_PROJECT_AMOUNT_PRICE_LIST_SELECT":"建筑工程工程量清单报价表","TEMPORARY_PROJECT_AMOUNT_PRICE_LIST_SELECT":"临时工程工程量清单报价表","OTHER_PROJECT_AMOUNT_PRICE_LIST_SELECT":"无","ELECTRICAL_OR_METALLIC_STRUCTURES_PROJECT_AMOUNT_PRICE_LIST_SELECT":"无","EQUIPMENT_AND_INSTALLATION_PROJECT_AMOUNT_PRICE_LIST_SELECT":"设备及安装工程工程量清单报价表","SUPPLEMENTARY_LIST_ATTACHMENTS":[],"TOTAL_PROJECT_PRICE_LIST":[{"index":"第一部分","name":"建筑工程","cost":"","remark":""},{"index":"第二部分","name":"输水管线设备及安装工程","cost":"","remark":""},{"index":"第三部分","name":"临时工程","cost":"","remark":""},{"index":"","name":"小计(元)","cost":"","remark":""},{"index":"","name":"总 计","cost":"","remark":""}],"PRIMARY_LIST":[{"PROJECT_NUMBER":"第一部分","PROJECT_LIST_NAME":"建筑工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"一","PROJECT_LIST_NAME":"管道土建工程","UNIT":"","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"拆除混凝土路面","UNIT":"m3","QUANTITIES":"1165.83","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"拆除路面水泥稳定层","UNIT":"m3","QUANTITIES":"1133.78","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"拆除路面碎石层","UNIT":"m3","QUANTITIES":"1207.71","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"拆除路沿石(立缘石) (石质截面半周长50cm以内)","UNIT":"m","QUANTITIES":"579.86","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"拆除路沿石(立缘石) (石质截面半周长50cm以外)","UNIT":"m","QUANTITIES":"222","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"商品混凝土路面 厚度22cm","UNIT":"m2","QUANTITIES":"5299.22","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"路基预拌商品5%水泥稳定层厚度20cm","UNIT":"m2","QUANTITIES":"5299.22","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"路面基层 碎石 压实厚度20cm","UNIT":"m2","QUANTITIES":"5299.22","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"拆除人行道面砖","UNIT":"m3","QUANTITIES":"66.54","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"人行道20*10*6cm彩色环保透水砖(1:3干拌水泥砂浆厚30)","UNIT":"m2","QUANTITIES":"739.32","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"人行道预拌商品5%水泥稳定层厚度10cm","UNIT":"m2","QUANTITIES":"739.32","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"人行道基层 碎石 压实厚度20cm","UNIT":"m2","QUANTITIES":"739.32","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"13","PROJECT_LIST_NAME":"路缘石铺设 石质缘石(利用旧路缘石)","UNIT":"延长m","QUANTITIES":"801.86","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"14","PROJECT_LIST_NAME":"挖沟槽土方2m以内 土类级别 Ⅲ","UNIT":"m3","QUANTITIES":"7406.75","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"15","PROJECT_LIST_NAME":"挖沟槽土方4m以内 土类级别 Ⅲ","UNIT":"m3","QUANTITIES":"4645.71","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"16","PROJECT_LIST_NAME":"挖装沟槽淤泥外弃7km","UNIT":"m3","QUANTITIES":"2074.19","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"17","PROJECT_LIST_NAME":"工作坑及接收坑开挖三类土","UNIT":"m3","QUANTITIES":"32","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"18","PROJECT_LIST_NAME":"管槽土料回填夯实(利用开挖料)","UNIT":"m3实方","QUANTITIES":"9474.65","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"19","PROJECT_LIST_NAME":"管道中粗砂垫层","UNIT":"m3","QUANTITIES":"1762.79","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"20","PROJECT_LIST_NAME":"管槽抛填块石","UNIT":"m3","QUANTITIES":"3476.68","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"21","PROJECT_LIST_NAME":"C20商品混凝土包管","UNIT":"m3","QUANTITIES":"2204.14","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"22","PROJECT_LIST_NAME":"普通平面钢模板 制作安拆","UNIT":"m2","QUANTITIES":"4390.65","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"23","PROJECT_LIST_NAME":"C20商品砼管道镇墩","UNIT":"m3","QUANTITIES":"34.3","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"24","PROJECT_LIST_NAME":"流量阀井(JYGS-S530-142-143)","UNIT":"座","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"25","PROJECT_LIST_NAME":"蝶阀井(05S502-90)","UNIT":"座","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"26","PROJECT_LIST_NAME":"排气阀井(05S502-164)","UNIT":"座","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"27","PROJECT_LIST_NAME":"蝶阀井(05S502-89)","UNIT":"座","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"28","PROJECT_LIST_NAME":"排水泥阀井(详见设计图纸)","UNIT":"座","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"29","PROJECT_LIST_NAME":"湿井(详见设计图纸)","UNIT":"座","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"30","PROJECT_LIST_NAME":"拆除混凝土挡墙","UNIT":"m3","QUANTITIES":"120","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"31","PROJECT_LIST_NAME":"C20商品砼挡墙","UNIT":"m3","QUANTITIES":"120","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"32","PROJECT_LIST_NAME":"普通平面钢模板 制作安拆","UNIT":"m2","QUANTITIES":"80","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"33","PROJECT_LIST_NAME":"石立柱安装(50%利旧)","UNIT":"根","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"34","PROJECT_LIST_NAME":"石栏杆安装(利旧)","UNIT":"m","QUANTITIES":"5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"35","PROJECT_LIST_NAME":"石栏杆安装","UNIT":"m","QUANTITIES":"5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"36","PROJECT_LIST_NAME":"人工拆除石栏杆","UNIT":"m","QUANTITIES":"10","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"37","PROJECT_LIST_NAME":"C20砼标志桩制作安装","UNIT":"m3","QUANTITIES":"0.61","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"38","PROJECT_LIST_NAME":"标志桩钢筋制作与安装","UNIT":"t","QUANTITIES":"0.015","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"二","PROJECT_LIST_NAME":"阀井工程","UNIT":"","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"钢筋砼流量计阀井(井径2.6*2.6m,井深2.73m)","UNIT":"座","QUANTITIES":"1","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"C15商品砼垫层100厚","UNIT":"m3","QUANTITIES":"1.32","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"C25商品砼底板300厚","UNIT":"m3","QUANTITIES":"3.47","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"C25商品砼井壁300厚","UNIT":"m3","QUANTITIES":"9.5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"C25预制商品混凝土井室盖板制作安装","UNIT":"m3","QUANTITIES":"1.09","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"集水坑砼管管径DN300mm","UNIT":"m","QUANTITIES":"0.5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"C15商品砼管道支墩","UNIT":"m3","QUANTITIES":"0.22","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"球墨铸铁井盖井座φ800","UNIT":"套","QUANTITIES":"1","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"爬梯 (φ25)","UNIT":"步","QUANTITIES":"9","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"钢筋制作与安装","UNIT":"t","QUANTITIES":"2.107","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"井壁普通平面钢模板制作安拆","UNIT":"m2","QUANTITIES":"63.34","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"胶合木模板 制作安拆","UNIT":"m2","QUANTITIES":"6.96","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"DN800钢筋砼蝶阀井(井径1.8*2.6m,井深2.41m,详05S502P90)","UNIT":"座","QUANTITIES":"4","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"C15商品砼垫层100厚","UNIT":"m3","QUANTITIES":"3.07","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"C25商品砼底板250厚","UNIT":"m3","QUANTITIES":"6.6","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"C25商品砼井壁200厚","UNIT":"m3","QUANTITIES":"17.65","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"C25预制商品混凝土井室盖板制作安装","UNIT":"m3","QUANTITIES":"5.56","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"集水坑砼管管径DN300mm","UNIT":"m","QUANTITIES":"2","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"C15商品砼管道支墩","UNIT":"m3","QUANTITIES":"0.58","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"球墨铸铁井盖井座φ800","UNIT":"套","QUANTITIES":"4","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"塑钢爬梯踏步","UNIT":"步","QUANTITIES":"28","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"钢筋制作与安装","UNIT":"t","QUANTITIES":"4.785","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"井壁普通平面钢模板制作安拆","UNIT":"m2","QUANTITIES":"176.49","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"胶合木模板 制作安拆","UNIT":"m2","QUANTITIES":"18.72","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"DN300钢筋砼蝶阀井(井径1.4*1.4m,井深2.13m,详05S502P89)","UNIT":"座","QUANTITIES":"2","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"C15商品砼垫层100厚","UNIT":"m3","QUANTITIES":"0.72","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"C25商品砼底板200厚","UNIT":"m3","QUANTITIES":"1.16","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"C25商品砼井壁150厚","UNIT":"m3","QUANTITIES":"3.92","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"C25预制商品混凝土井室盖板制作安装","UNIT":"m3","QUANTITIES":"0.62","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"集水坑砼管管径DN300mm","UNIT":"m","QUANTITIES":"1","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"C15商品砼管道支墩","UNIT":"m3","QUANTITIES":"0.05","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"球墨铸铁井盖井座φ800","UNIT":"套","QUANTITIES":"2","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"塑钢爬梯踏步","UNIT":"步","QUANTITIES":"12","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"钢筋制作与安装","UNIT":"t","QUANTITIES":"0.93","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"井壁普通平面钢模板制作安拆","UNIT":"m2","QUANTITIES":"52.21","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"胶合木模板 制作安拆","UNIT":"m2","QUANTITIES":"4.96","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"DN800钢筋砼排气阀井(井径1.4*1.4m,井深1.89m,详05S502P164)","UNIT":"座","QUANTITIES":"9","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"C15商品砼垫层100厚","UNIT":"m3","QUANTITIES":"3.6","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"C25商品砼底板250厚","UNIT":"m3","QUANTITIES":"7.29","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"C25商品砼井壁200厚","UNIT":"m3","QUANTITIES":"19.85","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"C25预制商品混凝土井室盖板制作安装","UNIT":"m3","QUANTITIES":"4.32","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"C15商品砼管道支墩","UNIT":"m3","QUANTITIES":"1.3","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"球墨铸铁井盖井座φ800","UNIT":"套","QUANTITIES":"9","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"塑钢爬梯踏步","UNIT":"步","QUANTITIES":"45","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"钢筋制作与安装","UNIT":"t","QUANTITIES":"4.498","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"井壁普通平面钢模板制作安拆","UNIT":"m2","QUANTITIES":"198.5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"胶合木模板 制作安拆","UNIT":"m2","QUANTITIES":"32.04","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"DN800钢筋砼排水泥阀井(圆形)(井径2.0m,井深2.44m)","UNIT":"座","QUANTITIES":"5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"砂碎石垫层200厚","UNIT":"m3","QUANTITIES":"6.6","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"C15商品砼垫层100厚","UNIT":"m3","QUANTITIES":"3.3","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"C25商品砼底板250厚","UNIT":"m3","QUANTITIES":"7.15","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"C25商品砼井壁250厚","UNIT":"m3","QUANTITIES":"21.46","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"C25预制商品混凝土井室盖板制作安装","UNIT":"m3","QUANTITIES":"2.2","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"集水坑砼管管径DN300mm","UNIT":"m","QUANTITIES":"2.75","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"C15商品砼管道支墩","UNIT":"m3","QUANTITIES":"0.22","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"球墨铸铁井盖井座φ800","UNIT":"套","QUANTITIES":"5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"爬梯 (φ20)","UNIT":"步","QUANTITIES":"30","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"钢筋制作与安装","UNIT":"t","QUANTITIES":"5.569","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"井壁普通曲面钢模板制作安拆","UNIT":"m2","QUANTITIES":"172.03","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"胶合木模板 制作安拆","UNIT":"m2","QUANTITIES":"18.04","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"钢筋砼排泥湿井(圆形)(井径1.2m,井深2.44m)","UNIT":"座","QUANTITIES":"5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"砂碎石垫层200厚","UNIT":"m3","QUANTITIES":"3.46","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"C15商品砼垫层100厚","UNIT":"m3","QUANTITIES":"1.73","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"C25商品砼底板250厚","UNIT":"m3","QUANTITIES":"3.54","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"C25商品砼井壁250厚","UNIT":"m3","QUANTITIES":"13.83","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"C25预制商品混凝土井室盖板制作安装","UNIT":"m3","QUANTITIES":"0.88","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"球墨铸铁井盖井座φ800","UNIT":"套","QUANTITIES":"5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"爬梯 (φ20)","UNIT":"步","QUANTITIES":"30","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"钢筋制作与安装","UNIT":"t","QUANTITIES":"3.478","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"井壁普通曲面钢模板制作安拆","UNIT":"m2","QUANTITIES":"110.64","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"胶合木模板 制作安拆","UNIT":"m2","QUANTITIES":"10.75","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"合计","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"第三部分","PROJECT_LIST_NAME":"临时工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"一","PROJECT_LIST_NAME":"施工便道","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"泥结碎石路面 厚度16cm","UNIT":"m2","QUANTITIES":"3262.5","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"碎石垫层 厚度20cm","UNIT":"m2","QUANTITIES":"3770","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"石渣混合料路基填筑(利用开挖料)","UNIT":"m3实方","QUANTITIES":"4809.82","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"石渣混合料路基填筑(外购)","UNIT":"m3实方","QUANTITIES":"6404.59","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"二","PROJECT_LIST_NAME":"钢板桩支护","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"打拔槽钢钢板桩 支护 (含使用费)","UNIT":"t钢板桩","QUANTITIES":"471.169","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"打拔拉森钢板桩 支护 (含使用费)","UNIT":"t钢板桩","QUANTITIES":"8415.744","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"工作坑及接收井打拔槽钢钢板桩 支护(含使用费)","UNIT":"t钢板桩","QUANTITIES":"6.827","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"型钢横梁及支撑安装拆除(含使用费)","UNIT":"t","QUANTITIES":"648.757","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"三","PROJECT_LIST_NAME":"抽水台班","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"点工抽水台班","UNIT":"台班","QUANTITIES":"150","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"四","PROJECT_LIST_NAME":"施工专项工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"安全生产措施费","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"安全生产措施费","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"施工现场标准化建设工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"施工现场标准化建设工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"五","PROJECT_LIST_NAME":"施工房屋建筑工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"办公、生活及文化福利建筑","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"办公、生活及文化福利建筑","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"六","PROJECT_LIST_NAME":"其他临时工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"其他临时工程","UNIT":"元","QUANTITIES":"25170042","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"合计","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":""},{"PROJECT_NUMBER":"第二部分","PROJECT_LIST_NAME":"输水管线设备及安装工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"一","PROJECT_LIST_NAME":"管线工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"水平定向钻开挖发送沟土方","UNIT":"m3","QUANTITIES":"4893.75","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"水平定向钻开挖发送沟回填土","UNIT":"m3实方","QUANTITIES":"4893.75","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"拆除玻璃钢管 管径 (DN1400)","UNIT":"m","QUANTITIES":"5","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"铺设Q235B钢管φ1420×14(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"m","QUANTITIES":"5","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"铺设Q235B钢管φ820×10(工作压力0.4Mpa,管道试压及冲洗,外包砼段,含内外壁防腐)","UNIT":"m","QUANTITIES":"1518.63","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"铺设Q235B钢管φ325×8(工作压力0.4Mpa,管道试压及冲洗,埋地段,含内外壁防腐)","UNIT":"m","QUANTITIES":"50","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"铺设Q235B钢管φ820×10(工作压力0.4Mpa,管道试压及冲洗,外露段,含内外壁防腐)","UNIT":"m","QUANTITIES":"12.13","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"铺设Q235B钢管φ820×10(工作压力0.4Mpa,管道试压及冲洗,埋地段,含内外壁防腐)","UNIT":"m","QUANTITIES":"3018.58","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"定向钻机穿越敷管 DN800(1#)","UNIT":"m","QUANTITIES":"0","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"定向钻机穿越敷管 DN800(2#)","UNIT":"m","QUANTITIES":"0","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"(1#)定向钻机穿越敷Q235B钢管φ820×12(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐,土壤类别详见地勘报告)","UNIT":"m","QUANTITIES":"351.6","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"(2#)定向钻机穿越敷Q235B钢管φ820×12(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐,土壤类别详见地勘报告)","UNIT":"m","QUANTITIES":"350.46","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"13","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管35.4°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"14","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管27.6°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"15","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管25.7°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"16","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管24.4°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"17","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管26.1°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"18","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管22.6°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"19","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管41.8°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"20","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管32.5°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"21","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管64.9°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"22","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管35.6°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"23","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管60.9°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"24","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管35.2°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"25","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管25.6°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"26","PROJECT_LIST_NAME":"Q235B钢管φ820×10弯管29.1°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","UNIT":"个","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"二","PROJECT_LIST_NAME":"配水工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"IFC300W DN800流量计","UNIT":"套","QUANTITIES":"1","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"C2F-10 DN300伸缩节","UNIT":"个","QUANTITIES":"7","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"C2F-6 DN800伸缩节","UNIT":"个","QUANTITIES":"5","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"φ1020*10-300钢套管","UNIT":"个","QUANTITIES":"0","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"钢套管及止水环制作安装( φ1020*10-300,φ1320/φ1020*10)","UNIT":"个","QUANTITIES":"2","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"钢套管及止水环制作安装( φ960*10-300,φ1200/φ962*10)","UNIT":"个","QUANTITIES":"8","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"钢套管及止水环制作安装( φ1040*10-290,φ1340/φ1042*10)","UNIT":"个","QUANTITIES":"18","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"钢套管及止水环制作安装( φ540*10-260,φ800/φ542*10)","UNIT":"个","QUANTITIES":"14","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"DN300偏心半球阀PN1.0MPa","UNIT":"个","QUANTITIES":"5","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"Dd941X-6,DN300蝶阀","UNIT":"个","QUANTITIES":"2","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"Dd941X-6,DN800蝶阀","UNIT":"个","QUANTITIES":"4","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"P42X-10,DN100排气阀","UNIT":"个","QUANTITIES":"9","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"13","PROJECT_LIST_NAME":"Z45X-10,DN100闸阀","UNIT":"个","QUANTITIES":"9","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"14","PROJECT_LIST_NAME":"钢制弯管DN800","UNIT":"个","QUANTITIES":"0","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"15","PROJECT_LIST_NAME":"钢制排泥三通DN800*325","UNIT":"个","QUANTITIES":"5","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"16","PROJECT_LIST_NAME":"φ1320/φ1020*10止水环","UNIT":"个","QUANTITIES":"0","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"17","PROJECT_LIST_NAME":"无缝钢管DN108*5-220","UNIT":"m","QUANTITIES":"1.98","UNIVALENT":0,"TOTAL":0},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"合计","UNIT":"","QUANTITIES":"","UNIVALENT":0,"TOTAL":0}],"CONSTRUCTION_PROJECT_AMOUNT_PRICE_LIST":[{"index":"第一部分","name":"建筑工程","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"一","name":"管道土建工程","unit":"","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"拆除混凝土路面","unit":"m3","project_amount":"1165.83","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"拆除路面水泥稳定层","unit":"m3","project_amount":"1133.78","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"拆除路面碎石层","unit":"m3","project_amount":"1207.71","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"拆除路沿石(立缘石) (石质截面半周长50cm以内)","unit":"m","project_amount":"579.86","unit_price":"","combined_price":"","remark":""},{"index":"5","name":"拆除路沿石(立缘石) (石质截面半周长50cm以外)","unit":"m","project_amount":"222","unit_price":"","combined_price":"","remark":""},{"index":"6","name":"商品混凝土路面 厚度22cm","unit":"m2","project_amount":"5299.22","unit_price":"","combined_price":"","remark":""},{"index":"7","name":"路基预拌商品5%水泥稳定层厚度20cm","unit":"m2","project_amount":"5299.22","unit_price":"","combined_price":"","remark":""},{"index":"8","name":"路面基层 碎石 压实厚度20cm","unit":"m2","project_amount":"5299.22","unit_price":"","combined_price":"","remark":""},{"index":"9","name":"拆除人行道面砖","unit":"m3","project_amount":"66.54","unit_price":"","combined_price":"","remark":""},{"index":"10","name":"人行道20*10*6cm彩色环保透水砖(1:3干拌水泥砂浆厚30)","unit":"m2","project_amount":"739.32","unit_price":"","combined_price":"","remark":""},{"index":"11","name":"人行道预拌商品5%水泥稳定层厚度10cm","unit":"m2","project_amount":"739.32","unit_price":"","combined_price":"","remark":""},{"index":"12","name":"人行道基层 碎石 压实厚度20cm","unit":"m2","project_amount":"739.32","unit_price":"","combined_price":"","remark":""},{"index":"13","name":"路缘石铺设 石质缘石(利用旧路缘石)","unit":"延长m","project_amount":"801.86","unit_price":"","combined_price":"","remark":""},{"index":"14","name":"挖沟槽土方2m以内 土类级别 Ⅲ","unit":"m3","project_amount":"7406.75","unit_price":"","combined_price":"","remark":""},{"index":"15","name":"挖沟槽土方4m以内 土类级别 Ⅲ","unit":"m3","project_amount":"4645.71","unit_price":"","combined_price":"","remark":""},{"index":"16","name":"挖装沟槽淤泥外弃7km","unit":"m3","project_amount":"2074.19","unit_price":"","combined_price":"","remark":""},{"index":"17","name":"工作坑及接收坑开挖三类土","unit":"m3","project_amount":"32","unit_price":"","combined_price":"","remark":""},{"index":"18","name":"管槽土料回填夯实(利用开挖料)","unit":"m3实方","project_amount":"9474.65","unit_price":"","combined_price":"","remark":""},{"index":"19","name":"管道中粗砂垫层","unit":"m3","project_amount":"1762.79","unit_price":"","combined_price":"","remark":""},{"index":"20","name":"管槽抛填块石","unit":"m3","project_amount":"3476.68","unit_price":"","combined_price":"","remark":""},{"index":"21","name":"C20商品混凝土包管","unit":"m3","project_amount":"2204.14","unit_price":"","combined_price":"","remark":""},{"index":"22","name":"普通平面钢模板 制作安拆","unit":"m2","project_amount":"4390.65","unit_price":"","combined_price":"","remark":""},{"index":"23","name":"C20商品砼管道镇墩","unit":"m3","project_amount":"34.3","unit_price":"","combined_price":"","remark":""},{"index":"24","name":"流量阀井(JYGS-S530-142-143)","unit":"座","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"25","name":"蝶阀井(05S502-90)","unit":"座","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"26","name":"排气阀井(05S502-164)","unit":"座","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"27","name":"蝶阀井(05S502-89)","unit":"座","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"28","name":"排水泥阀井(详见设计图纸)","unit":"座","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"29","name":"湿井(详见设计图纸)","unit":"座","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"30","name":"拆除混凝土挡墙","unit":"m3","project_amount":"120","unit_price":"","combined_price":"","remark":""},{"index":"31","name":"C20商品砼挡墙","unit":"m3","project_amount":"120","unit_price":"","combined_price":"","remark":""},{"index":"32","name":"普通平面钢模板 制作安拆","unit":"m2","project_amount":"80","unit_price":"","combined_price":"","remark":""},{"index":"33","name":"石立柱安装(50%利旧)","unit":"根","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"34","name":"石栏杆安装(利旧)","unit":"m","project_amount":"5","unit_price":"","combined_price":"","remark":""},{"index":"35","name":"石栏杆安装","unit":"m","project_amount":"5","unit_price":"","combined_price":"","remark":""},{"index":"36","name":"人工拆除石栏杆","unit":"m","project_amount":"10","unit_price":"","combined_price":"","remark":""},{"index":"37","name":"C20砼标志桩制作安装","unit":"m3","project_amount":"0.61","unit_price":"","combined_price":"","remark":""},{"index":"38","name":"标志桩钢筋制作与安装","unit":"t","project_amount":"0.015","unit_price":"","combined_price":"","remark":""},{"index":"二","name":"阀井工程","unit":"","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"钢筋砼流量计阀井(井径2.6*2.6m,井深2.73m)","unit":"座","project_amount":"1","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"C15商品砼垫层100厚","unit":"m3","project_amount":"1.32","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"C25商品砼底板300厚","unit":"m3","project_amount":"3.47","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"C25商品砼井壁300厚","unit":"m3","project_amount":"9.5","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"C25预制商品混凝土井室盖板制作安装","unit":"m3","project_amount":"1.09","unit_price":"","combined_price":"","remark":""},{"index":"5","name":"集水坑砼管管径DN300mm","unit":"m","project_amount":"0.5","unit_price":"","combined_price":"","remark":""},{"index":"6","name":"C15商品砼管道支墩","unit":"m3","project_amount":"0.22","unit_price":"","combined_price":"","remark":""},{"index":"7","name":"球墨铸铁井盖井座φ800","unit":"套","project_amount":"1","unit_price":"","combined_price":"","remark":""},{"index":"8","name":"爬梯 (φ25)","unit":"步","project_amount":"9","unit_price":"","combined_price":"","remark":""},{"index":"9","name":"钢筋制作与安装","unit":"t","project_amount":"2.107","unit_price":"","combined_price":"","remark":""},{"index":"10","name":"井壁普通平面钢模板制作安拆","unit":"m2","project_amount":"63.34","unit_price":"","combined_price":"","remark":""},{"index":"11","name":"胶合木模板 制作安拆","unit":"m2","project_amount":"6.96","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"DN800钢筋砼蝶阀井(井径1.8*2.6m,井深2.41m,详05S502P90)","unit":"座","project_amount":"4","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"C15商品砼垫层100厚","unit":"m3","project_amount":"3.07","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"C25商品砼底板250厚","unit":"m3","project_amount":"6.6","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"C25商品砼井壁200厚","unit":"m3","project_amount":"17.65","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"C25预制商品混凝土井室盖板制作安装","unit":"m3","project_amount":"5.56","unit_price":"","combined_price":"","remark":""},{"index":"5","name":"集水坑砼管管径DN300mm","unit":"m","project_amount":"2","unit_price":"","combined_price":"","remark":""},{"index":"6","name":"C15商品砼管道支墩","unit":"m3","project_amount":"0.58","unit_price":"","combined_price":"","remark":""},{"index":"7","name":"球墨铸铁井盖井座φ800","unit":"套","project_amount":"4","unit_price":"","combined_price":"","remark":""},{"index":"8","name":"塑钢爬梯踏步","unit":"步","project_amount":"28","unit_price":"","combined_price":"","remark":""},{"index":"9","name":"钢筋制作与安装","unit":"t","project_amount":"4.785","unit_price":"","combined_price":"","remark":""},{"index":"10","name":"井壁普通平面钢模板制作安拆","unit":"m2","project_amount":"176.49","unit_price":"","combined_price":"","remark":""},{"index":"11","name":"胶合木模板 制作安拆","unit":"m2","project_amount":"18.72","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"DN300钢筋砼蝶阀井(井径1.4*1.4m,井深2.13m,详05S502P89)","unit":"座","project_amount":"2","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"C15商品砼垫层100厚","unit":"m3","project_amount":"0.72","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"C25商品砼底板200厚","unit":"m3","project_amount":"1.16","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"C25商品砼井壁150厚","unit":"m3","project_amount":"3.92","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"C25预制商品混凝土井室盖板制作安装","unit":"m3","project_amount":"0.62","unit_price":"","combined_price":"","remark":""},{"index":"5","name":"集水坑砼管管径DN300mm","unit":"m","project_amount":"1","unit_price":"","combined_price":"","remark":""},{"index":"6","name":"C15商品砼管道支墩","unit":"m3","project_amount":"0.05","unit_price":"","combined_price":"","remark":""},{"index":"7","name":"球墨铸铁井盖井座φ800","unit":"套","project_amount":"2","unit_price":"","combined_price":"","remark":""},{"index":"8","name":"塑钢爬梯踏步","unit":"步","project_amount":"12","unit_price":"","combined_price":"","remark":""},{"index":"9","name":"钢筋制作与安装","unit":"t","project_amount":"0.93","unit_price":"","combined_price":"","remark":""},{"index":"10","name":"井壁普通平面钢模板制作安拆","unit":"m2","project_amount":"52.21","unit_price":"","combined_price":"","remark":""},{"index":"11","name":"胶合木模板 制作安拆","unit":"m2","project_amount":"4.96","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"DN800钢筋砼排气阀井(井径1.4*1.4m,井深1.89m,详05S502P164)","unit":"座","project_amount":"9","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"C15商品砼垫层100厚","unit":"m3","project_amount":"3.6","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"C25商品砼底板250厚","unit":"m3","project_amount":"7.29","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"C25商品砼井壁200厚","unit":"m3","project_amount":"19.85","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"C25预制商品混凝土井室盖板制作安装","unit":"m3","project_amount":"4.32","unit_price":"","combined_price":"","remark":""},{"index":"5","name":"C15商品砼管道支墩","unit":"m3","project_amount":"1.3","unit_price":"","combined_price":"","remark":""},{"index":"6","name":"球墨铸铁井盖井座φ800","unit":"套","project_amount":"9","unit_price":"","combined_price":"","remark":""},{"index":"7","name":"塑钢爬梯踏步","unit":"步","project_amount":"45","unit_price":"","combined_price":"","remark":""},{"index":"8","name":"钢筋制作与安装","unit":"t","project_amount":"4.498","unit_price":"","combined_price":"","remark":""},{"index":"9","name":"井壁普通平面钢模板制作安拆","unit":"m2","project_amount":"198.5","unit_price":"","combined_price":"","remark":""},{"index":"10","name":"胶合木模板 制作安拆","unit":"m2","project_amount":"32.04","unit_price":"","combined_price":"","remark":""},{"index":"5","name":"DN800钢筋砼排水泥阀井(圆形)(井径2.0m,井深2.44m)","unit":"座","project_amount":"5","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"砂碎石垫层200厚","unit":"m3","project_amount":"6.6","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"C15商品砼垫层100厚","unit":"m3","project_amount":"3.3","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"C25商品砼底板250厚","unit":"m3","project_amount":"7.15","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"C25商品砼井壁250厚","unit":"m3","project_amount":"21.46","unit_price":"","combined_price":"","remark":""},{"index":"5","name":"C25预制商品混凝土井室盖板制作安装","unit":"m3","project_amount":"2.2","unit_price":"","combined_price":"","remark":""},{"index":"6","name":"集水坑砼管管径DN300mm","unit":"m","project_amount":"2.75","unit_price":"","combined_price":"","remark":""},{"index":"7","name":"C15商品砼管道支墩","unit":"m3","project_amount":"0.22","unit_price":"","combined_price":"","remark":""},{"index":"8","name":"球墨铸铁井盖井座φ800","unit":"套","project_amount":"5","unit_price":"","combined_price":"","remark":""},{"index":"9","name":"爬梯 (φ20)","unit":"步","project_amount":"30","unit_price":"","combined_price":"","remark":""},{"index":"10","name":"钢筋制作与安装","unit":"t","project_amount":"5.569","unit_price":"","combined_price":"","remark":""},{"index":"11","name":"井壁普通曲面钢模板制作安拆","unit":"m2","project_amount":"172.03","unit_price":"","combined_price":"","remark":""},{"index":"12","name":"胶合木模板 制作安拆","unit":"m2","project_amount":"18.04","unit_price":"","combined_price":"","remark":""},{"index":"6","name":"钢筋砼排泥湿井(圆形)(井径1.2m,井深2.44m)","unit":"座","project_amount":"5","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"砂碎石垫层200厚","unit":"m3","project_amount":"3.46","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"C15商品砼垫层100厚","unit":"m3","project_amount":"1.73","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"C25商品砼底板250厚","unit":"m3","project_amount":"3.54","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"C25商品砼井壁250厚","unit":"m3","project_amount":"13.83","unit_price":"","combined_price":"","remark":""},{"index":"5","name":"C25预制商品混凝土井室盖板制作安装","unit":"m3","project_amount":"0.88","unit_price":"","combined_price":"","remark":""},{"index":"6","name":"球墨铸铁井盖井座φ800","unit":"套","project_amount":"5","unit_price":"","combined_price":"","remark":""},{"index":"7","name":"爬梯 (φ20)","unit":"步","project_amount":"30","unit_price":"","combined_price":"","remark":""},{"index":"8","name":"钢筋制作与安装","unit":"t","project_amount":"3.478","unit_price":"","combined_price":"","remark":""},{"index":"9","name":"井壁普通曲面钢模板制作安拆","unit":"m2","project_amount":"110.64","unit_price":"","combined_price":"","remark":""},{"index":"10","name":"胶合木模板 制作安拆","unit":"m2","project_amount":"10.75","unit_price":"","combined_price":"","remark":""},{"index":"","name":"合计","unit":"","project_amount":"","unit_price":"","combined_price":"","remark":""}],"TEMPORARY_PROJECT_AMOUNT_PRICE_LIST":[{"index":"第三部分","name":"临时工程","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"一","name":"施工便道","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"泥结碎石路面 厚度16cm","unit":"m2","project_amount":"3262.5","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"碎石垫层 厚度20cm","unit":"m2","project_amount":"3770","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"石渣混合料路基填筑(利用开挖料)","unit":"m3实方","project_amount":"4809.82","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"石渣混合料路基填筑(外购)","unit":"m3实方","project_amount":"6404.59","unit_price":"","combined_price":"","remark":""},{"index":"二","name":"钢板桩支护","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"打拔槽钢钢板桩 支护 (含使用费)","unit":"t钢板桩","project_amount":"471.169","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"打拔拉森钢板桩 支护 (含使用费)","unit":"t钢板桩","project_amount":"8415.744","unit_price":"","combined_price":"","remark":""},{"index":"3","name":"工作坑及接收井打拔槽钢钢板桩 支护(含使用费)","unit":"t钢板桩","project_amount":"6.827","unit_price":"","combined_price":"","remark":""},{"index":"4","name":"型钢横梁及支撑安装拆除(含使用费)","unit":"t","project_amount":"648.757","unit_price":"","combined_price":"","remark":""},{"index":"三","name":"抽水台班","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"点工抽水台班","unit":"台班","project_amount":"150","unit_price":"","combined_price":"","remark":""},{"index":"四","name":"施工专项工程","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"安全生产措施费","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"安全生产措施费","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"2","name":"施工现场标准化建设工程","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"施工现场标准化建设工程","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"五","name":"施工房屋建筑工程","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"办公、生活及文化福利建筑","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"办公、生活及文化福利建筑","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"六","name":"其他临时工程","unit":"元","project_amount":"0","unit_price":"","combined_price":"","remark":""},{"index":"1","name":"其他临时工程","unit":"元","project_amount":"25170042","unit_price":"","combined_price":"","remark":""},{"index":"","name":"合计","unit":"","project_amount":"","unit_price":"","combined_price":"","remark":""}],"OTHER_PROJECT_AMOUNT_PRICE_LIST":[],"ELECTRICAL_OR_METALLIC_STRUCTURES_PROJECT_AMOUNT_PRICE_LIST":[],"EQUIPMENT_AND_INSTALLATION_PROJECT_AMOUNT_PRICE_LIST":[{"index":"第二部分","name":"输水管线设备及安装工程","unit":"元","project_amount":"0","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"一","name":"管线工程","unit":"元","project_amount":"0","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"1","name":"水平定向钻开挖发送沟土方","unit":"m3","project_amount":"4893.75","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"2","name":"水平定向钻开挖发送沟回填土","unit":"m3实方","project_amount":"4893.75","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"3","name":"拆除玻璃钢管 管径 (DN1400)","unit":"m","project_amount":"5","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"4","name":"铺设Q235B钢管φ1420×14(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"m","project_amount":"5","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"5","name":"铺设Q235B钢管φ820×10(工作压力0.4Mpa,管道试压及冲洗,外包砼段,含内外壁防腐)","unit":"m","project_amount":"1518.63","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"6","name":"铺设Q235B钢管φ325×8(工作压力0.4Mpa,管道试压及冲洗,埋地段,含内外壁防腐)","unit":"m","project_amount":"50","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"7","name":"铺设Q235B钢管φ820×10(工作压力0.4Mpa,管道试压及冲洗,外露段,含内外壁防腐)","unit":"m","project_amount":"12.13","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"8","name":"铺设Q235B钢管φ820×10(工作压力0.4Mpa,管道试压及冲洗,埋地段,含内外壁防腐)","unit":"m","project_amount":"3018.58","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"9","name":"定向钻机穿越敷管 DN800(1#)","unit":"m","project_amount":"0","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"10","name":"定向钻机穿越敷管 DN800(2#)","unit":"m","project_amount":"0","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"11","name":"(1#)定向钻机穿越敷Q235B钢管φ820×12(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐,土壤类别详见地勘报告)","unit":"m","project_amount":"351.6","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"12","name":"(2#)定向钻机穿越敷Q235B钢管φ820×12(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐,土壤类别详见地勘报告)","unit":"m","project_amount":"350.46","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"13","name":"Q235B钢管φ820×10弯管35.4°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"14","name":"Q235B钢管φ820×10弯管27.6°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"15","name":"Q235B钢管φ820×10弯管25.7°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"16","name":"Q235B钢管φ820×10弯管24.4°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"17","name":"Q235B钢管φ820×10弯管26.1°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"18","name":"Q235B钢管φ820×10弯管22.6°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"19","name":"Q235B钢管φ820×10弯管41.8°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"20","name":"Q235B钢管φ820×10弯管32.5°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"21","name":"Q235B钢管φ820×10弯管64.9°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"22","name":"Q235B钢管φ820×10弯管35.6°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"23","name":"Q235B钢管φ820×10弯管60.9°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"24","name":"Q235B钢管φ820×10弯管35.2°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"25","name":"Q235B钢管φ820×10弯管25.6°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"26","name":"Q235B钢管φ820×10弯管29.1°(工作压力0.4Mpa,管道试压及冲洗,含内外壁防腐)","unit":"个","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"二","name":"配水工程","unit":"元","project_amount":"0","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"1","name":"IFC300W DN800流量计","unit":"套","project_amount":"1","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"2","name":"C2F-10 DN300伸缩节","unit":"个","project_amount":"7","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"3","name":"C2F-6 DN800伸缩节","unit":"个","project_amount":"5","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"4","name":"φ1020*10-300钢套管","unit":"个","project_amount":"0","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"5","name":"钢套管及止水环制作安装( φ1020*10-300,φ1320/φ1020*10)","unit":"个","project_amount":"2","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"6","name":"钢套管及止水环制作安装( φ960*10-300,φ1200/φ962*10)","unit":"个","project_amount":"8","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"7","name":"钢套管及止水环制作安装( φ1040*10-290,φ1340/φ1042*10)","unit":"个","project_amount":"18","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"8","name":"钢套管及止水环制作安装( φ540*10-260,φ800/φ542*10)","unit":"个","project_amount":"14","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"9","name":"DN300偏心半球阀PN1.0MPa","unit":"个","project_amount":"5","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"10","name":"Dd941X-6,DN300蝶阀","unit":"个","project_amount":"2","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"11","name":"Dd941X-6,DN800蝶阀","unit":"个","project_amount":"4","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"12","name":"P42X-10,DN100排气阀","unit":"个","project_amount":"9","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"13","name":"Z45X-10,DN100闸阀","unit":"个","project_amount":"9","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"14","name":"钢制弯管DN800","unit":"个","project_amount":"0","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"15","name":"钢制排泥三通DN800*325","unit":"个","project_amount":"5","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"16","name":"φ1320/φ1020*10止水环","unit":"个","project_amount":"0","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"17","name":"无缝钢管DN108*5-220","unit":"m","project_amount":"1.98","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""},{"index":"","name":"合计","unit":"","project_amount":"","unit_equip_price":"","unit_install_price":"","unit_price":0,"combined_equip_price":"","combined_install_price":"","combined_price":0,"remark":""}]}},"updateContent_price":{"CONTROL_PRICE":"26131808","COMPETITION_PRICE":"25629158","NON_COMPETITION_PRICE":"502650"},"UUM_ENTP_BASE_INFO":{"BusinessData":"","OrganizationNumber":"","Email":"1244685@qq.com","LocaltaxData":"","tbwjAttachments":{"Busattachments":[],"Socattachments":[{"id":"5a168e14a6e3253c60d5104d","md5":"592F6749D61BF66F0CF20C68D3FBF7A1","name":"机电招标-副本-丁熙法人.jpg","new_id":"5a168e14a6e3253c60d5104d","url":"/file/getcontent/5a168e14a6e3253c60d5104d.jpg"},{"id":"5f5ec97f089c8e2444fd004d","md5":"A1DEDC2F298FE22E476D55E05804343F","name":"2018 机电招标营业执照副本.jpg","new_id":"5f5ec97f089c8e2444fd004d","size":341849,"url":"/file/getcontent/5f5ec97f089c8e2444fd004d.jpg"}],"Staattachments":[],"Govattachments":[],"Orgattachments":[],"Locattachments":[]},"BasicName":"福建省机电设备招标有限公司","BasicUnitName":"福建省机电设备招标有限公司","LocaltaxNumber":"","LeType":"1","Currency":"156","LeoIDType":"身份证","GoverData":"","StateTaxNumberDas":false,"LeoIDNumber":"350102196902036412","ConPhone":"13599963105","CreditRatingLabel":"","OrganizationData":"","unitName":"福建省机电设备招标有限公司","CreditRating":"AAA","ENTP_PROPERTY":"1","LeoPhone":"0591-38872062","City":"福州","Province":"福建","GoverNumber":"","SocietyData":"2065-11-15","OrganizationNumberDas":false,"Country":"中国

联系人:郝工
电话:010-68960698
邮箱:1049263697@qq.com

标签: 水管 产业

0人觉得有用

招标
业主

-

关注我们可获得更多采购需求

关注
相关推荐
 
查看详情 免费咨询

最近搜索

热门搜索