福建省南平市浦城县南浦灌区续建配套与节水改造工程莲塘镇灌片（2021年度）第二标段
福建省南平市浦城县南浦灌区续建配套与节水改造工程莲塘镇灌片（2021年度）第二标段
本招标项目专用合同条款如下：
1.1.2 合同当事人和人员
1.1.2.2 发包人：_浦城县莲塘镇人民政府____
1.1.2.3 承包人：_____________________________
1.1.2.5 分包人：_____________________________
1.1.2.6 监理人：_____________________________
1.1.4 日期
1.1.4.3 工期：_100日历天（其中各关键节点的工期：主体在70日历天内完成）
1.1.4.5缺陷责任期（工程质量保修期）：__工程通过合同工程完工验收后1年____________________________
进入合同文件的各项文件及其优先顺序是_____________________________。
1.7.2来往函件均应按技术标准和要求（合同技术条款）约定的期限送达监理人，并办理签收手续。
2.3.2 发包人提供的施工用地范围为：发包人负责办理招标图纸所示范围内用地征地，向承包人提供能满足施工条件所需的用地，提供的用地期限在签订合同书时商定。超出招标图纸所示范围的用地，由承包人报监理人及发包人审批，若确需增加临时用地，经发包人同意后负责征用，发生费用由承包人自行承担。
2.3.3 承包人自行勘察的施工场地范围为：__发包人负责办理工地范围内的征地。施工用地由承包人自行勘察并对其结果自行负责，提供的用地范围和期限在签订协议书时商定。
(根据发包人的合同管理要求补充)
（1）……
（2）……
3.1.1监理人须根据发包人事先批准的权力范围行使权力，发包人批准的权力范围：（填写监理人须经发包人批准才能行使的权力，以下示例供参考）
（1）按第4.3条约定，批准工程的分包。
（2）按第11.3条约定，确定延长完工期限。
（3）按第15.6条约定，批准暂列金额的使用。
……
4.1.10其他义务
（1）为确保工程施工进度、质量和安全，履行承包人投标时的承诺，承包人保证按照经发包人、监理工程师批准的工程施工进度计划进行施工，按照规定建立施工项目组织管理机构，按投标文件承诺派出现场施工主要管理人员（包括项目经理、项目技术负责人、施工员、质量员、安全员、造价员和材料员等）和施工班组技术骨干以及施工人员到发包人工地现场，完成各项承包工作。
（2）承担施工安全保卫工作及夜间施工照明的责任和要求。
（3）办理有关施工场地交通、环卫和施工噪音管理等手续。
（4）承包人应负责已完工部分工程的保护工作；应做好防雷电、防火等的安全防护工作；承担施工现场和施工人员的治安、环境卫生、计生、外来人员暂住手续等管理工作和相关费用；若发生任何事故，均由承包人负责。
（5）承包人应负责整个场地的安全文明卫生管理，做到文明施工，保持施工场地清洁，施工现场做好标识、围挡及防护措施，保证过往车辆及行人的人生及财产安全。所有施工建筑垃圾应全部清运出现场。场地平整、场地道路、场地排水排污附属设施等，均由承包人自行负责施工并承担费用，包括在合同价款中。施工过程中发生的各项清理费用、临时性收费、临时设施费、不可预见费用和施工临时便道、堆放场、预制场等临时性占用场地费，由承包方承担，均包括在合同价款中。承包人必须保证整个工程项目在建设过程中无重大安全责任事故产生，并争创“文明工地”。
（6）承包人若发现合同图纸及工料规范之内或互相之间有任何差异，须立刻以书面通知发包人（监理人），说明差异之处，而发包人（监理人）须给予指令。
（7）承包人严把材料质量关。所有进场原材料、成品、半成品、构配件必须向监理单位报验，并出具相应的质量证明文件，按规定经监理见证取样，交由具有相应资质的检测机构进行复验，复验合格后方可使用。
（8）承包人应严格工序报验程序。每道工序完成后，必须在质检员检查合格并填写工序质量评定表、隐蔽验收记录后向监理人报验，由监理人员验收签字后，才能进行下道工序施工。工序验收资料未经监理人员签字的，该工序视为未验收，不得进入下道工序施工。
（9）承包人应规范施工文件资料管理。施工文件资料应按《水利工程建设项目档案管理规定》（水办[2005]480号）进行整理归档。文件资料应随施工进度及时整理，所需表格应按规定中的要求认真填写、字迹清楚、项目齐全、记录准确、真实完整。
（10）承包人应严格遵守国家有关解决拖欠工程款和民工工资的法律、法规，及时支付工程中的材料、设备货款及民工工资等费用。承包人不得以任何借口拖欠材料、设备货款及民工工资等费用，如果出现此种现象，发包人有权代为支付其拖欠的材料、设备货款及民工工资，并从应付给承包人的工程款中扣除相应款项。对恶意拖欠和拒不按计划支付的，作为不良记录纳入水利建设市场信用信息管理系统。
4.2 履约担保
承包人是否提供履约担保：是。履约担保的形式和金额：在发出中标通知书后15日内且在合同签订前，承包人应提交履约担保。履约担保采用现金（银行转账或电汇）或银行保函形式提交，为签约合同价的 10%。在合同工程完工证书颁发后 28 天内无息退还给承包人。
4.3.2 允许承包人分包的工程项目、工作内容与分包金额限额为：
（1）工程项目：_____________________。
（2）工作内容：_____________________。
（3）分包金额限额：_____________________。
4.3.10 分包人项目管理机构的设立：_____________________。
4.5 承包人项目经理
4.5.5补充条款：承包人应按投标承诺指派项目经理（建造师）到职，项目经理（建造师）为承包人书面委派常驻现场负责执行和管理本合同工程的代表。凡本合同执行中的有关技术、工程进度、现场协调、质量管理、安全管理、计量支付、竣工结算等方面工作，由其代表承包人全面负责。合同期间承包人更换项目经理（建造师）应先提出书面申请，并应在更换14天前将更换人员报经发包人、监理人批准，且所更换人员的资格、业绩和信誉不得低于承包人投标时承诺标准，经发包人和监理人书面批准后方可更换，工作移接完毕后方可离开。 本合同的项目经理（建造师）未到职或擅自更换(除因病长期住院治疗及发包人认可的原因外)每人次承包人须向发包人交纳违约金人民币10万元。本合同的项目经理（建造师）每月出勤不得少于22天，发包人有权制定考勤办法。本合同的项目经理（建造师）需常驻现场，短期离开施工场地，应事先征得监理人及发包人同意，并委派代表代行其职责。如发现项目经理（建造师）未签到或没有在现场履行职责，且未事先征得监理人及发包人同意，则发包人可按承包人项目经理擅自离岗，承包人需按每人天1000元标准向发包人支付违约金，上述约定的违约金发包人有权从尚未支付的工程款中直接扣除。
4.6 承包人人员的管理
4.6.3承包人应按投标承诺指派技术负责人等主要管理人员到职，合同期间如需更换技术负责人等，需提前14天将拟代之以相应资历（投标时要求的技术负责人资历）人员报经发包人、监理人批准，工作移接完毕后方可离开。本合同的技术负责人未到职或擅自更换每人次罚款人民币10万元。本合同的关键岗位人员（施工员、质检员、安全员、材料员）未到职或擅自更换每人次罚款人民币1万元。本合同的技术负责人和关键岗位人员每月出勤不得少于22天，发包人有权制定考勤办法。技术负责人擅自离岗，经发现承包人需按每人天1000元标准向发包人支付违约金。关键岗位人员擅自离岗，经发现承包人需按每人天300元标准向发包人支付违约金。上述约定的违约金发包人有权从尚未支付的工程款中直接扣除。
4.11.1 不利物质条件的范围：_____________________。
5.2.1 发包人提供的材料和工程设备见下表：本项目发包人不提供材料和工程设备
（1）发包人提供的的施工设备见下表：无
道路通行权和场外设施的约定：承包人应根据工程的施工需要，配合办理取得出入施工场地的专用和临时道路的通行权，以及取得为工程建设所需修建场外设施的权利，并承担有关费用。发包人应协助承包人办理上述手续。
8.1.1 施工控制网的约定：_发包人应在载明的开工日期前7天通过监理人向承包人提供测量基准点、基准线和水准点及其书面资料。承包人应在收到上述资料后14天内，根据国家测绘基准、测绘系统和工程测量技术规范，按上述基准点（线）以及合同工程精度要求，测设施工控制网，并将施工控制网资料报送监理人审批。监理人应在收到报批件后7天内批复承包人_。9 施工安全、治安保卫和环境保护
9.1.4 发包人提供__另行约定资料，其余资料由承包人负责收集。
9.2.12 下列工程应编制专项施工方案：_土方开挖、模板工程、其他危险性较大的工程。其中__/___应组织专家论证和审查。
9.7.1本合同文明工地的约定：_按照主管部门有关规定执行。
承包人应当按照发包人（监理人）的指示组建现场治安保卫机构，承担治安保卫职责；
承包人应负责编制《施工场地治安管理计划和突发治安事件应急预案》，并在开工后3日内报送监理人（发包人）审批后执行。
11.4.3本合同工程界定异常恶劣气候条件的范围为：
(1) 每小时降雨量达16毫米以上，或连续12小时降雨量达35毫米以上，或连续24小时降雨量达60毫米以上的降雨，连续大于3天；
(2) 风速大于25米/秒的10及以上台风灾害；
(3) 日气温超过38℃的高温，连续大于7天；
(4) 日气温低于0℃的严寒，连续大于7天；
(5) 造成工程损坏的冰雹和大雪灾害；
(6) 其它异常恶劣气候灾害。
以项目所在地的气象主管部门发布的为准。气象主管部门未发布相关气候数据的，双方约定由监理人按有关规定认定。
（1）因承包人原因造成工期延误，承包人应支付逾期完工违约金5000元/天。
（2）逾期完工违约金按天计算，时间自预定的完工日期起到工程完工证书中写明的实际完工日期止（扣除已批准的延长工期），按天计算。
（3）全部逾期完工违约金的总限额为不超过合同总价的5%。
（4）承包人应承担因工期延误而引起的相应延期部分的监理费用。发包人可以从应付或到期应付给承包人的任何款项中或采用其他方法扣除此违约金。
工期提前的奖金约定：不奖励_。
（5）承包人承担暂停施工责任的其它情形：_发包人因防汛安全需要暂停施工的，承包人的工期可相应顺延，由此产生的费用由承包人承担，发包人不予任何补偿。
（3）发包人承担暂停施工责任的其它情形：_按通用合同条款及其他相关规范合格标准执行。
13.7.4 重要隐蔽单元工程和关键部位单元工程质量评定的约定：_/
13.7.7 工程合格标准为：工程施工质量应达到符合《水利水电工程施工质量检验与评定规程》（SL176-2007）、《水利水电工程单元工程施工质量验收评定标准》（SL631～637-2012）、《工程施工质量验收规范》、国家、行业及地方相关施工验收规范达到合格标准；优良标准为：___/___。达到优良的奖金为：___/___。
13.8.4 工程竣工验收时，__承包人向竣工验收委员会汇报并提交历次质量缺陷处理的备案资料。
14.1.5 水工金属结构、启闭机及机电产品进场后的交货检查和验收中，承包人负责验收合格后保管全部的设备并承担相应的费用。
14.1.6 本工程实行见证取样的试块、试件及有关材料：_见证取样的范围和数量应按监理人的指示进行。本工程所有相关的检测费用均由承包人承担。
（6）增加或减少合同中关键项目的工程量超过其工程总量的____/___%，关键项目：____/__，单价调整方式：_不调整_。
15.5.2承包人实现合理化建议的奖励金额为：不予奖励。
15.8.1（1）发包人和承包人组织招标的暂估价项目：_______/_____；发包人组织招标的暂估价项目：_______/_____。
（2）发包人和承包人以招标方式选择暂估价项目供应商或分包人时，双方的权利义务关系：___________/__________。
物价波动引起的价格调整方式：__不予调整。
16.1.2 采用造价信息调整价格差额
工程造价信息的来源：__________/___________。
价格调整的项目和系数：________/_____________。
17.1.3关于计量周期的约定：本项目合同价格形式为固定单价合同，已完成工程量计量。
17.2.1预付款
（1）本招标项目无预付工程款。
17.3.1付款周期：按完成的工程量支付工程进度款。
17.3.3 进度付款证书和支付时间
①本工程设进度款，进度款按每月完成工程量的50%支付至合同价的40%，
②工程完工经有关部门验收合格后，发包人支付至合同价的80%。
③工程结算并经有关部门审核确认并完成相关资料并归档后，发包人支付至审核价的97％（处罚款除外），剩余3％作为工程质量保证金。
④每次付款前，承包人应向发包人开具等额的增值税一般纳税人专用发票，否则发包人有权拒绝付款且不承担任何的违约责任，税金由承包人自理。
17.4.1每个付款周期扣留的质量保证金为工程进度付款的_工程结算价款的3％，待缺陷责任期（工程质量保修期）满后一个月内退还质量保证金（不计利息）。
17.5.1竣工（完工）付款申请单
（1）承包人应提交完工付款申请单一式陆份。
17.5.2竣工（完工）付款证书及支付时间
监理人在收到承包人提交的完工付款申请单后14天内完成核查，发包人应在收到后14天内审核完毕，由监理人向承包人出具经发包人签认的完工付款证书，按17.3.3目的约定进行支付。
17.6.1最终结清申请单
（1）承包人应提交最终结清申请单一式陆份。
承包人应为竣工财务决算编制提供的资料：按主管部门有关规定。
本工程法人验收包括：分部工程验收、单位工程验收、合同工程完工验收；政府验收包括：__阶段验收、专项验收、竣工验收。验收条件为：___/____，验收程序为：_按现行《水利水电建设工程验收规程》(SL223-2008)规定程序组织验收。
18.2.2 本工程由发包人主持的分部工程验收为______/_________，其余由监理人主持。
18.3.4 提前投入使用的单位工程包括：________/____、____________、____________。
18.5.1 本合同工程阶段验收类别包括：按行业主管部门有关规定。
18.6.2 本合同工程专项验收类别包括：按行业主管部门有关规定_。
18.7.3 本工程按行业主管部门有关规定竣工验收技术鉴定（蓄水安全鉴定）。
18.8.1 需要在施工期运行的单位工程或工程设备为：按行业主管部门有关规定_。
18.9.1 试运行的组织：__按通用合同条款约定_；费用承担：由承包人负责_。
本工程缺陷责任期（工程质量保修期）计算如下：工程通过合同工程完工验收后1年。
建筑工程一切险和（或）安装工程一切险投保人由承包人负责；投保内容：_为本合同工程的永久工程、临时工程和设备及已运至施工工地用于永久工程的材料和设备所投的保险；保险金额、保险费率和保险期限：含在报价中，开工日起直至本合同工程竣工验收合格之日止。
承包人应对本工程施工范围内的第三者进行保险，其费用含在报价中。。
20.6.1保险凭证
承包人提交保险凭证的期限：承包人向发包人提交各项保险生效的证据和保险单副本的期限：总监理工程师签发开工令前48小时。
20.6.4保险金不足的补偿
承包人负责补偿的范围与金额：由承包人负责补偿_；发包人负责补偿的范围与金额：__由承包人负责补偿。
21. 不可抗力
21.1不可抗力的确认
视为不可抗力的情形为：
（1）地震、海啸、暴雨（雪）、台风、龙卷风、水灾等自然灾害；
（2）战争、戒严、骚乱、暴动，但纯属承包人或其分包人派遣与雇用的人员由于本合同工程施工原因引起者除外；
（3）核反应、辐射或放射性污染；
（4）空中飞行物体附落或非发包人或承包人责任造成的爆炸、火灾；
（5）瘟疫；
（6）合同约定的其他情形。
上述款中地震、台风和暴雨定义如下：
地震：指国家地震局规定的震级在4.75级以上且烈度在6度以上的地震，即破坏性地震。
台风：指中心附近最大平均风力12级或以上，即风速在32.6米／秒以上的热带气旋。是否构成台风以当地气象站的认定为准。
暴雨：连续3天，24小时降雨量达60毫米以上。
上述风、雨、震等自然灾害必须发生在合同工程所在地并造成实质性影响，才构成不可抗力。地震级别、水位、风力均以当地地震局、水文站、气象站提供的资料为准据。
22. 违约
22.1 承包人违约
22.1.1 承包人违约的情形
双方约定的承包人其他违约责任：
（1）承包人违反本合同约定进行转包或违法分包的，发包人有权责令其改正，承包人应按其转包或分包金额的20%向发包人支付违约金；
（2）承包人违反合同约定采购和使用不合格的材料和工程设备的，发包人有权责令其无条件改正、更换，并赔偿由此给发包人造成的一切损失，同时发包人有权要求承包人承担合同价款5%的违约金；
（3）因承包人的原因造成工程质量不符合合同要求的，发包人有权责令其无条件改正、重做，并赔偿由此给发包人造成的一切损失，同时发包人有权要求承包人承担合同价款5%的违约金；
（4）承包人未经批准，私自将已按照合同约定进入施工现场的材料或设备撤离施工现场的，每发生一次，发包人有权要求承包人承担合同价款1%的违约金，并赔偿由此给发包人造成的一切损失；
（5）承包人在责任缺陷期及保修期内，未能在合理期限对工程缺陷进行修复，或拒绝按发包人要求进行修复的，发包人可自行修复或委托第三方修复，发生的费用及损失全部由承包人承担；
（6）承包人明确表示或以其行为表明不履行合同主要义务的，发包人有权解除合同，承包人应赔偿给发包人造成的一切损失，同时发包人有权要求承包人承担合同价款20%的违约金；
22.1.2承包人违约的处理
承包人违约责任的承担方式：直接从工程款中扣除，不足部分由承包人以其他方式支付
合同当事人友好协商解决不成、不愿提请争议评审或不接受争议评审组意见的，约定的合同争议解决方式：_向项目所在地有管辖权的人民法院提起诉讼。
本招标项目专用合同条款如下：
1.1.2 合同当事人和人员
1.1.2.2 发包人：_浦城县莲塘镇人民政府____
1.1.2.3 承包人：_____________________________
1.1.2.5 分包人：_____________________________
1.1.2.6 监理人：_____________________________
1.1.4 日期
1.1.4.3 工期：_100日历天（其中各关键节点的工期：主体在70日历天内完成）
1.1.4.5缺陷责任期（工程质量保修期）：__工程通过合同工程完工验收后1年____________________________
进入合同文件的各项文件及其优先顺序是_____________________________。
1.7.2来往函件均应按技术标准和要求（合同技术条款）约定的期限送达监理人，并办理签收手续。
2.3.2 发包人提供的施工用地范围为：发包人负责办理招标图纸所示范围内用地征地，向承包人提供能满足施工条件所需的用地，提供的用地期限在签订合同书时商定。超出招标图纸所示范围的用地，由承包人报监理人及发包人审批，若确需增加临时用地，经发包人同意后负责征用，发生费用由承包人自行承担。
2.3.3 承包人自行勘察的施工场地范围为：__发包人负责办理工地范围内的征地。施工用地由承包人自行勘察并对其结果自行负责，提供的用地范围和期限在签订协议书时商定。
(根据发包人的合同管理要求补充)
（1）……
（2）……
3.1.1监理人须根据发包人事先批准的权力范围行使权力，发包人批准的权力范围：（填写监理人须经发包人批准才能行使的权力，以下示例供参考）
（1）按第4.3条约定，批准工程的分包。
（2）按第11.3条约定，确定延长完工期限。
（3）按第15.6条约定，批准暂列金额的使用。
……
4.1.10其他义务
（1）为确保工程施工进度、质量和安全，履行承包人投标时的承诺，承包人保证按照经发包人、监理工程师批准的工程施工进度计划进行施工，按照规定建立施工项目组织管理机构，按投标文件承诺派出现场施工主要管理人员（包括项目经理、项目技术负责人、施工员、质量员、安全员、造价员和材料员等）和施工班组技术骨干以及施工人员到发包人工地现场，完成各项承包工作。
（2）承担施工安全保卫工作及夜间施工照明的责任和要求。
（3）办理有关施工场地交通、环卫和施工噪音管理等手续。
（4）承包人应负责已完工部分工程的保护工作；应做好防雷电、防火等的安全防护工作；承担施工现场和施工人员的治安、环境卫生、计生、外来人员暂住手续等管理工作和相关费用；若发生任何事故，均由承包人负责。
（5）承包人应负责整个场地的安全文明卫生管理，做到文明施工，保持施工场地清洁，施工现场做好标识、围挡及防护措施，保证过往车辆及行人的人生及财产安全。所有施工建筑垃圾应全部清运出现场。场地平整、场地道路、场地排水排污附属设施等，均由承包人自行负责施工并承担费用，包括在合同价款中。施工过程中发生的各项清理费用、临时性收费、临时设施费、不可预见费用和施工临时便道、堆放场、预制场等临时性占用场地费，由承包方承担，均包括在合同价款中。承包人必须保证整个工程项目在建设过程中无重大安全责任事故产生，并争创“文明工地”。
（6）承包人若发现合同图纸及工料规范之内或互相之间有任何差异，须立刻以书面通知发包人（监理人），说明差异之处，而发包人（监理人）须给予指令。
（7）承包人严把材料质量关。所有进场原材料、成品、半成品、构配件必须向监理单位报验，并出具相应的质量证明文件，按规定经监理见证取样，交由具有相应资质的检测机构进行复验，复验合格后方可使用。
（8）承包人应严格工序报验程序。每道工序完成后，必须在质检员检查合格并填写工序质量评定表、隐蔽验收记录后向监理人报验，由监理人员验收签字后，才能进行下道工序施工。工序验收资料未经监理人员签字的，该工序视为未验收，不得进入下道工序施工。
（9）承包人应规范施工文件资料管理。施工文件资料应按《水利工程建设项目档案管理规定》（水办[2005]480号）进行整理归档。文件资料应随施工进度及时整理，所需表格应按规定中的要求认真填写、字迹清楚、项目齐全、记录准确、真实完整。
（10）承包人应严格遵守国家有关解决拖欠工程款和民工工资的法律、法规，及时支付工程中的材料、设备货款及民工工资等费用。承包人不得以任何借口拖欠材料、设备货款及民工工资等费用，如果出现此种现象，发包人有权代为支付其拖欠的材料、设备货款及民工工资，并从应付给承包人的工程款中扣除相应款项。对恶意拖欠和拒不按计划支付的，作为不良记录纳入水利建设市场信用信息管理系统。
4.2 履约担保
承包人是否提供履约担保：是。履约担保的形式和金额：在发出中标通知书后15日内且在合同签订前，承包人应提交履约担保。履约担保采用现金（银行转账或电汇）或银行保函形式提交，为签约合同价的 10%。在合同工程完工证书颁发后 28 天内无息退还给承包人。
4.3.2 允许承包人分包的工程项目、工作内容与分包金额限额为：
（1）工程项目：_____________________。
（2）工作内容：_____________________。
（3）分包金额限额：_____________________。
4.3.10 分包人项目管理机构的设立：_____________________。
4.5 承包人项目经理
4.5.5补充条款：承包人应按投标承诺指派项目经理（建造师）到职，项目经理（建造师）为承包人书面委派常驻现场负责执行和管理本合同工程的代表。凡本合同执行中的有关技术、工程进度、现场协调、质量管理、安全管理、计量支付、竣工结算等方面工作，由其代表承包人全面负责。合同期间承包人更换项目经理（建造师）应先提出书面申请，并应在更换14天前将更换人员报经发包人、监理人批准，且所更换人员的资格、业绩和信誉不得低于承包人投标时承诺标准，经发包人和监理人书面批准后方可更换，工作移接完毕后方可离开。 本合同的项目经理（建造师）未到职或擅自更换(除因病长期住院治疗及发包人认可的原因外)每人次承包人须向发包人交纳违约金人民币10万元。本合同的项目经理（建造师）每月出勤不得少于22天，发包人有权制定考勤办法。本合同的项目经理（建造师）需常驻现场，短期离开施工场地，应事先征得监理人及发包人同意，并委派代表代行其职责。如发现项目经理（建造师）未签到或没有在现场履行职责，且未事先征得监理人及发包人同意，则发包人可按承包人项目经理擅自离岗，承包人需按每人天1000元标准向发包人支付违约金，上述约定的违约金发包人有权从尚未支付的工程款中直接扣除。
4.6 承包人人员的管理
4.6.3承包人应按投标承诺指派技术负责人等主要管理人员到职，合同期间如需更换技术负责人等，需提前14天将拟代之以相应资历（投标时要求的技术负责人资历）人员报经发包人、监理人批准，工作移接完毕后方可离开。本合同的技术负责人未到职或擅自更换每人次罚款人民币10万元。本合同的关键岗位人员（施工员、质检员、安全员、材料员）未到职或擅自更换每人次罚款人民币1万元。本合同的技术负责人和关键岗位人员每月出勤不得少于22天，发包人有权制定考勤办法。技术负责人擅自离岗，经发现承包人需按每人天1000元标准向发包人支付违约金。关键岗位人员擅自离岗，经发现承包人需按每人天300元标准向发包人支付违约金。上述约定的违约金发包人有权从尚未支付的工程款中直接扣除。
4.11.1 不利物质条件的范围：_____________________。
5.2.1 发包人提供的材料和工程设备见下表：本项目发包人不提供材料和工程设备
（1）发包人提供的的施工设备见下表：无
道路通行权和场外设施的约定：承包人应根据工程的施工需要，配合办理取得出入施工场地的专用和临时道路的通行权，以及取得为工程建设所需修建场外设施的权利，并承担有关费用。发包人应协助承包人办理上述手续。
8.1.1 施工控制网的约定：_发包人应在载明的开工日期前7天通过监理人向承包人提供测量基准点、基准线和水准点及其书面资料。承包人应在收到上述资料后14天内，根据国家测绘基准、测绘系统和工程测量技术规范，按上述基准点（线）以及合同工程精度要求，测设施工控制网，并将施工控制网资料报送监理人审批。监理人应在收到报批件后7天内批复承包人_。9 施工安全、治安保卫和环境保护
9.1.4 发包人提供__另行约定资料，其余资料由承包人负责收集。
9.2.12 下列工程应编制专项施工方案：_土方开挖、模板工程、其他危险性较大的工程。其中__/___应组织专家论证和审查。
9.7.1本合同文明工地的约定：_按照主管部门有关规定执行。
承包人应当按照发包人（监理人）的指示组建现场治安保卫机构，承担治安保卫职责；
承包人应负责编制《施工场地治安管理计划和突发治安事件应急预案》，并在开工后3日内报送监理人（发包人）审批后执行。
11.4.3本合同工程界定异常恶劣气候条件的范围为：
(1) 每小时降雨量达16毫米以上，或连续12小时降雨量达35毫米以上，或连续24小时降雨量达60毫米以上的降雨，连续大于3天；
(2) 风速大于25米/秒的10及以上台风灾害；
(3) 日气温超过38℃的高温，连续大于7天；
(4) 日气温低于0℃的严寒，连续大于7天；
(5) 造成工程损坏的冰雹和大雪灾害；
(6) 其它异常恶劣气候灾害。
以项目所在地的气象主管部门发布的为准。气象主管部门未发布相关气候数据的，双方约定由监理人按有关规定认定。
（1）因承包人原因造成工期延误，承包人应支付逾期完工违约金5000元/天。
（2）逾期完工违约金按天计算，时间自预定的完工日期起到工程完工证书中写明的实际完工日期止（扣除已批准的延长工期），按天计算。
（3）全部逾期完工违约金的总限额为不超过合同总价的5%。
（4）承包人应承担因工期延误而引起的相应延期部分的监理费用。发包人可以从应付或到期应付给承包人的任何款项中或采用其他方法扣除此违约金。
工期提前的奖金约定：不奖励_。
（5）承包人承担暂停施工责任的其它情形：_发包人因防汛安全需要暂停施工的，承包人的工期可相应顺延，由此产生的费用由承包人承担，发包人不予任何补偿。
（3）发包人承担暂停施工责任的其它情形：_按通用合同条款及其他相关规范合格标准执行。
13.7.4 重要隐蔽单元工程和关键部位单元工程质量评定的约定：_/
13.7.7 工程合格标准为：工程施工质量应达到符合《水利水电工程施工质量检验与评定规程》（SL176-2007）、《水利水电工程单元工程施工质量验收评定标准》（SL631～637-2012）、《工程施工质量验收规范》、国家、行业及地方相关施工验收规范达到合格标准；优良标准为：___/___。达到优良的奖金为：___/___。
13.8.4 工程竣工验收时，__承包人向竣工验收委员会汇报并提交历次质量缺陷处理的备案资料。
14.1.5 水工金属结构、启闭机及机电产品进场后的交货检查和验收中，承包人负责验收合格后保管全部的设备并承担相应的费用。
14.1.6 本工程实行见证取样的试块、试件及有关材料：_见证取样的范围和数量应按监理人的指示进行。本工程所有相关的检测费用均由承包人承担。
（6）增加或减少合同中关键项目的工程量超过其工程总量的____/___%，关键项目：____/__，单价调整方式：_不调整_。
15.5.2承包人实现合理化建议的奖励金额为：不予奖励。
15.8.1（1）发包人和承包人组织招标的暂估价项目：_______/_____；发包人组织招标的暂估价项目：_______/_____。
（2）发包人和承包人以招标方式选择暂估价项目供应商或分包人时，双方的权利义务关系：___________/__________。
物价波动引起的价格调整方式：__不予调整。
16.1.2 采用造价信息调整价格差额
工程造价信息的来源：__________/___________。
价格调整的项目和系数：________/_____________。
17.1.3关于计量周期的约定：本项目合同价格形式为固定单价合同，已完成工程量计量。
17.2.1预付款
（1）本招标项目无预付工程款。
17.3.1付款周期：按完成的工程量支付工程进度款。
17.3.3 进度付款证书和支付时间
①本工程设进度款，进度款按每月完成工程量的50%支付至合同价的40%，
②工程完工经有关部门验收合格后，发包人支付至合同价的80%。
③工程结算并经有关部门审核确认并完成相关资料并归档后，发包人支付至审核价的97％（处罚款除外），剩余3％作为工程质量保证金。
④每次付款前，承包人应向发包人开具等额的增值税一般纳税人专用发票，否则发包人有权拒绝付款且不承担任何的违约责任，税金由承包人自理。
17.4.1每个付款周期扣留的质量保证金为工程进度付款的_工程结算价款的3％，待缺陷责任期（工程质量保修期）满后一个月内退还质量保证金（不计利息）。
17.5.1竣工（完工）付款申请单
（1）承包人应提交完工付款申请单一式陆份。
17.5.2竣工（完工）付款证书及支付时间
监理人在收到承包人提交的完工付款申请单后14天内完成核查，发包人应在收到后14天内审核完毕，由监理人向承包人出具经发包人签认的完工付款证书，按17.3.3目的约定进行支付。
17.6.1最终结清申请单
（1）承包人应提交最终结清申请单一式陆份。
承包人应为竣工财务决算编制提供的资料：按主管部门有关规定。
本工程法人验收包括：分部工程验收、单位工程验收、合同工程完工验收；政府验收包括：__阶段验收、专项验收、竣工验收。验收条件为：___/____，验收程序为：_按现行《水利水电建设工程验收规程》(SL223-2008)规定程序组织验收。
18.2.2 本工程由发包人主持的分部工程验收为______/_________，其余由监理人主持。
18.3.4 提前投入使用的单位工程包括：________/____、____________、____________。
18.5.1 本合同工程阶段验收类别包括：按行业主管部门有关规定。
18.6.2 本合同工程专项验收类别包括：按行业主管部门有关规定_。
18.7.3 本工程按行业主管部门有关规定竣工验收技术鉴定（蓄水安全鉴定）。
18.8.1 需要在施工期运行的单位工程或工程设备为：按行业主管部门有关规定_。
18.9.1 试运行的组织：__按通用合同条款约定_；费用承担：由承包人负责_。
本工程缺陷责任期（工程质量保修期）计算如下：工程通过合同工程完工验收后1年。
建筑工程一切险和（或）安装工程一切险投保人由承包人负责；投保内容：_为本合同工程的永久工程、临时工程和设备及已运至施工工地用于永久工程的材料和设备所投的保险；保险金额、保险费率和保险期限：含在报价中，开工日起直至本合同工程竣工验收合格之日止。
承包人应对本工程施工范围内的第三者进行保险，其费用含在报价中。。
20.6.1保险凭证
承包人提交保险凭证的期限：承包人向发包人提交各项保险生效的证据和保险单副本的期限：总监理工程师签发开工令前48小时。
20.6.4保险金不足的补偿
承包人负责补偿的范围与金额：由承包人负责补偿_；发包人负责补偿的范围与金额：__由承包人负责补偿。
21. 不可抗力
21.1不可抗力的确认
视为不可抗力的情形为：
（1）地震、海啸、暴雨（雪）、台风、龙卷风、水灾等自然灾害；
（2）战争、戒严、骚乱、暴动，但纯属承包人或其分包人派遣与雇用的人员由于本合同工程施工原因引起者除外；
（3）核反应、辐射或放射性污染；
（4）空中飞行物体附落或非发包人或承包人责任造成的爆炸、火灾；
（5）瘟疫；
（6）合同约定的其他情形。
上述款中地震、台风和暴雨定义如下：
地震：指国家地震局规定的震级在4.75级以上且烈度在6度以上的地震，即破坏性地震。
台风：指中心附近最大平均风力12级或以上，即风速在32.6米／秒以上的热带气旋。是否构成台风以当地气象站的认定为准。
暴雨：连续3天，24小时降雨量达60毫米以上。
上述风、雨、震等自然灾害必须发生在合同工程所在地并造成实质性影响，才构成不可抗力。地震级别、水位、风力均以当地地震局、水文站、气象站提供的资料为准据。
22. 违约
22.1 承包人违约
22.1.1 承包人违约的情形
双方约定的承包人其他违约责任：
（1）承包人违反本合同约定进行转包或违法分包的，发包人有权责令其改正，承包人应按其转包或分包金额的20%向发包人支付违约金；
（2）承包人违反合同约定采购和使用不合格的材料和工程设备的，发包人有权责令其无条件改正、更换，并赔偿由此给发包人造成的一切损失，同时发包人有权要求承包人承担合同价款5%的违约金；
（3）因承包人的原因造成工程质量不符合合同要求的，发包人有权责令其无条件改正、重做，并赔偿由此给发包人造成的一切损失，同时发包人有权要求承包人承担合同价款5%的违约金；
（4）承包人未经批准，私自将已按照合同约定进入施工现场的材料或设备撤离施工现场的，每发生一次，发包人有权要求承包人承担合同价款1%的违约金，并赔偿由此给发包人造成的一切损失；
（5）承包人在责任缺陷期及保修期内，未能在合理期限对工程缺陷进行修复，或拒绝按发包人要求进行修复的，发包人可自行修复或委托第三方修复，发生的费用及损失全部由承包人承担；
（6）承包人明确表示或以其行为表明不履行合同主要义务的，发包人有权解除合同，承包人应赔偿给发包人造成的一切损失，同时发包人有权要求承包人承担合同价款20%的违约金；
22.1.2承包人违约的处理
承包人违约责任的承担方式：直接从工程款中扣除，不足部分由承包人以其他方式支付
合同当事人友好协商解决不成、不愿提请争议评审或不接受争议评审组意见的，约定的合同争议解决方式：_向项目所在地有管辖权的人民法院提起诉讼。
","template":"","PROJECT_PRICE_LIST_ATTACHMENTS":[{"id":"614dd1af6db4b71858b641dd","md5":"C54B8CB4F*******E2D********611B0","name":"工程项目总价表.xlsx","new_id":"614dd1af6db4b71858b641dd","size":20555,"url":"/file/getcontent/614dd1af6db4b71858b641dd.xlsx"}],"TOTAL_PROJECT_PRICE_LIST_SELECT":"工程项目总价表","CONSTRUCTION_PROJECT_AMOUNT_PRICE_LIST_SELECT":"建筑工程工程量清单报价表","TEMPORARY_PROJECT_AMOUNT_PRICE_LIST_SELECT":"临时工程工程量清单报价表","OTHER_PROJECT_AMOUNT_PRICE_LIST_SELECT":"其他项目工程工程量清单报价表","ELECTRICAL_OR_METALLIC_STRUCTURES_PROJECT_AMOUNT_PRICE_LIST_SELECT":"机电或金属结构工程工程量清单报价表","EQUIPMENT_AND_INSTALLATION_PROJECT_AMOUNT_PRICE_LIST_SELECT":"设备及安装工程工程量清单报价表","OTHER_INDUSTRY_PROJECT_AMOUNT_LIST_ATTACHMENTS":[],"SUPPLEMENTARY_LIST_ATTACHMENTS":[],"TOTAL_PROJECT_PRICE_LIST":[{"index":"","name":"第一部分 建筑工程","cost":"*******","remark":""},{"index":"","name":"第二部分 施工临时工程","cost":"161932","remark":""},{"index":"","name":"小计(元)","cost":"*******","remark":""},{"index":"","name":"总 计","cost":"*******","remark":""}],"PRIMARY_LIST":[{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"第一部分 建筑工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"*******"},{"PROJECT_NUMBER":"一","PROJECT_LIST_NAME":"引水坝工程","UNIT":"","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"337023"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"电厂引水坝","UNIT":"","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"337023"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"土方开挖","UNIT":"m3","QUANTITIES":"1536.27","UNIVALENT":"2.9","TOTAL":"4455"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"砂卵石回填","UNIT":"m3","QUANTITIES":"230.79","UNIVALENT":"15.38","TOTAL":"3550"},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"土方回填","UNIT":"m3","QUANTITIES":"103.14","UNIVALENT":"19.77","TOTAL":"2039"},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"面层大块毛（卵）石（单块》100kg）","UNIT":"m3","QUANTITIES":"63.36","UNIVALENT":"94.65","TOTAL":"5997"},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"回填卵石 利用开挖料","UNIT":"m3","QUANTITIES":"37","UNIVALENT":"14.46","TOTAL":"535"},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"土工布 400g/m2","UNIT":"m2","QUANTITIES":"509.49","UNIVALENT":"12.5","TOTAL":"6369"},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"土工反滤包","UNIT":"个","QUANTITIES":"33","UNIVALENT":"11.78","TOTAL":"389"},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"卵石垫层 利用开挖料","UNIT":"m3","QUANTITIES":"81.68","UNIVALENT":"29.09","TOTAL":"2376"},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"平面钢模板","UNIT":"m2","QUANTITIES":"362.29","UNIVALENT":"50.62","TOTAL":"18339"},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"C15砼灌砌大块（卵）石海漫","UNIT":"m3","QUANTITIES":"167.61","UNIVALENT":"262.68","TOTAL":"44028"},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"C20坝体混凝土","UNIT":"m3","QUANTITIES":"15.48","UNIVALENT":"448.2","TOTAL":"6938"},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"C20坝体埋石砼（埋石率25%）","UNIT":"m3","QUANTITIES":"0","UNIVALENT":"369.44","TOTAL":"0"},{"PROJECT_NUMBER":"13","PROJECT_LIST_NAME":"C20埋石混凝土挡墙（埋石率20%）","UNIT":"m3","QUANTITIES":"226.44","UNIVALENT":"394.85","TOTAL":"89410"},{"PROJECT_NUMBER":"14","PROJECT_LIST_NAME":"C20埋石刺墙砼","UNIT":"m3","QUANTITIES":"42.55","UNIVALENT":"421.19","TOTAL":"17922"},{"PROJECT_NUMBER":"15","PROJECT_LIST_NAME":"C20消力池砼","UNIT":"m3","QUANTITIES":"115.81","UNIVALENT":"450.28","TOTAL":"52147"},{"PROJECT_NUMBER":"16","PROJECT_LIST_NAME":"C25护脚砼","UNIT":"m3","QUANTITIES":"28.8","UNIVALENT":"469.94","TOTAL":"13534"},{"PROJECT_NUMBER":"17","PROJECT_LIST_NAME":"钢筋制安","UNIT":"t","QUANTITIES":"2.353","UNIVALENT":"7411.03","TOTAL":"17438"},{"PROJECT_NUMBER":"18","PROJECT_LIST_NAME":"插筋 φ20 L=0.6m","UNIT":"根","QUANTITIES":"1008","UNIVALENT":"33.01","TOTAL":"33274"},{"PROJECT_NUMBER":"19","PROJECT_LIST_NAME":"DN110PVC排水管","UNIT":"m","QUANTITIES":"51","UNIVALENT":"32.08","TOTAL":"1636"},{"PROJECT_NUMBER":"20","PROJECT_LIST_NAME":"DN75PVC排水管","UNIT":"m","QUANTITIES":"44.21","UNIVALENT":"19.97","TOTAL":"883"},{"PROJECT_NUMBER":"21","PROJECT_LIST_NAME":"橡胶止水带","UNIT":"m","QUANTITIES":"37","UNIVALENT":"52.03","TOTAL":"1925"},{"PROJECT_NUMBER":"22","PROJECT_LIST_NAME":"沥青松木板（沉降缝）","UNIT":"m2","QUANTITIES":"96.46","UNIVALENT":"134.88","TOTAL":"13011"},{"PROJECT_NUMBER":"23","PROJECT_LIST_NAME":"松木板（闸门）","UNIT":"m2","QUANTITIES":"1.64","UNIVALENT":"200","TOTAL":"328"},{"PROJECT_NUMBER":"24","PROJECT_LIST_NAME":"警示牌","UNIT":"个","QUANTITIES":"1","UNIVALENT":"500","TOTAL":"500"},{"PROJECT_NUMBER":"二","PROJECT_LIST_NAME":"渠道工程","UNIT":"","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"*******"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"黄墩金山下垅排涝沟","UNIT":"m","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"*******"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"土方开挖","UNIT":"m3","QUANTITIES":"9498.5","UNIVALENT":"15.49","TOTAL":"147132"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"土方回填","UNIT":"m3","QUANTITIES":"3674","UNIVALENT":"10.21","TOTAL":"37512"},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"回填砂卵石","UNIT":"m3","QUANTITIES":"495","UNIVALENT":"105.29","TOTAL":"52119"},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"碎石垫层","UNIT":"m3","QUANTITIES":"389.017","UNIVALENT":"173.56","TOTAL":"67518"},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"平面钢模板","UNIT":"m2","QUANTITIES":"5351.693","UNIVALENT":"50.62","TOTAL":"270903"},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"C20埋石混凝土挡墙（埋石率20%）","UNIT":"m3","QUANTITIES":"2134","UNIVALENT":"455.64","TOTAL":"972336"},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"C20地梁砼","UNIT":"m3","QUANTITIES":"7.92","UNIVALENT":"547.33","TOTAL":"4335"},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"沥青松木板（伸缩缝）","UNIT":"m2","QUANTITIES":"214.693","UNIVALENT":"134.88","TOTAL":"28958"},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"DN75PVC排水管","UNIT":"m","QUANTITIES":"968","UNIVALENT":"19.97","TOTAL":"19331"},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"过机板","UNIT":"","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"0"},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"土方开挖","UNIT":"m3","QUANTITIES":"19.307","UNIVALENT":"2.9","TOTAL":"56"},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"土方回填","UNIT":"m3","QUANTITIES":"13.173","UNIVALENT":"10.21","TOTAL":"134"},{"PROJECT_NUMBER":"13","PROJECT_LIST_NAME":"平面钢模板","UNIT":"m2","QUANTITIES":"165.28","UNIVALENT":"50.62","TOTAL":"8366"},{"PROJECT_NUMBER":"14","PROJECT_LIST_NAME":"C25桥板砼","UNIT":"m3","QUANTITIES":"23.52","UNIVALENT":"549.43","TOTAL":"12923"},{"PROJECT_NUMBER":"15","PROJECT_LIST_NAME":"C20桥台砼","UNIT":"m3","QUANTITIES":"16.82","UNIVALENT":"525","TOTAL":"8831"},{"PROJECT_NUMBER":"16","PROJECT_LIST_NAME":"C25台帽砼","UNIT":"m3","QUANTITIES":"6.487","UNIVALENT":"568.56","TOTAL":"3688"},{"PROJECT_NUMBER":"17","PROJECT_LIST_NAME":"C20地梁砼","UNIT":"m3","QUANTITIES":"7.92","UNIVALENT":"547.33","TOTAL":"4335"},{"PROJECT_NUMBER":"18","PROJECT_LIST_NAME":"沥青松木板（伸缩缝）","UNIT":"m2","QUANTITIES":"10.133","UNIVALENT":"134.88","TOTAL":"1367"},{"PROJECT_NUMBER":"19","PROJECT_LIST_NAME":"钢筋制安","UNIT":"t","QUANTITIES":"1.92","UNIVALENT":"7411.03","TOTAL":"14229"},{"PROJECT_NUMBER":"20","PROJECT_LIST_NAME":"畜力运输 砂","UNIT":"m3","QUANTITIES":"0","UNIVALENT":"78.83","TOTAL":"0"},{"PROJECT_NUMBER":"21","PROJECT_LIST_NAME":"畜力运输 碎石","UNIT":"m3","QUANTITIES":"0","UNIVALENT":"85.71","TOTAL":"0"},{"PROJECT_NUMBER":"22","PROJECT_LIST_NAME":"畜力运输 水泥","UNIT":"t","QUANTITIES":"0","UNIVALENT":"70.48","TOTAL":"0"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"夵二金山垅引水渠","UNIT":"m","QUANTITIES":"500","UNIVALENT":"524.99","TOTAL":"262495"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"土方开挖","UNIT":"m3","QUANTITIES":"563.13","UNIVALENT":"2.9","TOTAL":"1633"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"土方回填","UNIT":"m3","QUANTITIES":"178.13","UNIVALENT":"10.21","TOTAL":"1819"},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"碎石垫层","UNIT":"m3","QUANTITIES":"98","UNIVALENT":"173.56","TOTAL":"17009"},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"胶合木模板","UNIT":"m2","QUANTITIES":"1365","UNIVALENT":"31.2","TOTAL":"42588"},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"C20渠墙砼","UNIT":"m3","QUANTITIES":"163.5","UNIVALENT":"563.62","TOTAL":"92152"},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"C20渠底砼","UNIT":"m3","QUANTITIES":"106","UNIVALENT":"505.92","TOTAL":"53628"},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"沥青松木板","UNIT":"m2","QUANTITIES":"54.44","UNIVALENT":"134.88","TOTAL":"7343"},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"量水堰不锈钢板","UNIT":"kg","QUANTITIES":"25","UNIVALENT":"9.03","TOTAL":"226"},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"陶瓷水尺","UNIT":"把","QUANTITIES":"1","UNIVALENT":"200","TOTAL":"200"},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"畜力运输 砂","UNIT":"m3","QUANTITIES":"158.58","UNIVALENT":"78.83","TOTAL":"12501"},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"畜力运输 碎石","UNIT":"m3","QUANTITIES":"323.03","UNIVALENT":"85.71","TOTAL":"27687"},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"畜力运输 水泥","UNIT":"t","QUANTITIES":"81","UNIVALENT":"70.48","TOTAL":"5709"},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"桐一甲垅引水渠","UNIT":"m","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"255081"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"土方开挖","UNIT":"m3","QUANTITIES":"904.95","UNIVALENT":"2.9","TOTAL":"2624"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"土方回填","UNIT":"m3","QUANTITIES":"292.5","UNIVALENT":"10.21","TOTAL":"2986"},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"碎石垫层","UNIT":"m3","QUANTITIES":"72.45","UNIVALENT":"173.56","TOTAL":"12574"},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"胶合木模板","UNIT":"m2","QUANTITIES":"1620","UNIVALENT":"31.2","TOTAL":"50544"},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"C20渠墙砼","UNIT":"m3","QUANTITIES":"180","UNIVALENT":"563.62","TOTAL":"101452"},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"C20渠底砼","UNIT":"m3","QUANTITIES":"72","UNIVALENT":"505.92","TOTAL":"36426"},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"沥青松木板","UNIT":"m2","QUANTITIES":"50.96","UNIVALENT":"134.88","TOTAL":"6873"},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"量水堰不锈钢板","UNIT":"kg","QUANTITIES":"25","UNIVALENT":"9.03","TOTAL":"226"},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"陶瓷水尺","UNIT":"把","QUANTITIES":"1","UNIVALENT":"200","TOTAL":"200"},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"畜力运输 砂","UNIT":"m3","QUANTITIES":"148.29","UNIVALENT":"78.83","TOTAL":"11690"},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"畜力运输 碎石","UNIT":"m3","QUANTITIES":"281.72","UNIVALENT":"85.71","TOTAL":"24146"},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"畜力运输 水泥","UNIT":"t","QUANTITIES":"75.76","UNIVALENT":"70.48","TOTAL":"5340"},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"梦笔水库干渠","UNIT":"m","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"*******"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"土方开挖","UNIT":"m3","QUANTITIES":"8961.56","UNIVALENT":"2.9","TOTAL":"25989"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"土方回填","UNIT":"m3","QUANTITIES":"1704.38","UNIVALENT":"10.21","TOTAL":"17402"},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"碎石垫层","UNIT":"m3","QUANTITIES":"439.8","UNIVALENT":"173.56","TOTAL":"76332"},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"胶合木模板","UNIT":"m2","QUANTITIES":"10530","UNIVALENT":"31.2","TOTAL":"328536"},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"C20渠墙砼","UNIT":"m3","QUANTITIES":"1057.5","UNIVALENT":"563.62","TOTAL":"596028"},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"C20渠底砼","UNIT":"m3","QUANTITIES":"423","UNIVALENT":"505.92","TOTAL":"214004"},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"C25过人板砼","UNIT":"m3","QUANTITIES":"1.01","UNIVALENT":"549.43","TOTAL":"555"},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"C20埋石混凝土挡墙（埋石率20%）","UNIT":"m3","QUANTITIES":"46.35","UNIVALENT":"455.64","TOTAL":"21119"},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"C25预制盖板砼","UNIT":"m3","QUANTITIES":"2.03","UNIVALENT":"1039.18","TOTAL":"2110"},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"C25槽板砼","UNIT":"m3","QUANTITIES":"3.88","UNIVALENT":"549.43","TOTAL":"2132"},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"钢筋制安","UNIT":"t","QUANTITIES":"0.622","UNIVALENT":"7411.03","TOTAL":"4610"},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"沥青松木板","UNIT":"m2","QUANTITIES":"296.98","UNIVALENT":"134.88","TOTAL":"40057"},{"PROJECT_NUMBER":"13","PROJECT_LIST_NAME":"量水堰不锈钢板","UNIT":"kg","QUANTITIES":"25","UNIVALENT":"9.03","TOTAL":"226"},{"PROJECT_NUMBER":"14","PROJECT_LIST_NAME":"陶瓷水尺","UNIT":"把","QUANTITIES":"1","UNIVALENT":"200","TOTAL":"200"},{"PROJECT_NUMBER":"15","PROJECT_LIST_NAME":"畜力运输 砂","UNIT":"m3","QUANTITIES":"897.1","UNIVALENT":"78.83","TOTAL":"70718"},{"PROJECT_NUMBER":"16","PROJECT_LIST_NAME":"畜力运输 碎石","UNIT":"m3","QUANTITIES":"1706","UNIVALENT":"85.71","TOTAL":"146221"},{"PROJECT_NUMBER":"17","PROJECT_LIST_NAME":"畜力运输 水泥","UNIT":"t","QUANTITIES":"458.63","UNIVALENT":"70.48","TOTAL":"32324"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"合计","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":"*******"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"第二部分 施工临时工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"161932"},{"PROJECT_NUMBER":"一","PROJECT_LIST_NAME":"施工导流工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"17249"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"电厂引水坝","UNIT":"","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"17249"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"土石围堰填筑 利用料","UNIT":"m3","QUANTITIES":"941.65","UNIVALENT":"6.49","TOTAL":"6111"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"袋装土填筑 利用料","UNIT":"m3","QUANTITIES":"142.34","UNIVALENT":"78.25","TOTAL":"11138"},{"PROJECT_NUMBER":"二","PROJECT_LIST_NAME":"施工专项工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"102612"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"安全生产措施费","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"82090"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"安全生产措施费","UNIT":"项","QUANTITIES":"*******","UNIVALENT":"2","TOTAL":"82090"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"施工现场标准化建设工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"20522"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"施工现场标准化建设工程","UNIT":"项","QUANTITIES":"*******","UNIVALENT":"0.5","TOTAL":"20522"},{"PROJECT_NUMBER":"三","PROJECT_LIST_NAME":"其他施工临时工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"42071"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"其他施工临时工程","UNIT":"项","QUANTITIES":"*******","UNIVALENT":"1","TOTAL":"42071"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"合计","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":"161932"}],"CONSTRUCTION_PROJECT_AMOUNT_PRICE_LIST":[{"index":"","name":"第一部分 建筑工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"*******","remark":""},{"index":"一","name":"引水坝工程","unit":"","project_amount":"0","unit_price":"0","combined_price":"337023","remark":""},{"index":"1","name":"电厂引水坝","unit":"","project_amount":"0","unit_price":"0","combined_price":"337023","remark":""},{"index":"1","name":"土方开挖","unit":"m3","project_amount":"1536.27","unit_price":"2.9","combined_price":"4455","remark":""},{"index":"2","name":"砂卵石回填","unit":"m3","project_amount":"230.79","unit_price":"15.38","combined_price":"3550","remark":""},{"index":"3","name":"土方回填","unit":"m3","project_amount":"103.14","unit_price":"19.77","combined_price":"2039","remark":""},{"index":"4","name":"面层大块毛（卵）石（单块》100kg）","unit":"m3","project_amount":"63.36","unit_price":"94.65","combined_price":"5997","remark":""},{"index":"5","name":"回填卵石 利用开挖料","unit":"m3","project_amount":"37","unit_price":"14.46","combined_price":"535","remark":""},{"index":"6","name":"土工布 400g/m2","unit":"m2","project_amount":"509.49","unit_price":"12.5","combined_price":"6369","remark":""},{"index":"7","name":"土工反滤包","unit":"个","project_amount":"33","unit_price":"11.78","combined_price":"389","remark":""},{"index":"8","name":"卵石垫层 利用开挖料","unit":"m3","project_amount":"81.68","unit_price":"29.09","combined_price":"2376","remark":""},{"index":"9","name":"平面钢模板","unit":"m2","project_amount":"362.29","unit_price":"50.62","combined_price":"18339","remark":""},{"index":"10","name":"C15砼灌砌大块（卵）石海漫","unit":"m3","project_amount":"167.61","unit_price":"262.68","combined_price":"44028","remark":""},{"index":"11","name":"C20坝体混凝土","unit":"m3","project_amount":"15.48","unit_price":"448.2","combined_price":"6938","remark":""},{"index":"12","name":"C20坝体埋石砼（埋石率25%）","unit":"m3","project_amount":"0","unit_price":"369.44","combined_price":"0","remark":""},{"index":"13","name":"C20埋石混凝土挡墙（埋石率20%）","unit":"m3","project_amount":"226.44","unit_price":"394.85","combined_price":"89410","remark":""},{"index":"14","name":"C20埋石刺墙砼","unit":"m3","project_amount":"42.55","unit_price":"421.19","combined_price":"17922","remark":""},{"index":"15","name":"C20消力池砼","unit":"m3","project_amount":"115.81","unit_price":"450.28","combined_price":"52147","remark":""},{"index":"16","name":"C25护脚砼","unit":"m3","project_amount":"28.8","unit_price":"469.94","combined_price":"13534","remark":""},{"index":"17","name":"钢筋制安","unit":"t","project_amount":"2.353","unit_price":"7411.03","combined_price":"17438","remark":""},{"index":"18","name":"插筋 φ20 L=0.6m","unit":"根","project_amount":"1008","unit_price":"33.01","combined_price":"33274","remark":""},{"index":"19","name":"DN110PVC排水管","unit":"m","project_amount":"51","unit_price":"32.08","combined_price":"1636","remark":""},{"index":"20","name":"DN75PVC排水管","unit":"m","project_amount":"44.21","unit_price":"19.97","combined_price":"883","remark":""},{"index":"21","name":"橡胶止水带","unit":"m","project_amount":"37","unit_price":"52.03","combined_price":"1925","remark":""},{"index":"22","name":"沥青松木板（沉降缝）","unit":"m2","project_amount":"96.46","unit_price":"134.88","combined_price":"13011","remark":""},{"index":"23","name":"松木板（闸门）","unit":"m2","project_amount":"1.64","unit_price":"200","combined_price":"328","remark":""},{"index":"24","name":"警示牌","unit":"个","project_amount":"1","unit_price":"500","combined_price":"500","remark":""},{"index":"二","name":"渠道工程","unit":"","project_amount":"0","unit_price":"0","combined_price":"*******","remark":""},{"index":"1","name":"黄墩金山下垅排涝沟","unit":"m","project_amount":"0","unit_price":"0","combined_price":"*******","remark":""},{"index":"1","name":"土方开挖","unit":"m3","project_amount":"9498.5","unit_price":"15.49","combined_price":"147132","remark":""},{"index":"2","name":"土方回填","unit":"m3","project_amount":"3674","unit_price":"10.21","combined_price":"37512","remark":""},{"index":"3","name":"回填砂卵石","unit":"m3","project_amount":"495","unit_price":"105.29","combined_price":"52119","remark":""},{"index":"4","name":"碎石垫层","unit":"m3","project_amount":"389.017","unit_price":"173.56","combined_price":"67518","remark":""},{"index":"5","name":"平面钢模板","unit":"m2","project_amount":"5351.693","unit_price":"50.62","combined_price":"270903","remark":""},{"index":"6","name":"C20埋石混凝土挡墙（埋石率20%）","unit":"m3","project_amount":"2134","unit_price":"455.64","combined_price":"972336","remark":""},{"index":"7","name":"C20地梁砼","unit":"m3","project_amount":"7.92","unit_price":"547.33","combined_price":"4335","remark":""},{"index":"8","name":"沥青松木板（伸缩缝）","unit":"m2","project_amount":"214.693","unit_price":"134.88","combined_price":"28958","remark":""},{"index":"9","name":"DN75PVC排水管","unit":"m","project_amount":"968","unit_price":"19.97","combined_price":"19331","remark":""},{"index":"10","name":"过机板","unit":"","project_amount":"0","unit_price":"0","combined_price":"0","remark":""},{"index":"11","name":"土方开挖","unit":"m3","project_amount":"19.307","unit_price":"2.9","combined_price":"56","remark":""},{"index":"12","name":"土方回填","unit":"m3","project_amount":"13.173","unit_price":"10.21","combined_price":"134","remark":""},{"index":"13","name":"平面钢模板","unit":"m2","project_amount":"165.28","unit_price":"50.62","combined_price":"8366","remark":""},{"index":"14","name":"C25桥板砼","unit":"m3","project_amount":"23.52","unit_price":"549.43","combined_price":"12923","remark":""},{"index":"15","name":"C20桥台砼","unit":"m3","project_amount":"16.82","unit_price":"525","combined_price":"8831","remark":""},{"index":"16","name":"C25台帽砼","unit":"m3","project_amount":"6.487","unit_price":"568.56","combined_price":"3688","remark":""},{"index":"17","name":"C20地梁砼","unit":"m3","project_amount":"7.92","unit_price":"547.33","combined_price":"4335","remark":""},{"index":"18","name":"沥青松木板（伸缩缝）","unit":"m2","project_amount":"10.133","unit_price":"134.88","combined_price":"1367","remark":""},{"index":"19","name":"钢筋制安","unit":"t","project_amount":"1.92","unit_price":"7411.03","combined_price":"14229","remark":""},{"index":"20","name":"畜力运输 砂","unit":"m3","project_amount":"0","unit_price":"78.83","combined_price":"0","remark":""},{"index":"21","name":"畜力运输 碎石","unit":"m3","project_amount":"0","unit_price":"85.71","combined_price":"0","remark":""},{"index":"22","name":"畜力运输 水泥","unit":"t","project_amount":"0","unit_price":"70.48","combined_price":"0","remark":""},{"index":"2","name":"夵二金山垅引水渠","unit":"m","project_amount":"500","unit_price":"524.99","combined_price":"262495","remark":""},{"index":"1","name":"土方开挖","unit":"m3","project_amount":"563.13","unit_price":"2.9","combined_price":"1633","remark":""},{"index":"2","name":"土方回填","unit":"m3","project_amount":"178.13","unit_price":"10.21","combined_price":"1819","remark":""},{"index":"3","name":"碎石垫层","unit":"m3","project_amount":"98","unit_price":"173.56","combined_price":"17009","remark":""},{"index":"4","name":"胶合木模板","unit":"m2","project_amount":"1365","unit_price":"31.2","combined_price":"42588","remark":""},{"index":"5","name":"C20渠墙砼","unit":"m3","project_amount":"163.5","unit_price":"563.62","combined_price":"92152","remark":""},{"index":"6","name":"C20渠底砼","unit":"m3","project_amount":"106","unit_price":"505.92","combined_price":"53628","remark":""},{"index":"7","name":"沥青松木板","unit":"m2","project_amount":"54.44","unit_price":"134.88","combined_price":"7343","remark":""},{"index":"8","name":"量水堰不锈钢板","unit":"kg","project_amount":"25","unit_price":"9.03","combined_price":"226","remark":""},{"index":"9","name":"陶瓷水尺","unit":"把","project_amount":"1","unit_price":"200","combined_price":"200","remark":""},{"index":"10","name":"畜力运输 砂","unit":"m3","project_amount":"158.58","unit_price":"78.83","combined_price":"12501","remark":""},{"index":"11","name":"畜力运输 碎石","unit":"m3","project_amount":"323.03","unit_price":"85.71","combined_price":"27687","remark":""},{"index":"12","name":"畜力运输 水泥","unit":"t","project_amount":"81","unit_price":"70.48","combined_price":"5709","remark":""},{"index":"3","name":"桐一甲垅引水渠","unit":"m","project_amount":"0","unit_price":"0","combined_price":"255081","remark":""},{"index":"1","name":"土方开挖","unit":"m3","project_amount":"904.95","unit_price":"2.9","combined_price":"2624","remark":""},{"index":"2","name":"土方回填","unit":"m3","project_amount":"292.5","unit_price":"10.21","combined_price":"2986","remark":""},{"index":"3","name":"碎石垫层","unit":"m3","project_amount":"72.45","unit_price":"173.56","combined_price":"12574","remark":""},{"index":"4","name":"胶合木模板","unit":"m2","project_amount":"1620","unit_price":"31.2","combined_price":"50544","remark":""},{"index":"5","name":"C20渠墙砼","unit":"m3","project_amount":"180","unit_price":"563.62","combined_price":"101452","remark":""},{"index":"6","name":"C20渠底砼","unit":"m3","project_amount":"72","unit_price":"505.92","combined_price":"36426","remark":""},{"index":"7","name":"沥青松木板","unit":"m2","project_amount":"50.96","unit_price":"134.88","combined_price":"6873","remark":""},{"index":"8","name":"量水堰不锈钢板","unit":"kg","project_amount":"25","unit_price":"9.03","combined_price":"226","remark":""},{"index":"9","name":"陶瓷水尺","unit":"把","project_amount":"1","unit_price":"200","combined_price":"200","remark":""},{"index":"10","name":"畜力运输 砂","unit":"m3","project_amount":"148.29","unit_price":"78.83","combined_price":"11690","remark":""},{"index":"11","name":"畜力运输 碎石","unit":"m3","project_amount":"281.72","unit_price":"85.71","combined_price":"24146","remark":""},{"index":"12","name":"畜力运输 水泥","unit":"t","project_amount":"75.76","unit_price":"70.48","combined_price":"5340","remark":""},{"index":"4","name":"梦笔水库干渠","unit":"m","project_amount":"0","unit_price":"0","combined_price":"*******","remark":""},{"index":"1","name":"土方开挖","unit":"m3","project_amount":"8961.56","unit_price":"2.9","combined_price":"25989","remark":""},{"index":"2","name":"土方回填","unit":"m3","project_amount":"1704.38","unit_price":"10.21","combined_price":"17402","remark":""},{"index":"3","name":"碎石垫层","unit":"m3","project_amount":"439.8","unit_price":"173.56","combined_price":"76332","remark":""},{"index":"4","name":"胶合木模板","unit":"m2","project_amount":"10530","unit_price":"31.2","combined_price":"328536","remark":""},{"index":"5","name":"C20渠墙砼","unit":"m3","project_amount":"1057.5","unit_price":"563.62","combined_price":"596028","remark":""},{"index":"6","name":"C20渠底砼","unit":"m3","project_amount":"423","unit_price":"505.92","combined_price":"214004","remark":""},{"index":"7","name":"C25过人板砼","unit":"m3","project_amount":"1.01","unit_price":"549.43","combined_price":"555","remark":""},{"index":"8","name":"C20埋石混凝土挡墙（埋石率20%）","unit":"m3","project_amount":"46.35","unit_price":"455.64","combined_price":"21119","remark":""},{"index":"9","name":"C25预制盖板砼","unit":"m3","project_amount":"2.03","unit_price":"1039.18","combined_price":"2110","remark":""},{"index":"10","name":"C25槽板砼","unit":"m3","project_amount":"3.88","unit_price":"549.43","combined_price":"2132","remark":""},{"index":"11","name":"钢筋制安","unit":"t","project_amount":"0.622","unit_price":"7411.03","combined_price":"4610","remark":""},{"index":"12","name":"沥青松木板","unit":"m2","project_amount":"296.98","unit_price":"134.88","combined_price":"40057","remark":""},{"index":"13","name":"量水堰不锈钢板","unit":"kg","project_amount":"25","unit_price":"9.03","combined_price":"226","remark":""},{"index":"14","name":"陶瓷水尺","unit":"把","project_amount":"1","unit_price":"200","combined_price":"200","remark":""},{"index":"15","name":"畜力运输 砂","unit":"m3","project_amount":"897.1","unit_price":"78.83","combined_price":"70718","remark":""},{"index":"16","name":"畜力运输 碎石","unit":"m3","project_amount":"1706","unit_price":"85.71","combined_price":"146221","remark":""},{"index":"17","name":"畜力运输 水泥","unit":"t","project_amount":"458.63","unit_price":"70.48","combined_price":"32324","remark":""},{"index":"","name":"合计","unit":"","project_amount":"","unit_price":"","combined_price":"*******","remark":""}],"TEMPORARY_PROJECT_AMOUNT_PRICE_LIST":[{"index":"","name":"第二部分 施工临时工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"161932","remark":""},{"index":"一","name":"施工导流工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"17249","remark":""},{"index":"1","name":"电厂引水坝","unit":"","project_amount":"0","unit_price":"0","combined_price":"17249","remark":""},{"index":"1","name":"土石围堰填筑 利用料","unit":"m3","project_amount":"941.65","unit_price":"6.49","combined_price":"6111","remark":""},{"index":"2","name":"袋装土填筑 利用料","unit":"m3","project_amount":"142.34","unit_price":"78.25","combined_price":"11138","remark":""},{"index":"二","name":"施工专项工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"102612","remark":""},{"index":"1","name":"安全生产措施费","unit":"元","project_amount":"0","unit_price":"0","combined_price":"82090","remark":""},{"index":"1","name":"安全生产措施费","unit":"项","project_amount":"*******","unit_price":"2","combined_price":"82090","remark":""},{"index":"2","name":"施工现场标准化建设工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"20522","remark":""},{"index":"1","name":"施工现场标准化建设工程","unit":"项","project_amount":"*******","unit_price":"0.5","combined_price":"20522","remark":""},{"index":"三","name":"其他施工临时工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"42071","remark":""},{"index":"1","name":"其他施工临时工程","unit":"项","project_amount":"*******","unit_price":"1","combined_price":"42071","remark":""},{"index":"","name":"合计","unit":"","project_amount":"","unit_price":"","combined_price":"161932","remark":""}],"OTHER_PROJECT_AMOUNT_PRICE_LIST":[],"ELECTRICAL_OR_METALLIC_STRUCTURES_PROJECT_AMOUNT_PRICE_LIST":[],"EQUIPMENT_AND_INSTALLATION_PROJECT_AMOUNT_PRICE_LIST":[],"GRAPH_PAPER_ATTACHMENTS":[{"id":"614de722fcf481190cdf1297","md5":"692D5B41FBACE30F********B424AB61","name":"（审核）莲塘（图审后）.YST21.rar","new_id":"614de722fcf481190cdf1297","size":*******,"url":"/file/getcontent/614de722fcf481190cdf1297.rar"},{"id":"614de733fcf481190cdf129d","md5":"*******AF3D157151FCD2F582F4E60D0","name":"9-5莲塘审核.zip","new_id":"614de733fcf481190cdf129d","size":144909,"url":"/file/getcontent/614de733fcf481190cdf129d.zip"},{"id":"614de7346db4b71858b66156","md5":"4E1FD6C1360D76C01F3600FAB34F92F4","name":"莲塘镇施工导流及临时便道设计图.pdf","new_id":"614de7346db4b71858b66156","size":*******,"url":"/file/getcontent/614de7346db4b71858b66156.pdf"},{"id":"6151b68ec82e452c5027ba12","md5":"97121F423E4F********F0A1F43EDCC8","name":"(无关联式)（用这份）1（审核改）莲塘（图审后）.yst21.xls","new_id":"6151b68ec82e452c5027ba12","size":547328,"url":"/file/getcontent/6151b68ec82e452c5027ba12.xls"}],"TECHNICAL_REQUIREMENTS_ATTACHMENTS":[],"ISUNION":"否","UNIONTENDER":"","UNIONCODE":"","UNIONCODETYPE":"","XM_BID_SECTION_NUM":"","PRICE_FORM_CODE":"9","MARGIN_PERCENT":"/","IS_REPORT_PROVINCE_OUTSIDE":"","IS_REPORT_CTBA":"","NOTICE_CONTENT_ATTACHMENTS_PDF":[],"FJGGZY_FILE_LIST":[{"name":"立项批复文件（项目审批核准文件）","key":"SGG_LXPFWJ","val":[{"id":"********c82e452c5022d4b9","md5":"FC8EA59A422A9EB0831FEB02FBEEE3F3","name":"福建省水利厅文件.pdf","new_id":"********c82e452c5022d4b9","size":*******,"url":"/file/getcontent/********c82e452c5022d4b9.pdf"}],"isUpload":true,"limit":""},{"name":"招标文件附件","key":"SGG_ZBWJFJ","val":[{"id":"*******db5cab20374a3dbb0","md5":"9CEEA65DF6F269D4E1E9ACBF7C0DAB7D","name":"授权委托书2.pdf","new_id":"*******db5cab20374a3dbb0","size":*******,"url":"/file/getcontent/*******db5cab20374a3dbb0.pdf"}],"isUpload":true,"limit":""},{"name":"招标公告PDF文件（招标人或其代理机构盖章并由项目负责人签名或者电子签名）","key":"SGG_ZBGGPDFWJ","val":[{"id":"615179c0b5cab20374a336f1","md5":"9453A2691EC79A********C15D71B4FD","name":"招标公告.pdf","new_id":"615179c0b5cab20374a336f1","size":*******,"url":"/file/getcontent/615179c0b5cab20374a336f1.pdf"}],"isUpload":true,"limit":""},{"name":"招标公告电子签章文件（招标人或其代理机构盖章并由项目负责人签名或者电子签名）","key":"SGG_ZBGGDZQZWJ","val":[{"id":"*******fc82e452c50236a8a","md5":"9453A2691EC79A********C15D71B4FD","name":"招标公告.pdf","new_id":"*******fc82e452c50236a8a","size":*******,"url":"/file/getcontent/*******fc82e452c50236a8a.pdf"}],"isUpload":true,"limit":""},{"name":"主要负责人的授权书","key":"SGG_ZYFZRDSQS","val":[{"id":"********b5cab20374a3d66d","md5":"182BE4628B4530DD6EDF138F*******A","name":"授权委托书1(2).pdf","new_id":"********b5cab20374a3d66d","size":*******,"url":"/file/getcontent/********b5cab20374a3d66d.pdf"},{"id":"6151822eb5cab20374a3e911","md5":"79D3F2556B8EF949DDD6DE6A3A246F27","name":"招标人委托代理电子签章授权书.pdf","new_id":"6151822eb5cab20374a3e911","size":4070670,"url":"/file/getcontent/6151822eb5cab20374a3e911.pdf"}],"isUpload":true,"limit":""},{"name":"资金来源落实证明文件","key":"SGG_ZJLYLSZMWJ","val":[{"id":"61517299c82e452c5022d7fe","md5":"F0E446C717868927A646720D6133B73E","name":"资金到位函.pdf","new_id":"61517299c82e452c5022d7fe","size":215533,"url":"/file/getcontent/61517299c82e452c5022d7fe.pdf"}],"isUpload":true,"limit":""},{"name":"招标代理合同","key":"SGG_ZBDLHT","val":[{"id":"615172c3b5cab20374a2a961","md5":"08C5249632BC76BB5BE39869D6D52330","name":"招标代理合同.zip","new_id":"615172c3b5cab20374a2a961","size":11077462,"url":"/file/getcontent/615172c3b5cab20374a2a961.zip"}],"isUpload":false,"limit":""},{"name":"公共资源交易入场登记表","key":"SGG_GGZYJYRCDJB","val":[],"isUpload":false,"limit":""},{"name":"招标代理机构承诺书","key":"SGG_ZBDLJGCNS","val":[],"isUpload":false,"limit":""},{"name":"其他招标代理机构认为需要上传的文件资料","key":"SGG_QTZBDLJGRWXYSCDWJZL","val":[],"isUpload":false,"limit":""},{"name":"入场登记表中由行政主管部门明确入场意见","key":"SGG_RCDJBZYXZZGBMMQRCYJ","val":[],"isUpload":false,"limit":""},{"name":"加盖电子印章的澄清、答疑及补充PDF电子文件","key":"SGG_JGDZYZDCQDYJBCPDFDZWJ","val":[],"isUpload":false,"limit":""},{"name":"投标邀请书","key":"SGG_TBYQS","val":[],"isUpload":false,"limit":""}],"SGG_ZBWJFJ":[{"id":"*******db5cab20374a3dbb0","md5":"9CEEA65DF6F269D4E1E9ACBF7C0DAB7D","name":"授权委托书2.pdf","new_id":"*******db5cab20374a3dbb0","size":*******,"url":"/file/getcontent/*******db5cab20374a3dbb0.pdf"}],"IS_ABLE_USE_DZBH":false,"bookingOptions":[{"value":"1","label":"其他场地"},{"value":"cef360bf-d874-4312-a1c0-dc3ddd96c3d5","label":"中世e招电子交易平台石嘴山平台"},{"value":"7d404270-09fb-4ed3-83ff-f906a82dd643","label":"中世e招电子交易平台银川平台"},{"value":"7c06a30f-abae-4349-9a32-69ac8a57f67f","label":"随行易交易（莆田）公共资源交易平台"},{"value":"0b9db8fb-c404-4939-9a2e-4cf24240d462","label":"中世e招电子交易平台吴忠平台"},{"value":"197cd3c0-241a-4e6c-8dcc-58c768b39721","label":"随行易交易（漳州）公共资源交易平台"},{"value":"bd4ee2a0-6234-4aaa-bf6a-769a0309db2d","label":"随行易交易（龙岩）公共资源交易平台"},{"value":"4077f61c-8973-4a52-aa33-1f284ee5b1a9","label":"随行易交易（宁德）公共资源交易平台"},{"value":"764734c8-f943-408d-ae7d-7c92afe90bcf","label":"中世e招电子交易平台中卫平台"},{"value":"3403de24-75be-4242-bee8-4f38fabc851c","label":"斗门区阳光小额平台"},{"value":"928c2dd9-a5f5-4cda-be1f-f1dc666b8ec5","label":"浦城县公共资源交易中心"},{"value":"8103f762-803f-4460-bb4c-dceb7c4e542d","label":"随行易交易（泉州）公共资源交易平台"},{"value":"3872eb74-fb8f-499e-9d53-f6c48a193781","label":"海南招协招标采购交易平台"},{"value":"8cc8e04c-deed-4129-b22b-a4c1bc336100","label":"随行易交易（福州）公共资源交易平台"},{"value":"bb886a12-1a9c-444c-a08f-90128847961f","label":"公e采电子交易平台场地预约系统"}],"Is_MultiSegment":"否","PM_TABLE_DATA":[{"POST":"项目技术负责人","POST_NUMBER":"1","PROFESSIONAL_TITLE":"中级及以上职称","PROFESSIONAL":"水利水电工程"},{"POST":" 施工员","POST_NUMBER":"1","PROFESSIONAL_TITLE":"具备水行政主管部门核发的合格有效的岗位证书（或中国水利工程协会核发的合格有效的岗位培训合格证书）","PROFESSIONAL":"/"},{"POST":"质检员","POST_NUMBER":"1","PROFESSIONAL_TITLE":"具备水行政主管部门核发的合格有效的岗位证书（或中国水利工程协会核发的合格有效的岗位培训合格证书）","PROFESSIONAL":"/"},{"POST":"材料员","POST_NUMBER":"1","PROFESSIONAL_TITLE":"具备水行政主管部门核发的合格有效的岗位证书（或中国水利工程协会核发的合格有效的岗位培训合格证书）","PROFESSIONAL":"/"},{"POST":" 安全员","POST_NUMBER":"1","PROFESSIONAL_TITLE":"具备水行政主管部门核发的合格有效的岗位证书（或中国水利工程协会核发的合格有效的岗位培训合格证书）和具有水行政主管部门颁发的合格有效的安全考核合格证书（C证）","PROFESSIONAL":"/"}],"EARNEST_BLOCK_METHOD":["现金","支票","银行保函","电子保函","年度保证金"],"updateContent_cost":{"TENDER_QUANTITIES":{"PROJECT_PRICE_LIST_ATTACHMENTS":[{"id":"614dd1af6db4b71858b641dd","md5":"C54B8CB4F*******E2D********611B0","name":"工程项目总价表.xlsx","new_id":"614dd1af6db4b71858b641dd","size":20555,"url":"/file/getcontent/614dd1af6db4b71858b641dd.xlsx"}],"TOTAL_PROJECT_PRICE_LIST_SELECT":"工程项目总价表","CONSTRUCTION_PROJECT_AMOUNT_PRICE_LIST_SELECT":"建筑工程工程量清单报价表","TEMPORARY_PROJECT_AMOUNT_PRICE_LIST_SELECT":"临时工程工程量清单报价表","OTHER_PROJECT_AMOUNT_PRICE_LIST_SELECT":"其他项目工程工程量清单报价表","ELECTRICAL_OR_METALLIC_STRUCTURES_PROJECT_AMOUNT_PRICE_LIST_SELECT":"机电或金属结构工程工程量清单报价表","EQUIPMENT_AND_INSTALLATION_PROJECT_AMOUNT_PRICE_LIST_SELECT":"设备及安装工程工程量清单报价表","SUPPLEMENTARY_LIST_ATTACHMENTS":[],"TOTAL_PROJECT_PRICE_LIST":[{"index":"","name":"第一部分 建筑工程","cost":"*******","remark":""},{"index":"","name":"第二部分 施工临时工程","cost":"161932","remark":""},{"index":"","name":"小计(元)","cost":"*******","remark":""},{"index":"","name":"总 计","cost":"*******","remark":""}],"PRIMARY_LIST":[{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"第一部分 建筑工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"*******"},{"PROJECT_NUMBER":"一","PROJECT_LIST_NAME":"引水坝工程","UNIT":"","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"337023"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"电厂引水坝","UNIT":"","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"337023"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"土方开挖","UNIT":"m3","QUANTITIES":"1536.27","UNIVALENT":"2.9","TOTAL":"4455"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"砂卵石回填","UNIT":"m3","QUANTITIES":"230.79","UNIVALENT":"15.38","TOTAL":"3550"},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"土方回填","UNIT":"m3","QUANTITIES":"103.14","UNIVALENT":"19.77","TOTAL":"2039"},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"面层大块毛（卵）石（单块》100kg）","UNIT":"m3","QUANTITIES":"63.36","UNIVALENT":"94.65","TOTAL":"5997"},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"回填卵石 利用开挖料","UNIT":"m3","QUANTITIES":"37","UNIVALENT":"14.46","TOTAL":"535"},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"土工布 400g/m2","UNIT":"m2","QUANTITIES":"509.49","UNIVALENT":"12.5","TOTAL":"6369"},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"土工反滤包","UNIT":"个","QUANTITIES":"33","UNIVALENT":"11.78","TOTAL":"389"},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"卵石垫层 利用开挖料","UNIT":"m3","QUANTITIES":"81.68","UNIVALENT":"29.09","TOTAL":"2376"},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"平面钢模板","UNIT":"m2","QUANTITIES":"362.29","UNIVALENT":"50.62","TOTAL":"18339"},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"C15砼灌砌大块（卵）石海漫","UNIT":"m3","QUANTITIES":"167.61","UNIVALENT":"262.68","TOTAL":"44028"},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"C20坝体混凝土","UNIT":"m3","QUANTITIES":"15.48","UNIVALENT":"448.2","TOTAL":"6938"},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"C20坝体埋石砼（埋石率25%）","UNIT":"m3","QUANTITIES":"0","UNIVALENT":"369.44","TOTAL":"0"},{"PROJECT_NUMBER":"13","PROJECT_LIST_NAME":"C20埋石混凝土挡墙（埋石率20%）","UNIT":"m3","QUANTITIES":"226.44","UNIVALENT":"394.85","TOTAL":"89410"},{"PROJECT_NUMBER":"14","PROJECT_LIST_NAME":"C20埋石刺墙砼","UNIT":"m3","QUANTITIES":"42.55","UNIVALENT":"421.19","TOTAL":"17922"},{"PROJECT_NUMBER":"15","PROJECT_LIST_NAME":"C20消力池砼","UNIT":"m3","QUANTITIES":"115.81","UNIVALENT":"450.28","TOTAL":"52147"},{"PROJECT_NUMBER":"16","PROJECT_LIST_NAME":"C25护脚砼","UNIT":"m3","QUANTITIES":"28.8","UNIVALENT":"469.94","TOTAL":"13534"},{"PROJECT_NUMBER":"17","PROJECT_LIST_NAME":"钢筋制安","UNIT":"t","QUANTITIES":"2.353","UNIVALENT":"7411.03","TOTAL":"17438"},{"PROJECT_NUMBER":"18","PROJECT_LIST_NAME":"插筋 φ20 L=0.6m","UNIT":"根","QUANTITIES":"1008","UNIVALENT":"33.01","TOTAL":"33274"},{"PROJECT_NUMBER":"19","PROJECT_LIST_NAME":"DN110PVC排水管","UNIT":"m","QUANTITIES":"51","UNIVALENT":"32.08","TOTAL":"1636"},{"PROJECT_NUMBER":"20","PROJECT_LIST_NAME":"DN75PVC排水管","UNIT":"m","QUANTITIES":"44.21","UNIVALENT":"19.97","TOTAL":"883"},{"PROJECT_NUMBER":"21","PROJECT_LIST_NAME":"橡胶止水带","UNIT":"m","QUANTITIES":"37","UNIVALENT":"52.03","TOTAL":"1925"},{"PROJECT_NUMBER":"22","PROJECT_LIST_NAME":"沥青松木板（沉降缝）","UNIT":"m2","QUANTITIES":"96.46","UNIVALENT":"134.88","TOTAL":"13011"},{"PROJECT_NUMBER":"23","PROJECT_LIST_NAME":"松木板（闸门）","UNIT":"m2","QUANTITIES":"1.64","UNIVALENT":"200","TOTAL":"328"},{"PROJECT_NUMBER":"24","PROJECT_LIST_NAME":"警示牌","UNIT":"个","QUANTITIES":"1","UNIVALENT":"500","TOTAL":"500"},{"PROJECT_NUMBER":"二","PROJECT_LIST_NAME":"渠道工程","UNIT":"","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"*******"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"黄墩金山下垅排涝沟","UNIT":"m","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"*******"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"土方开挖","UNIT":"m3","QUANTITIES":"9498.5","UNIVALENT":"15.49","TOTAL":"147132"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"土方回填","UNIT":"m3","QUANTITIES":"3674","UNIVALENT":"10.21","TOTAL":"37512"},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"回填砂卵石","UNIT":"m3","QUANTITIES":"495","UNIVALENT":"105.29","TOTAL":"52119"},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"碎石垫层","UNIT":"m3","QUANTITIES":"389.017","UNIVALENT":"173.56","TOTAL":"67518"},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"平面钢模板","UNIT":"m2","QUANTITIES":"5351.693","UNIVALENT":"50.62","TOTAL":"270903"},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"C20埋石混凝土挡墙（埋石率20%）","UNIT":"m3","QUANTITIES":"2134","UNIVALENT":"455.64","TOTAL":"972336"},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"C20地梁砼","UNIT":"m3","QUANTITIES":"7.92","UNIVALENT":"547.33","TOTAL":"4335"},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"沥青松木板（伸缩缝）","UNIT":"m2","QUANTITIES":"214.693","UNIVALENT":"134.88","TOTAL":"28958"},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"DN75PVC排水管","UNIT":"m","QUANTITIES":"968","UNIVALENT":"19.97","TOTAL":"19331"},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"过机板","UNIT":"","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"0"},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"土方开挖","UNIT":"m3","QUANTITIES":"19.307","UNIVALENT":"2.9","TOTAL":"56"},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"土方回填","UNIT":"m3","QUANTITIES":"13.173","UNIVALENT":"10.21","TOTAL":"134"},{"PROJECT_NUMBER":"13","PROJECT_LIST_NAME":"平面钢模板","UNIT":"m2","QUANTITIES":"165.28","UNIVALENT":"50.62","TOTAL":"8366"},{"PROJECT_NUMBER":"14","PROJECT_LIST_NAME":"C25桥板砼","UNIT":"m3","QUANTITIES":"23.52","UNIVALENT":"549.43","TOTAL":"12923"},{"PROJECT_NUMBER":"15","PROJECT_LIST_NAME":"C20桥台砼","UNIT":"m3","QUANTITIES":"16.82","UNIVALENT":"525","TOTAL":"8831"},{"PROJECT_NUMBER":"16","PROJECT_LIST_NAME":"C25台帽砼","UNIT":"m3","QUANTITIES":"6.487","UNIVALENT":"568.56","TOTAL":"3688"},{"PROJECT_NUMBER":"17","PROJECT_LIST_NAME":"C20地梁砼","UNIT":"m3","QUANTITIES":"7.92","UNIVALENT":"547.33","TOTAL":"4335"},{"PROJECT_NUMBER":"18","PROJECT_LIST_NAME":"沥青松木板（伸缩缝）","UNIT":"m2","QUANTITIES":"10.133","UNIVALENT":"134.88","TOTAL":"1367"},{"PROJECT_NUMBER":"19","PROJECT_LIST_NAME":"钢筋制安","UNIT":"t","QUANTITIES":"1.92","UNIVALENT":"7411.03","TOTAL":"14229"},{"PROJECT_NUMBER":"20","PROJECT_LIST_NAME":"畜力运输 砂","UNIT":"m3","QUANTITIES":"0","UNIVALENT":"78.83","TOTAL":"0"},{"PROJECT_NUMBER":"21","PROJECT_LIST_NAME":"畜力运输 碎石","UNIT":"m3","QUANTITIES":"0","UNIVALENT":"85.71","TOTAL":"0"},{"PROJECT_NUMBER":"22","PROJECT_LIST_NAME":"畜力运输 水泥","UNIT":"t","QUANTITIES":"0","UNIVALENT":"70.48","TOTAL":"0"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"夵二金山垅引水渠","UNIT":"m","QUANTITIES":"500","UNIVALENT":"524.99","TOTAL":"262495"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"土方开挖","UNIT":"m3","QUANTITIES":"563.13","UNIVALENT":"2.9","TOTAL":"1633"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"土方回填","UNIT":"m3","QUANTITIES":"178.13","UNIVALENT":"10.21","TOTAL":"1819"},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"碎石垫层","UNIT":"m3","QUANTITIES":"98","UNIVALENT":"173.56","TOTAL":"17009"},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"胶合木模板","UNIT":"m2","QUANTITIES":"1365","UNIVALENT":"31.2","TOTAL":"42588"},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"C20渠墙砼","UNIT":"m3","QUANTITIES":"163.5","UNIVALENT":"563.62","TOTAL":"92152"},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"C20渠底砼","UNIT":"m3","QUANTITIES":"106","UNIVALENT":"505.92","TOTAL":"53628"},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"沥青松木板","UNIT":"m2","QUANTITIES":"54.44","UNIVALENT":"134.88","TOTAL":"7343"},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"量水堰不锈钢板","UNIT":"kg","QUANTITIES":"25","UNIVALENT":"9.03","TOTAL":"226"},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"陶瓷水尺","UNIT":"把","QUANTITIES":"1","UNIVALENT":"200","TOTAL":"200"},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"畜力运输 砂","UNIT":"m3","QUANTITIES":"158.58","UNIVALENT":"78.83","TOTAL":"12501"},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"畜力运输 碎石","UNIT":"m3","QUANTITIES":"323.03","UNIVALENT":"85.71","TOTAL":"27687"},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"畜力运输 水泥","UNIT":"t","QUANTITIES":"81","UNIVALENT":"70.48","TOTAL":"5709"},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"桐一甲垅引水渠","UNIT":"m","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"255081"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"土方开挖","UNIT":"m3","QUANTITIES":"904.95","UNIVALENT":"2.9","TOTAL":"2624"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"土方回填","UNIT":"m3","QUANTITIES":"292.5","UNIVALENT":"10.21","TOTAL":"2986"},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"碎石垫层","UNIT":"m3","QUANTITIES":"72.45","UNIVALENT":"173.56","TOTAL":"12574"},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"胶合木模板","UNIT":"m2","QUANTITIES":"1620","UNIVALENT":"31.2","TOTAL":"50544"},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"C20渠墙砼","UNIT":"m3","QUANTITIES":"180","UNIVALENT":"563.62","TOTAL":"101452"},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"C20渠底砼","UNIT":"m3","QUANTITIES":"72","UNIVALENT":"505.92","TOTAL":"36426"},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"沥青松木板","UNIT":"m2","QUANTITIES":"50.96","UNIVALENT":"134.88","TOTAL":"6873"},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"量水堰不锈钢板","UNIT":"kg","QUANTITIES":"25","UNIVALENT":"9.03","TOTAL":"226"},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"陶瓷水尺","UNIT":"把","QUANTITIES":"1","UNIVALENT":"200","TOTAL":"200"},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"畜力运输 砂","UNIT":"m3","QUANTITIES":"148.29","UNIVALENT":"78.83","TOTAL":"11690"},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"畜力运输 碎石","UNIT":"m3","QUANTITIES":"281.72","UNIVALENT":"85.71","TOTAL":"24146"},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"畜力运输 水泥","UNIT":"t","QUANTITIES":"75.76","UNIVALENT":"70.48","TOTAL":"5340"},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"梦笔水库干渠","UNIT":"m","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"*******"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"土方开挖","UNIT":"m3","QUANTITIES":"8961.56","UNIVALENT":"2.9","TOTAL":"25989"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"土方回填","UNIT":"m3","QUANTITIES":"1704.38","UNIVALENT":"10.21","TOTAL":"17402"},{"PROJECT_NUMBER":"3","PROJECT_LIST_NAME":"碎石垫层","UNIT":"m3","QUANTITIES":"439.8","UNIVALENT":"173.56","TOTAL":"76332"},{"PROJECT_NUMBER":"4","PROJECT_LIST_NAME":"胶合木模板","UNIT":"m2","QUANTITIES":"10530","UNIVALENT":"31.2","TOTAL":"328536"},{"PROJECT_NUMBER":"5","PROJECT_LIST_NAME":"C20渠墙砼","UNIT":"m3","QUANTITIES":"1057.5","UNIVALENT":"563.62","TOTAL":"596028"},{"PROJECT_NUMBER":"6","PROJECT_LIST_NAME":"C20渠底砼","UNIT":"m3","QUANTITIES":"423","UNIVALENT":"505.92","TOTAL":"214004"},{"PROJECT_NUMBER":"7","PROJECT_LIST_NAME":"C25过人板砼","UNIT":"m3","QUANTITIES":"1.01","UNIVALENT":"549.43","TOTAL":"555"},{"PROJECT_NUMBER":"8","PROJECT_LIST_NAME":"C20埋石混凝土挡墙（埋石率20%）","UNIT":"m3","QUANTITIES":"46.35","UNIVALENT":"455.64","TOTAL":"21119"},{"PROJECT_NUMBER":"9","PROJECT_LIST_NAME":"C25预制盖板砼","UNIT":"m3","QUANTITIES":"2.03","UNIVALENT":"1039.18","TOTAL":"2110"},{"PROJECT_NUMBER":"10","PROJECT_LIST_NAME":"C25槽板砼","UNIT":"m3","QUANTITIES":"3.88","UNIVALENT":"549.43","TOTAL":"2132"},{"PROJECT_NUMBER":"11","PROJECT_LIST_NAME":"钢筋制安","UNIT":"t","QUANTITIES":"0.622","UNIVALENT":"7411.03","TOTAL":"4610"},{"PROJECT_NUMBER":"12","PROJECT_LIST_NAME":"沥青松木板","UNIT":"m2","QUANTITIES":"296.98","UNIVALENT":"134.88","TOTAL":"40057"},{"PROJECT_NUMBER":"13","PROJECT_LIST_NAME":"量水堰不锈钢板","UNIT":"kg","QUANTITIES":"25","UNIVALENT":"9.03","TOTAL":"226"},{"PROJECT_NUMBER":"14","PROJECT_LIST_NAME":"陶瓷水尺","UNIT":"把","QUANTITIES":"1","UNIVALENT":"200","TOTAL":"200"},{"PROJECT_NUMBER":"15","PROJECT_LIST_NAME":"畜力运输 砂","UNIT":"m3","QUANTITIES":"897.1","UNIVALENT":"78.83","TOTAL":"70718"},{"PROJECT_NUMBER":"16","PROJECT_LIST_NAME":"畜力运输 碎石","UNIT":"m3","QUANTITIES":"1706","UNIVALENT":"85.71","TOTAL":"146221"},{"PROJECT_NUMBER":"17","PROJECT_LIST_NAME":"畜力运输 水泥","UNIT":"t","QUANTITIES":"458.63","UNIVALENT":"70.48","TOTAL":"32324"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"合计","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":"*******"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"第二部分 施工临时工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"161932"},{"PROJECT_NUMBER":"一","PROJECT_LIST_NAME":"施工导流工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"17249"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"电厂引水坝","UNIT":"","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"17249"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"土石围堰填筑 利用料","UNIT":"m3","QUANTITIES":"941.65","UNIVALENT":"6.49","TOTAL":"6111"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"袋装土填筑 利用料","UNIT":"m3","QUANTITIES":"142.34","UNIVALENT":"78.25","TOTAL":"11138"},{"PROJECT_NUMBER":"二","PROJECT_LIST_NAME":"施工专项工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"102612"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"安全生产措施费","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"82090"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"安全生产措施费","UNIT":"项","QUANTITIES":"*******","UNIVALENT":"2","TOTAL":"82090"},{"PROJECT_NUMBER":"2","PROJECT_LIST_NAME":"施工现场标准化建设工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"20522"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"施工现场标准化建设工程","UNIT":"项","QUANTITIES":"*******","UNIVALENT":"0.5","TOTAL":"20522"},{"PROJECT_NUMBER":"三","PROJECT_LIST_NAME":"其他施工临时工程","UNIT":"元","QUANTITIES":"0","UNIVALENT":"0","TOTAL":"42071"},{"PROJECT_NUMBER":"1","PROJECT_LIST_NAME":"其他施工临时工程","UNIT":"项","QUANTITIES":"*******","UNIVALENT":"1","TOTAL":"42071"},{"PROJECT_NUMBER":"","PROJECT_LIST_NAME":"合计","UNIT":"","QUANTITIES":"","UNIVALENT":"","TOTAL":"161932"}],"CONSTRUCTION_PROJECT_AMOUNT_PRICE_LIST":[{"index":"","name":"第一部分 建筑工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"*******","remark":""},{"index":"一","name":"引水坝工程","unit":"","project_amount":"0","unit_price":"0","combined_price":"337023","remark":""},{"index":"1","name":"电厂引水坝","unit":"","project_amount":"0","unit_price":"0","combined_price":"337023","remark":""},{"index":"1","name":"土方开挖","unit":"m3","project_amount":"1536.27","unit_price":"2.9","combined_price":"4455","remark":""},{"index":"2","name":"砂卵石回填","unit":"m3","project_amount":"230.79","unit_price":"15.38","combined_price":"3550","remark":""},{"index":"3","name":"土方回填","unit":"m3","project_amount":"103.14","unit_price":"19.77","combined_price":"2039","remark":""},{"index":"4","name":"面层大块毛（卵）石（单块》100kg）","unit":"m3","project_amount":"63.36","unit_price":"94.65","combined_price":"5997","remark":""},{"index":"5","name":"回填卵石 利用开挖料","unit":"m3","project_amount":"37","unit_price":"14.46","combined_price":"535","remark":""},{"index":"6","name":"土工布 400g/m2","unit":"m2","project_amount":"509.49","unit_price":"12.5","combined_price":"6369","remark":""},{"index":"7","name":"土工反滤包","unit":"个","project_amount":"33","unit_price":"11.78","combined_price":"389","remark":""},{"index":"8","name":"卵石垫层 利用开挖料","unit":"m3","project_amount":"81.68","unit_price":"29.09","combined_price":"2376","remark":""},{"index":"9","name":"平面钢模板","unit":"m2","project_amount":"362.29","unit_price":"50.62","combined_price":"18339","remark":""},{"index":"10","name":"C15砼灌砌大块（卵）石海漫","unit":"m3","project_amount":"167.61","unit_price":"262.68","combined_price":"44028","remark":""},{"index":"11","name":"C20坝体混凝土","unit":"m3","project_amount":"15.48","unit_price":"448.2","combined_price":"6938","remark":""},{"index":"12","name":"C20坝体埋石砼（埋石率25%）","unit":"m3","project_amount":"0","unit_price":"369.44","combined_price":"0","remark":""},{"index":"13","name":"C20埋石混凝土挡墙（埋石率20%）","unit":"m3","project_amount":"226.44","unit_price":"394.85","combined_price":"89410","remark":""},{"index":"14","name":"C20埋石刺墙砼","unit":"m3","project_amount":"42.55","unit_price":"421.19","combined_price":"17922","remark":""},{"index":"15","name":"C20消力池砼","unit":"m3","project_amount":"115.81","unit_price":"450.28","combined_price":"52147","remark":""},{"index":"16","name":"C25护脚砼","unit":"m3","project_amount":"28.8","unit_price":"469.94","combined_price":"13534","remark":""},{"index":"17","name":"钢筋制安","unit":"t","project_amount":"2.353","unit_price":"7411.03","combined_price":"17438","remark":""},{"index":"18","name":"插筋 φ20 L=0.6m","unit":"根","project_amount":"1008","unit_price":"33.01","combined_price":"33274","remark":""},{"index":"19","name":"DN110PVC排水管","unit":"m","project_amount":"51","unit_price":"32.08","combined_price":"1636","remark":""},{"index":"20","name":"DN75PVC排水管","unit":"m","project_amount":"44.21","unit_price":"19.97","combined_price":"883","remark":""},{"index":"21","name":"橡胶止水带","unit":"m","project_amount":"37","unit_price":"52.03","combined_price":"1925","remark":""},{"index":"22","name":"沥青松木板（沉降缝）","unit":"m2","project_amount":"96.46","unit_price":"134.88","combined_price":"13011","remark":""},{"index":"23","name":"松木板（闸门）","unit":"m2","project_amount":"1.64","unit_price":"200","combined_price":"328","remark":""},{"index":"24","name":"警示牌","unit":"个","project_amount":"1","unit_price":"500","combined_price":"500","remark":""},{"index":"二","name":"渠道工程","unit":"","project_amount":"0","unit_price":"0","combined_price":"*******","remark":""},{"index":"1","name":"黄墩金山下垅排涝沟","unit":"m","project_amount":"0","unit_price":"0","combined_price":"*******","remark":""},{"index":"1","name":"土方开挖","unit":"m3","project_amount":"9498.5","unit_price":"15.49","combined_price":"147132","remark":""},{"index":"2","name":"土方回填","unit":"m3","project_amount":"3674","unit_price":"10.21","combined_price":"37512","remark":""},{"index":"3","name":"回填砂卵石","unit":"m3","project_amount":"495","unit_price":"105.29","combined_price":"52119","remark":""},{"index":"4","name":"碎石垫层","unit":"m3","project_amount":"389.017","unit_price":"173.56","combined_price":"67518","remark":""},{"index":"5","name":"平面钢模板","unit":"m2","project_amount":"5351.693","unit_price":"50.62","combined_price":"270903","remark":""},{"index":"6","name":"C20埋石混凝土挡墙（埋石率20%）","unit":"m3","project_amount":"2134","unit_price":"455.64","combined_price":"972336","remark":""},{"index":"7","name":"C20地梁砼","unit":"m3","project_amount":"7.92","unit_price":"547.33","combined_price":"4335","remark":""},{"index":"8","name":"沥青松木板（伸缩缝）","unit":"m2","project_amount":"214.693","unit_price":"134.88","combined_price":"28958","remark":""},{"index":"9","name":"DN75PVC排水管","unit":"m","project_amount":"968","unit_price":"19.97","combined_price":"19331","remark":""},{"index":"10","name":"过机板","unit":"","project_amount":"0","unit_price":"0","combined_price":"0","remark":""},{"index":"11","name":"土方开挖","unit":"m3","project_amount":"19.307","unit_price":"2.9","combined_price":"56","remark":""},{"index":"12","name":"土方回填","unit":"m3","project_amount":"13.173","unit_price":"10.21","combined_price":"134","remark":""},{"index":"13","name":"平面钢模板","unit":"m2","project_amount":"165.28","unit_price":"50.62","combined_price":"8366","remark":""},{"index":"14","name":"C25桥板砼","unit":"m3","project_amount":"23.52","unit_price":"549.43","combined_price":"12923","remark":""},{"index":"15","name":"C20桥台砼","unit":"m3","project_amount":"16.82","unit_price":"525","combined_price":"8831","remark":""},{"index":"16","name":"C25台帽砼","unit":"m3","project_amount":"6.487","unit_price":"568.56","combined_price":"3688","remark":""},{"index":"17","name":"C20地梁砼","unit":"m3","project_amount":"7.92","unit_price":"547.33","combined_price":"4335","remark":""},{"index":"18","name":"沥青松木板（伸缩缝）","unit":"m2","project_amount":"10.133","unit_price":"134.88","combined_price":"1367","remark":""},{"index":"19","name":"钢筋制安","unit":"t","project_amount":"1.92","unit_price":"7411.03","combined_price":"14229","remark":""},{"index":"20","name":"畜力运输 砂","unit":"m3","project_amount":"0","unit_price":"78.83","combined_price":"0","remark":""},{"index":"21","name":"畜力运输 碎石","unit":"m3","project_amount":"0","unit_price":"85.71","combined_price":"0","remark":""},{"index":"22","name":"畜力运输 水泥","unit":"t","project_amount":"0","unit_price":"70.48","combined_price":"0","remark":""},{"index":"2","name":"夵二金山垅引水渠","unit":"m","project_amount":"500","unit_price":"524.99","combined_price":"262495","remark":""},{"index":"1","name":"土方开挖","unit":"m3","project_amount":"563.13","unit_price":"2.9","combined_price":"1633","remark":""},{"index":"2","name":"土方回填","unit":"m3","project_amount":"178.13","unit_price":"10.21","combined_price":"1819","remark":""},{"index":"3","name":"碎石垫层","unit":"m3","project_amount":"98","unit_price":"173.56","combined_price":"17009","remark":""},{"index":"4","name":"胶合木模板","unit":"m2","project_amount":"1365","unit_price":"31.2","combined_price":"42588","remark":""},{"index":"5","name":"C20渠墙砼","unit":"m3","project_amount":"163.5","unit_price":"563.62","combined_price":"92152","remark":""},{"index":"6","name":"C20渠底砼","unit":"m3","project_amount":"106","unit_price":"505.92","combined_price":"53628","remark":""},{"index":"7","name":"沥青松木板","unit":"m2","project_amount":"54.44","unit_price":"134.88","combined_price":"7343","remark":""},{"index":"8","name":"量水堰不锈钢板","unit":"kg","project_amount":"25","unit_price":"9.03","combined_price":"226","remark":""},{"index":"9","name":"陶瓷水尺","unit":"把","project_amount":"1","unit_price":"200","combined_price":"200","remark":""},{"index":"10","name":"畜力运输 砂","unit":"m3","project_amount":"158.58","unit_price":"78.83","combined_price":"12501","remark":""},{"index":"11","name":"畜力运输 碎石","unit":"m3","project_amount":"323.03","unit_price":"85.71","combined_price":"27687","remark":""},{"index":"12","name":"畜力运输 水泥","unit":"t","project_amount":"81","unit_price":"70.48","combined_price":"5709","remark":""},{"index":"3","name":"桐一甲垅引水渠","unit":"m","project_amount":"0","unit_price":"0","combined_price":"255081","remark":""},{"index":"1","name":"土方开挖","unit":"m3","project_amount":"904.95","unit_price":"2.9","combined_price":"2624","remark":""},{"index":"2","name":"土方回填","unit":"m3","project_amount":"292.5","unit_price":"10.21","combined_price":"2986","remark":""},{"index":"3","name":"碎石垫层","unit":"m3","project_amount":"72.45","unit_price":"173.56","combined_price":"12574","remark":""},{"index":"4","name":"胶合木模板","unit":"m2","project_amount":"1620","unit_price":"31.2","combined_price":"50544","remark":""},{"index":"5","name":"C20渠墙砼","unit":"m3","project_amount":"180","unit_price":"563.62","combined_price":"101452","remark":""},{"index":"6","name":"C20渠底砼","unit":"m3","project_amount":"72","unit_price":"505.92","combined_price":"36426","remark":""},{"index":"7","name":"沥青松木板","unit":"m2","project_amount":"50.96","unit_price":"134.88","combined_price":"6873","remark":""},{"index":"8","name":"量水堰不锈钢板","unit":"kg","project_amount":"25","unit_price":"9.03","combined_price":"226","remark":""},{"index":"9","name":"陶瓷水尺","unit":"把","project_amount":"1","unit_price":"200","combined_price":"200","remark":""},{"index":"10","name":"畜力运输 砂","unit":"m3","project_amount":"148.29","unit_price":"78.83","combined_price":"11690","remark":""},{"index":"11","name":"畜力运输 碎石","unit":"m3","project_amount":"281.72","unit_price":"85.71","combined_price":"24146","remark":""},{"index":"12","name":"畜力运输 水泥","unit":"t","project_amount":"75.76","unit_price":"70.48","combined_price":"5340","remark":""},{"index":"4","name":"梦笔水库干渠","unit":"m","project_amount":"0","unit_price":"0","combined_price":"*******","remark":""},{"index":"1","name":"土方开挖","unit":"m3","project_amount":"8961.56","unit_price":"2.9","combined_price":"25989","remark":""},{"index":"2","name":"土方回填","unit":"m3","project_amount":"1704.38","unit_price":"10.21","combined_price":"17402","remark":""},{"index":"3","name":"碎石垫层","unit":"m3","project_amount":"439.8","unit_price":"173.56","combined_price":"76332","remark":""},{"index":"4","name":"胶合木模板","unit":"m2","project_amount":"10530","unit_price":"31.2","combined_price":"328536","remark":""},{"index":"5","name":"C20渠墙砼","unit":"m3","project_amount":"1057.5","unit_price":"563.62","combined_price":"596028","remark":""},{"index":"6","name":"C20渠底砼","unit":"m3","project_amount":"423","unit_price":"505.92","combined_price":"214004","remark":""},{"index":"7","name":"C25过人板砼","unit":"m3","project_amount":"1.01","unit_price":"549.43","combined_price":"555","remark":""},{"index":"8","name":"C20埋石混凝土挡墙（埋石率20%）","unit":"m3","project_amount":"46.35","unit_price":"455.64","combined_price":"21119","remark":""},{"index":"9","name":"C25预制盖板砼","unit":"m3","project_amount":"2.03","unit_price":"1039.18","combined_price":"2110","remark":""},{"index":"10","name":"C25槽板砼","unit":"m3","project_amount":"3.88","unit_price":"549.43","combined_price":"2132","remark":""},{"index":"11","name":"钢筋制安","unit":"t","project_amount":"0.622","unit_price":"7411.03","combined_price":"4610","remark":""},{"index":"12","name":"沥青松木板","unit":"m2","project_amount":"296.98","unit_price":"134.88","combined_price":"40057","remark":""},{"index":"13","name":"量水堰不锈钢板","unit":"kg","project_amount":"25","unit_price":"9.03","combined_price":"226","remark":""},{"index":"14","name":"陶瓷水尺","unit":"把","project_amount":"1","unit_price":"200","combined_price":"200","remark":""},{"index":"15","name":"畜力运输 砂","unit":"m3","project_amount":"897.1","unit_price":"78.83","combined_price":"70718","remark":""},{"index":"16","name":"畜力运输 碎石","unit":"m3","project_amount":"1706","unit_price":"85.71","combined_price":"146221","remark":""},{"index":"17","name":"畜力运输 水泥","unit":"t","project_amount":"458.63","unit_price":"70.48","combined_price":"32324","remark":""},{"index":"","name":"合计","unit":"","project_amount":"","unit_price":"","combined_price":"*******","remark":""}],"TEMPORARY_PROJECT_AMOUNT_PRICE_LIST":[{"index":"","name":"第二部分 施工临时工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"161932","remark":""},{"index":"一","name":"施工导流工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"17249","remark":""},{"index":"1","name":"电厂引水坝","unit":"","project_amount":"0","unit_price":"0","combined_price":"17249","remark":""},{"index":"1","name":"土石围堰填筑 利用料","unit":"m3","project_amount":"941.65","unit_price":"6.49","combined_price":"6111","remark":""},{"index":"2","name":"袋装土填筑 利用料","unit":"m3","project_amount":"142.34","unit_price":"78.25","combined_price":"11138","remark":""},{"index":"二","name":"施工专项工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"102612","remark":""},{"index":"1","name":"安全生产措施费","unit":"元","project_amount":"0","unit_price":"0","combined_price":"82090","remark":""},{"index":"1","name":"安全生产措施费","unit":"项","project_amount":"*******","unit_price":"2","combined_price":"82090","remark":""},{"index":"2","name":"施工现场标准化建设工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"20522","remark":""},{"index":"1","name":"施工现场标准化建设工程","unit":"项","project_amount":"*******","unit_price":"0.5","combined_price":"20522","remark":""},{"index":"三","name":"其他施工临时工程","unit":"元","project_amount":"0","unit_price":"0","combined_price":"42071","remark":""},{"index":"1","name":"其他施工临时工程","unit":"项","project_amount":"*******","unit_price":"1","combined_price":"42071","remark":""},{"index":"","name":"合计","unit":"","project_amount":"","unit_price":"","combined_price":"161932","remark":""}],"OTHER_PROJECT_AMOUNT_PRICE_LIST":[],"ELECTRICAL_OR_METALLIC_STRUCTURES_PROJECT_AMOUNT_PRICE_LIST":[],"EQUIPMENT_AND_INSTALLATION_PROJECT_AMOUNT_PRICE_LIST":[]}},"updateContent_price":{"CONTROL_PRICE":"*******","COMPETITION_PRICE":"*******","NON_COMPETITION_PRICE":"144683"},"UUM_ENTP_BASE_INFO":{"BusinessData":"","OrganizationNumber":"","Email":"qianyuzx@163.com","LocaltaxData":"","tbwjAttachments":{"Busattachments":[],"Socattachments":[{"id":"5aa0f83aa6e3252ae01a3773","md5":"67F876B4922E30D6A7673F9600425DDA","name":"仟羽营业执照证.jpg","new_id":"5aa0f83aa6e3252ae01a3773","url":"/file/getcontent/5aa0f83aa6e3252ae01a3773.jpg"},{"id":"5ef98bee62d265f4e8cee8f7","md5":"4A3FDAD5BBAFFDB4921F365DDF426AA5","name":"（最新）营业执照副本.jpg","new_id":"5ef98bee62d265f4e8cee8f7","size":524749,"url":"/file/getcontent/5ef98bee62d265f4e8cee8f7.jpg"}],"Staattachments":[],"Govattachments":[],"Orgattachments":[],"Locattachments":[]},"BasicName":"福建省仟羽工程咨询有限公司","BasicUnitName":"福建省仟羽工程咨询有限公司","LocaltaxNumber":"","LeType":"2","Currency":"156","LeoIDType":"身份证","GoverData":"","StateTaxNumberDas":false,"LeoIDNumber":"350104196703270022","ConPhone":"15159506769","CreditRatingLabel":"","OrganizationData":"","unitName":"福建省仟羽工程咨询有限公司","CreditRating":"A","ENTP_PROPERTY":"9","LeoPhone":"18650791155","City":"泉州市","Province":"福建省","GoverNumber":"","SocietyData":"","OrganizationNumberDas":false,"Country":"中国|
招标
|
- 关注我们可获得更多采购需求 |
关注 |
最近搜索
无
热门搜索
无
